Conduct of Claims In the event of any claims, statutory fees, costs, charges, penalties (including without limitation any legal costs), contributions, compensations, cost recoveries, expenses or fines being levied or claimed from a person in respect of which an indemnity is provided by the Supplier pursuant to ARTICLE 11, the following provisions shall apply:
(a) subject to Sections 11.3(b), 11.3(c) and 11.3(d), where it appears that a person is or may be entitled to indemnification from the Supplier in respect of all (but not part only) of the liability arising out of a claim, such person entitled to indemnification may at its sole election and subject to:
(i) approval by any relevant insurers (without prejudice to Section 11.3(f); and
(ii) the Supplier providing the party entitled to indemnification with a secured indemnity to its reasonable satisfaction against all costs and expenses (including legal expenses) that it may incur by reason of such action, permit or require the Supplier to dispute the claim on behalf of the person entitled to indemnification at the Supplier’s own expense and take conduct of any defence, dispute, compromise, or appeal of the claim and of any incidental negotiations; provided that the person entitled to indemnification shall give the Supplier (provided at the Supplier’s cost) all reasonable cooperation, access and assistance for the purposes of considering and resisting such claim;
(b) with respect to any claim conducted by the Supplier pursuant to Section 11.3(a):
(i) the Supplier shall keep the person entitled to indemnification fully informed and consult with it about material elements of the conduct of the claim;
(ii) the Supplier shall not bring the name of the person entitled to indemnification (or any Group Member thereof) into disrepute; and
(iii) the Supplier shall not pay or settle such claims without the prior consent of the person entitled to indemnification, such consent not to be unreasonably withheld or delayed;
(c) a person entitled to indemnification shall be free to pay or settle any claim on such terms as it thinks fit (and without prejudice to its rights and remedies under this Agreement) if:
(i) the Supplier is not entitled to, or is not permitted or instructed, take conduct of the claim in accordance with Section 11.3(a); or
(ii) the Supplier fails to comply in any material respect with the provisions of Sections 11.3(a) or 11.3(b);
(d) the person entitled to indemnification pursuant to ARTICLE 11 shall be free at any time to give notice to the Supplier that it is retaining or taking over (as the case may be) the conduct of any defence, dispute, compromise or appeal of any claim (or of any incidental negotiations) to which Section 11.3(a) applies. On receipt of such notice the Supplier shall promptly take all steps necessary to transfer the conduct of such claim to the person entitled to indemnification, and shall provide to the person entitled to indemnification all reasonable co- operation, access and assistance for the purposes of considering and resisting such claim;
(e) if the Supplier pays to the person entitled to indemnification an amount in respect of an indemnity and the person entitled to indemnification subsequently recovers (whether by payment, discount, credit, saving, relief or other benefit or otherwise) a sum which is directly referable to the fact, matter, event or circumstances giving rise to the claim under the indemnity, the person entitled to indemnification shall forthwith repay to the Supplier whichever is the lesser of:
(i) an amount equal to the sum recovered (or the value of the saving or benefit obtained) less any out-of-pocket costs and expenses (including legal expenses) properly incurred by the person entitled to indemnification in recovering the same; and
(ii) the amount paid to the person entitled to indemnification by the Supplier in respect of the claim under the relevant indemnity, provided that there shall be no obligation on the part of the person entitled to indemnification to pursue such recovery and that the Supplier is repaid only to the extent that the amount of such recovery aggregated with any sum recovered from the Supplier exceeds any loss sustained by the person entitled to indemnification;
(f) the Supplier shall inform the person entitled to indemnification of the requirements of any insurer who may have an obligation to provide an indemnity in respect of any liability arising under this Agreement and in relation to such the person entitled to indemnification shall issue instructions accordingly; and
(g) any person entitled to an indemnity from the Supplier must take all reasonable measures to mitigate any loss, damage or liability that it may suffer in respect of any such matter.
