Conduct of Business Pending the Closing During the period from the date of this Agreement and continuing until the earlier of the termination of this Agreement in accordance with its terms or the Closing, the Company shall, and shall cause each of its Subsidiaries to, carry on the Business in the ordinary course of business and, to the extent consistent therewith, use all commercially reasonable efforts to preserve the Business intact and preserve the goodwill of and relationships with Governmental Entities, customers, suppliers, partners, lessors, licensors, licensees, contractors, distributors, agents, officers and employees and others having business dealings with the Business, provided that the foregoing shall not prevent Sellers from rejecting Contracts that are not Assumed Contracts. During the period from the date of this Agreement through the Closing Date, the Company shall endeavor to maintain the Net Receivables Amount, the Inventory Value and each component of Inventory at or in excess of the amounts set forth on Schedule 7.1. Without limiting the generality of the first sentence of this Section 7.1, during the period from the date of this Agreement through the Closing Date, the Company shall not, and shall not permit any of its Subsidiaries to, without the prior written consent of Buyer:
(a) abandon any rights under any of the Assumed Contracts; terminate, amend, modify or supplement the terms of any Assumed Contract; or fail to honor or perform, the Assumed Contracts;
(b) other than sales of Inventory in the ordinary course of business or the disposition of obsolete equipment, lease, license, surrender, relinquish, sell, transfer, convey, assign or otherwise dispose of any Acquired Assets;
(c) mortgage, pledge or subject to Liens (other than Permitted Liens), any property, business or any of the Acquired Assets, other than as would not result in any Liability that would be or would increase an Assumed Liability as of or subsequent to the Closing;
(d) incur or permit to be incurred any Liability (other than Accounts Payable or in connection with the performance of Assumed Contracts) that would be or would increase an Assumed Liability as of or subsequent to the Closing;
(e) fail to replenish the Inventory and Supplies of the Business in the ordinary course of business;
(f) increase the salary of any Identified Employee at or after the time such person becomes an Identified Employee, other than in the ordinary course of business consistent with past practice;
(g) make or rescind any material Tax election or take any material Tax position (unless required by law) or file any Tax Return or change its fiscal year or financial or Tax accounting methods, policies or practices, or settle any Tax Liability, except in each case as would not reasonably be expected to affect the Buyer;
(h) institute, settle or agree to settle any litigation, action or Proceeding before any court or Governmental Entity relating to the Acquired Assets, or modify in any manner that is adverse to the Business or the Acquired Assets, rescind or terminate a material Permit, allowance, or credit (or application therefor) relating to the Business or the Acquired Assets;
(i) transfer or grant any rights under, modify any existing rights under, or enter into any settlement regarding the breach or infringement of, any material Intellectual Property; or
(j) enter into any Contract to do any of the foregoing.
Conduct of Business Prior to the Closing (a) Without the consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed, except (x) as otherwise contemplated by this Agreement, the Closing Agreements or the Restructuring, (y) as disclosed on Section 5.1 of the Seller Disclosure Schedule or (z) as required by Law or Order, during the Pre-Closing Period, Seller shall cause the Sold Companies to conduct their businesses (other than in respect of the Legacy Defense Business, which shall not be subject to this Section 5.1(a)) in the ordinary course of business and, to the extent consistent therewith, use commercially reasonable efforts to maintain satisfactory relationships with suppliers, customers, and other third parties having material business relationships with the Sold Companies (other than in respect of the Legacy Defense Business, which shall not be subject to this Section 5.1(a)).
