Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.
Conditions to Obligation of the Buyer The obligation of the Buyer to consummate the transactions to be performed by it in connection with the Closing is subject to satisfaction of the following conditions:
(i) the representations and warranties set forth in Section 3(a) above shall be true and correct in all material respects at and as of the Closing Date;
(ii) the Seller shall have performed and complied with all of their covenants hereunder in all material respects through the Closing;
(iii) there shall not be any injunction, judgment, order, decree, ruling, or charge in effect preventing consummation of any of the transactions contemplated by this Agreement;
(iv) all necessary governmental, shareholder and third party consents and approvals in connection with the transactions contemplated by the Agreement shall have been obtained;
(v) the Seller shall have delivered to the Buyer certificates executed by the responsible officer or the secretary of the Seller, as applicable, certifying (A) that each of the conditions specified in Section 9(a)(i)-(iv) are satisfied in all respects, (B) the resolution(s) of the Seller's board of directors authorizing the Seller's execution, delivery and performance of the Agreement and all matters in connection with the Agreement and transactions contemplated thereby, and (C) the incumbency of the officer of the Seller executing the Agreement and all other documents executed and delivered in connection therewith;
(vi) the relevant parties shall have entered into the agreements in the forms set forth in (A) Exhibit G (Agreement Amending the Warrants), (B) Exhibit H (Assumption Agreement regarding the Warrants) and (C) Exhibit I (Agreement Amending Securities Purchase Agreement) and attached hereto and the same shall be in full force and effect;
(vii) the Buyer shall have received: (A) from Hungarian Counsel of the Seller, a legal opinion in the form set forth in Exhibit L attached hereto, and dated as of the Closing Date, to the effect that (u) the Seller need not give any notice to, make any filing with, or obtain any authorization, consent, or approval of any government or governmental agency in order to consummate the transactions contemplated by this Agreement, or if such notice filing, authorization, consent or approval is needed, it has been gained or obtained, (v) any arbitration award in favor of the Buyer obtained pursuant to this Agreement would be valid and enforceable before a court of competent jurisdiction in Hungary and (x) the matters set forth in Section 3(a)(i) and the first and third sentences of Section 3(a)(ii) of the Agreement; and (B) from US Counsel to the Seller, an opinion in the form as may be attached hereto as Exhibit K, and dated as of the Closing Date (y) covering the matters set forth in the second sentence of Section 3(a)(ii) of the Agreement and (z) stating that no registration is required under the Securities Act to transfer the Shares, Unsecured Notes or the Warrants to Buyer in accordance with the Agreement;
(viii) the Closing Arrangements set forth in Exhibit J attached hereto shall have been implemented in full to the Buyer's satisfaction; for the avoidance of doubt Seller acknowledges and agrees that unless and until the Closing Arrangements set forth in Exhibit J have been implemented as contemplated by this Section 9(a)(viii), Buyer shall have no obligation whatsoever to pay the Purchase Price;
(ix) Since the date of the this Agreement, no event or events shall have occurred which have had or reasonably may be expected to have a Material Adverse Effect;
(x) All actions to be taken by the Seller in connection with consummation of the transactions contemplated hereby and all certificates, opinions, instruments, and other documents required to effect the transactions contemplated hereby will be reasonably satisfactory in form and substance to the Buyer; and
(xi) The Buyer shall have had the opportunity to conduct a reasonable investigation of the matters set forth in Schedule 3(a)(viii) of this Agreement and satisfy itself that no material commercial risk will be transferred with respect to the Shares, Unsecured Notes and Warrants as a result of the dispute described therein in the event that the Closing shall occur. The Buyer may waive any condition specified in this Section 9(a) if it executes a writing so stating at or prior to the Closing.
Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.
Condition of Facilities (i) Use of the Real Property of Purchaser for the various purposes for which it is presently being used is permitted as of right under all Applicable Laws related to zoning and is not subject to “permitted nonconforming” use or structure classifications. All Improvements are in compliance with all Applicable Laws, including those pertaining to zoning, building and the disabled, are in good repair and in good condition, ordinary wear and tear excepted, and are free from latent and patent defects. To the Knowledge of Purchaser, no part of any Improvement encroaches on any real property not included in the Real Property of Purchaser, and there are no buildings, structures, fixtures or other Improvements primarily situated on adjoining property which encroach on any part of the Land.
(ii) Each item of Tangible Personal Property is in good repair and good operating condition, ordinary wear and tear excepted, is suitable for immediate use in the Ordinary Course of Business and is free from latent and patent defects. No item of Tangible Personal Property is in need of repair or replacement other than as part of routine maintenance in the Ordinary Course of Business. Except as disclosed in Schedule 5.1(l)(ii), all Tangible Personal Property used in the Purchaser Business is in the possession of Purchaser.
Additional Conditions to Obligation of the Company The obligation of the Company to effect the Merger is also subject to the following conditions:
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Conditions to Obligation of the Company The obligation of the Company to effect the Merger is also subject to the satisfaction or waiver by the Company at or prior to the Effective Time of the following conditions:
CONDITIONS OF PREMISES A. Within seven (7) days after you move-in, you are required to submit an online Room Condition Update to notify us in writing of any defects or damages in your assigned space (including common area, fixtures, appliances and furniture). Failure to do so will result in the assigned space being considered to be in a clean, safe and good working condition and you will be responsible for defects or damages that may have occurred before you moved in.
B. With the exception of the items emailed to you or that you have submitted through the online Room Condition Update, you accept your assigned space, the fixtures, appliances and furniture in their “AS-IS” condition, with any faults. With regard to your assigned space, and the fixtures, appliances and furniture within, we make no express warranties and disclaim any and all implied warranties (other than the warranty of habitability).
C. Excluding ordinary wear and tear from normal usage, you will be solely responsible to the Housing Office for damages to your assigned space and the furnishings provided in the assigned space. You are responsible for the cost of all repairs made necessary by you and/or your guest(s) or, as set forth below, any other person in violation of the License. This includes the negligent or careless use of your assigned space or any part of the residence hall, including, without limitation, damage from waste water stoppages caused by foreign or improper objects in lines serving the bathroom used by you, damages to furniture, appliances, doors, windows or screens, damage from windows or doors being left open and repairs or replacements to security devices necessitated by misuse or damage. You may be required to prepay for these repairs, or, if we decide to advance the funds for the repairs, you will be responsible for repaying us within ten (10) days. In addition, you could be charged for damages that may have been caused by other Residents if we cannot determine who did it, and you will be jointly and severally liable for all damages to other shared areas of the assigned space and any furnishings provided in those shared areas. If the party responsible for damages is identified, we may nonetheless determine, in our sole discretion, if you and other potentially responsible parties are allowed to renew for the next year. Your obligations to pay the charges described in this paragraph will continue after the end of this License.
D. Furnishings Removal. You assume full responsibility for items furnished by us and agree to return them to us at the end of the License Term in as good condition as when you receive them, reasonable wear and tear excepted. You will be responsible for returning all furniture to its original position prior to vacating your assigned space. You will not remove our furniture, fixtures, and/or furnishings from the assigned space for any purpose.