Conduct of Indemnification Proceedings Any person entitled to indemnification hereunder shall (i) give prompt notice to the indemnifying party of any claim with respect to which it seeks indemnification and (ii) permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party; provided that any person entitled to indemnification hereunder shall have the right to employ separate counsel and to participate in the defense of such claim, but the fees and expenses of such counsel shall be at the expense of such person unless (a) the indemnifying party has agreed to pay such fees or expenses, or (b) the indemnifying party shall have failed to assume the defense of such claim and employ counsel reasonably satisfactory to such person or (c) in the reasonable judgment of any such person, based upon written advice of its counsel, a conflict of interest exists between such person and the indemnifying party with respect to such claims (in which case, if the person notifies the indemnifying party in writing that such person elects to employ separate counsel at the expense of the indemnifying party, the indemnifying party shall not have the right to assume the defense of such claim on behalf of such person); and provided, further, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations hereunder, except to the extent that such failure to give notice shall materially adversely affect the indemnifying party in the defense of any such claim or litigation. It is understood that the indemnifying party shall not, in connection with any proceeding in the same jurisdiction, be liable for fees or expenses of more than one separate firm of attorneys at any time for all such indemnified parties. No indemnifying party will, except with the consent of the indemnified party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a release from all liability in respect of such claim or litigation.
Payment of Claims A. If advance payment of all or a portion of the Grant funds is permitted by statute or regulation, and the State agrees to provide such advance payment, advance payment shall be made only upon submission of a proper claim setting out the intended purposes of those funds. After such funds have been expended, Grantee shall provide State with a reconciliation of those expenditures. Otherwise, all payments shall be made thirty five (35) days in arrears in conformance with State fiscal policies and procedures. As required by IC § 4-13-2-14.8, all payments will be by the direct deposit by electronic funds transfer to the financial institution designated by the Grantee in writing unless a specific waiver has been obtained from the Indiana Auditor of State
B. Requests for payment will be processed only upon presentation of a Claim Voucher in the form designated by the State. Such Claim Vouchers must be submitted with the budget expenditure report detailing disbursements of state, local and/or private funds by project budget line items.
C. The State may require evidence furnished by the Grantee that substantial progress has been made toward completion of the Project prior to making the first payment under this Grant. All payments are subject to the State's determination that the Grantee's performance to date conforms with the Project as approved, notwithstanding any other provision of this Grant Agreement.
D. Claims shall be submitted to the State within 10 calendar days following the end of the month in which work on or for the Project was performed. The State has the discretion, and reserves the right, to NOT pay any claims submitted later than 35 calendar days following the end of the month in which the services were provided. All final claims and reports must be submitted to the State within 10 calendar days after the expiration or termination of this agreement. Payment for claims submitted after that time may, at the discretion of the State, be denied. Claims may be submitted on a monthly basis only. If Grant funds have been advanced and are unexpended at the time that the final claim is submitted, all such unexpended Grant funds must be returned to the State.
E. Claims must be submitted with accompanying supportive documentation as designated by the State. Claims submitted without supportive documentation will be returned to the Grantee and not processed for payment. Failure to comply with the provisions of this Grant Agreement may result in the denial of a claim for payment.
Survival of Claims Anything contained in this Lease to the contrary notwithstanding, all claims against, and liabilities of, Tenant or Landlord arising prior to any date of termination of this Lease shall survive such termination.
Notification of Claims (a) Except as otherwise provided in this Agreement, a Person that may be entitled to be indemnified under this Agreement (the “Indemnified Party”), shall promptly notify the party liable for such indemnification (the “Indemnifying Party”) in writing of any pending or threatened claim, demand or circumstance that the Indemnified Party has determined has given or would reasonably be expected to give rise to a right of indemnification under this Agreement (including a pending or threatened claim or demand asserted by a third party against the Indemnified Party, such claim being a “Third Party Claim”), describing in reasonable detail the facts and circumstances with respect to the subject matter of such claim, demand or circumstance (a “Claim Notice”); provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article XI except to the extent the Indemnifying Party is prejudiced by such failure, it being understood that notices for claims in respect of a breach or inaccuracy of a representation or warranty or breach of or default under any obligation or covenant must be delivered before the expiration of any applicable survival period specified in Section 11.4(a).
(b) Upon receipt of a notice of a claim for indemnity from an Indemnified Party pursuant to Section 11.5(a) with respect to any Third Party Claim, the Indemnifying Party shall have the right (but not the obligation) to assume the defense and control of any Third Party Claim upon written notice to the Indemnified Party delivered within fifteen (15) Business Days of the Indemnifying Party’s receipt of the applicable Claim Notice and, in the event that the Indemnifying Party shall assume the defense of such claim, it shall allow the Indemnified Party a reasonable opportunity to participate in the defense of such Third Party Claim with its own counsel and at its own expense. The Person that shall control the defense of any such Third Party Claim (the “Controlling Party”) shall select counsel, contractors and consultants of recognized standing and competence after consultation with the other party and shall take all steps reasonably necessary in the defense or settlement of such Third Party Claim.
(c) The Sellers or the Buyer, as the case may be, shall, and shall cause each of its Affiliates and representatives to, reasonably cooperate with the Controlling Party in the defense of any Third Party Claim. The Indemnifying Party shall be authorized to consent to a settlement of, or the entry of any judgment arising from, any Third Party Claim, without the consent of any Indemnified Party; provided that (i) such settlement shall not encumber any of the assets of the Indemnified Party or contain any restriction or condition that would apply to such Indemnified Party or to the conduct of the Indemnified Party’s business, (ii) the Indemnifying Party shall pay all amounts arising out of such settlement or judgment concurrently with the effectiveness of such settlement (subject to Section 11.3, if applicable), and (iii) the Indemnifying Party shall obtain, as a condition of any settlement or other resolution, a complete release of any Indemnified Party potentially affected by such Third Party Claim.
Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Settlement of Claims The Company’s obligation to make the payments provided for in this Agreement and otherwise to perform its obligations hereunder shall not be affected by any circumstances, including, without limitation, any set-off, counterclaim, recoupment, defense or other right which the Company may have against the Executive or others.
Waiver of Claims; Indemnification To the fullest extent permitted by applicable law, You hereby release, waive, discharge and covenant not to xxx Us and Our Contractors for any liability to You, Your personal representatives, assigns, heirs, or successors in interest, or for any loss, damage or expenses, or any claims, demands or Actions therefore, arising from or related to, directly or indirectly, Our or Our Contractors' use of the rights and licenses granted in this Agreement to fulfill the Services and other obligations under this Agreement, including, but not limited to, claims for copyright or trademark infringement, infringement of moral rights, defamation, invasion of rights of privacy, rights of publicity, intrusion, false light, public disclosure of private facts, physical or emotional injury or distress or any similar claim or cause of action in tort, contract, or any other legal theory, now known or hereafter known in any jurisdiction throughout the world. For purposes of this Agreement, "Actions" include any litigation, lawsuit or administrative, governmental or other proceeding including, but not limited to, government investigations, inquiries, hearings, and other requests, or any appeal thereof. You acknowledge that You are solely and fully responsible for the content of the Manuscript and the Work and that We will not be liable to You, or to any third party or other person or entity for the content of Your Manuscript or the Work, regardless of whether We had any knowledge or could have reasonably known of any violation of Your above representations or that the Work or Manuscript otherwise violates law. You will fully indemnify and hold harmless, Us and Our Contractors, and each such entity’s officers, directors, employees, agents, insurers, contractors, successors, and permitted assigns from and against any claim, cause of action, demand, Action, proceeding, losses, liability, cost, expense (including reasonable attorneys’ fees) or damages arising out of or resulting from a breach of contract, including, but not limited to, any breach or alleged breach of any of Your foregoing representations, warranties, and obligations. Until any claim for indemnity hereunder has been fully satisfied, We may retain all payments due You, including Royalties, if any, and/or We may cease providing any further Services; and You will have no right to receive a Refund of any amounts paid by You to Us.
Conduct of Third Party Claims If the matter or circumstance that may give rise to a Claim other than a Tax Claim is a result of or in connection with a claim by a third party (a “Third Party Claim”) then:
11.4.1 the Purchaser shall, to the extent reasonably practicable and subject to Applicable Law, consult with the Seller in relation to the conduct of the Third Party Claim and shall take reasonable account of the views of the Seller before taking any action in relation to the Third Party Claim;
11.4.2 no admissions in relation to the Third Party Claim shall be made by or on behalf of the Purchaser or any member of the Purchaser’s Group and the Third Party Claim shall not be compromised, disposed of or settled without the written consent of the Seller, such consent not to be unreasonably withheld or delayed;
11.4.3 subject to the Seller indemnifying the Purchaser or member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred thereby, the Purchaser shall, or the Purchaser shall procure that the members of the Purchaser’s Group shall, take such action as the Seller may reasonably request to avoid, dispute, deny, defend, resist, appeal, compromise or contest the Third Party Claim;
11.4.4 the Seller shall, subject in each case to being paid all reasonable out-of-pocket costs and expenses:
(i) make available to the Purchaser and the relevant Group Company such persons and all such information as the Purchaser may reasonably request for assessing, contesting, disputing, defending, compromising or appealing the Third Party Claim; and
(ii) shall give the Purchaser and the relevant Group Company reasonable access to its premises and to its books and records for such purpose during normal business hours on any Business Day following reasonable notice being given to the Seller;
11.4.5 subject to 11.4.3, the Seller shall be entitled at its own expense and in its absolute discretion, by notice in writing to the Purchaser, to assume conduct of any Third Party Claim and to have the conduct of any related proceedings, negotiations or appeals;
11.4.6 if the Seller sends a notice to the Purchaser pursuant to Clause 11.4.5 and until such time as any final compromise, agreement, expert determination or non-appealable decision of a court or tribunal of competent jurisdiction is made in respect of that Third Party Claim or that Third Party Claim is otherwise finally disposed of:
(i) the Purchaser shall, and the Purchaser shall procure that any member of the Purchaser’s Group shall:
(a) give, subject to being paid all reasonable costs and expenses, all such information and assistance including access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records (excluding, in each case, information or documents which are protected by legal professional privilege but including, in each case, information or documents that are subject to common interest privilege), as the Seller may reasonably request, including instructing such professional or legal advisers as the Seller may nominate to act on behalf of the Purchaser or other member of the Purchaser’s Group concerned but in accordance with the Seller’s instructions, provided that the appointment of such adviser or advisers shall have been approved in writing by the Purchaser (such approval not to be unreasonably withheld, conditioned or delayed); and
(b) not make any admission of liability, agreement or compromise in relation to that Third Party Claim without the prior written approval of the Seller (such approval not to be unreasonably withheld, conditioned or delayed);
(ii) the Seller shall:
(a) consult with the Purchaser and take reasonable account of the views of the Purchaser before taking any action in relation to the Third Party Claim;
(b) without prejudice to its ability to defend the Third Party Claim, conduct the Third Party Claim with a view to minimising any material harm to the goodwill and reputation of the Wider Group or the Purchaser’s Group;
(c) keep the Purchaser informed of all relevant matters relating to the Third Party Claim and shall promptly forward or procure to be forwarded to the Purchaser copies of all correspondence and other written communications with such other information, including non-written records (except information or documents which are protected by legal professional privilege), relating to the Third Party Claim;
(d) not make any admission of liability, settlement or compromise of the Third Party Claim without the written consent of the Purchaser, such consent not to be unreasonably withheld, conditioned or delayed. If the Purchaser or member of the Purchaser’s Group fails to consent to a settlement or compromise, the maximum liability of the Seller shall (without prejudice to Clause 10) not exceed the full amount of the proposed settlement or compromise and the Purchaser or member of the Purchaser’s Group shall be liable for any damages awarded in excess of the proposed settlement or compromise and costs incurred from (and including) the date the Seller notified the Purchaser of the settlement or compromise; and
(e) indemnify, save as set out in Clause 11.4.6(ii)(d), the Purchaser or other member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred as a result of the Seller assuming conduct of the Third Party Claim.
11.4.7 The covenants in this Clause 11.4 may be enforced:
(i) by any Group Company against the Seller; and
(ii) by any member of the Seller’s Group against the Purchaser or a Group Company, under the Contracts (Rights of Third Parties) Xxx 0000.
11.4.8 The provisions of this Clause 11.4 may be varied or terminated by agreement between the Seller and the Purchaser (and the Purchaser may also release or compromise in whole or in part any liability in respect of rights or claims contemplated by this Clause 11.4) without the consent of any Group Company.
Insurance Indemnification 7.1 The Independent Contractor shall maintain a policy or policies of liability insurance with coverages (including, but not limited to, professional liability coverage) that is/are sufficient to protect NCISD and the Independent Contractor against any claims, demands, causes of action, or damages arising out of the Independent Contractor’s performance of services under this Agreement. The limits of liability of such policy(ies) shall be in an amount acceptable to NCISD. Such policy(ies) (i) shall be written by companies authorized to issue such insurance policy(ies) in the State of Texas, (ii) shall and must name NCISD as an additional insured, and (iii) shall contain no specific limitations on the coverage afforded additional insureds.
7.2 THE INDEPENDENT CONTRACTOR SHALL INDEMNIFY, HOLD HARMLESS, SAVE, AND DEFEND NCISD AND NCISD’S OFFICERS AND EMPLOYEES FROM AND AGAINST ANY AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, AND DAMAGES, INCLUDING BUT NOT LIMITED TO REASONABLE ATTORNEYS’ FEES AND EXPENSES, ARISING OUT OF OR IN ANY WAY RELATED TO THIS AGREEMENT, THE PROVISION OF SERVICES BY THE INDEPENDENT CONTRACTOR, OR ANY NEGLIGENT OR INTENTIONAL ACTS OR OMISSIONS OF THE INDEPENDENT CONTRACTOR.