(b) In furtherance of Section 5.1(a), without the consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed, except (x) as otherwise contemplated by this Agreement, the Closing Agreements or the Restructuring, (y) as disclosed on Section 5.1 of the Seller Disclosure Schedule or (z) as required by Law or Order, during the Pre-Closing Period, Seller shall cause each Sold Company (other than in respect of any actions relating to the Legacy Defense Business, which shall not be subject to this Section 5.1(b)) not to (and in the case of Section 5.1(b)(ii)(B), Seller shall not):
(i) amend its certificate of incorporation or bylaws or comparable organizational documents;
(ii) (A) issue, deliver, sell, pledge, dispose of or encumber any shares of capital stock or other ownership interests, or any options, warrants, convertible securities or other rights of any kind to acquire or receive any shares of capital stock or other ownership interests, in the Sold Companies, or (B) issue or grant any Seller Options;
(iii) reclassify, combine, split, subdivide, redeem, purchase or otherwise acquire any shares of capital stock or ownership interests;
(iv) (A) incur any obligations or commitments to make any capital expenditures in excess of $250,000 in the aggregate following the Closing, or (B) cease to continue to make capital expenditures in the ordinary course of business;
(v) with respect to Company Products, make any material change in the selling, distribution, advertising, terms of sale or collection practices outside of the ordinary course of business consistent with past practices;
(vi) after the close of business on the Business Day immediately preceding the Closing Date, declare, set aside, make or pay any dividend or other distribution in respect of the capital stock or other ownership interests of any of the Sold Companies or repurchase, redeem or otherwise acquire, or grant any rights or enter into any Contracts or commitments to repurchase, redeem or acquire, any outstanding shares of the capital stock or ownership interests of any of the Sold Companies;
(vii) acquire (whether by merger, consolidation or acquisition of stock or assets or otherwise) any corporation, partnership or other business organization or division thereof or any assets, other than purchases of inventory and other assets in the ordinary course of business and pursuant to existing Contracts made available to Buyer prior to the date hereof;
(viii) sell, lease, license, assign, transfer or otherwise dispose of (whether by merger, consolidation or acquisition of stock or assets or otherwise) (A) any corporation, partnership or other business organization or division thereof or (B) any Inventory, equipment, assets, rights or properties (including Intellectual Property) for consideration in excess of $50,000, or abandon or allow to expire any issued patent or material registration or application included in the Company-Owned Intellectual Property, in each case, other than (w) sales or dispositions of Inventory and licenses of products and services, in each case, in the ordinary course of business, (x) pursuant to existing Contracts made available to Buyer prior to the date hereof, (y) non-exclusive licenses of Company-Owned Intellectual Property granted in the ordinary course of business as necessary to make available the Company Products or (z) sales of dispositions of obsolete and worthless assets or scrap;
(ix) sell, lease, license, assign, pledge transfer, abandon, permit any Lien on or otherwise dispose of any Company-Owned Intellectual Property used in or necessary for the operation of the businesses of the Sold Companies, other than (x) non-exclusive licenses of Company-Owned Intellectual Property granted in the ordinary course of business or (y) pursuant to existing Contracts made available to Buyer prior to the date hereof;
(x) modify, amend, terminate or waive any rights under any Material Contract in any material respect or enter into any new Contract that would be a Material Contract if entered into prior to the date of this Agreement;
(xi) acquire or obtain any license to any Intellectual Property or technology other than in the ordinary course of business (including commercially available computer software available or design tools on standard terms and in object-code form) for consideration not to exceed $100,000 in the aggregate;
(xii) permit the loss, expiration or termination of any material license or right to any third party Intellectual Property used in or necessary for the operation of the businesses of the Sold Companies other than in the ordinary course of business;
(xiii) agree to by any exclusivity, non-competition, most favored nation, or similar provision or covenant restricting the Sold Companies from competing in any line of business or with any Person or in any area or engaging in any activity or business (including with respect to the development, manufacture, marketing or distribution of their respective products or services);
(xiv) disclose any material trade secrets or other material proprietary or confidential information of the Sold Companies to any Person not subject to a confidentiality or non-disclosure agreement;
(xv) except in the ordinary course of business, make any loans, advances or capital contributions to, or investments in, any other Person (other than in a Subsidiary or sister Subsidiary of such Person);
(xvi) except to the extent required under any Company Benefit Plan or Seller Benefit Plan in existence as of the date hereof or as required by applicable Law: (A) hire or terminate (other than for cause) any Business Employee who holds (or, if hired, would hold) the position of “vice president”, “director”, “manager”, “senior engineer”, “executive” or any other individual in a salary grade of 07 or higher or any individual consultant of the Sold Companies, except with respect to individual consultants who perform services for any of the Sold Companies whose aggregate fees are less than $100,000, (B) increase or establish, or commit to increase or establish, the compensation or benefits of any Business Employee or individual consultant of the Sold Companies, (C) establish, adopt, enter into, amend in any material respect or terminate any Seller Benefit Plan or Company Benefit Plan, in each case, affecting any Business Employees, (D) accelerate the vesting or payment of any compensation or benefits under any Seller Benefit Plan or Company Benefit Plan, in each case, with respect to any Business Employees, or (E) grant any cash bonus, incentive, performance or other incentive compensation to any Business Employee;
Conduct of the Business Pending the Closing (a) Except as otherwise expressly provided by this Agreement or with the prior written consent of Newco, between the date hereof and the Closing, the Company shall:
(i) conduct the Business only in the Ordinary Course of Business;
(ii) use its commercially reasonable efforts to (A) preserve the present business operations, organization (including officers and Employees) and goodwill of the Company and (B) preserve the present relationships with Persons having business dealings with the Company (including customers and suppliers);
(iii) maintain (A) all of the assets and properties of, or used by, the Company consistent with past practice, and (B) insurance upon all of the assets and properties of the Company in such amounts and of such kinds comparable to that in effect on the date of this Agreement;
(iv) (A) maintain the books, accounts and records of the Company in the Ordinary Course of Business, (B) continue to collect accounts receivable and pay accounts payable and other Liabilities set forth on the Balance Sheet in the Ordinary Course of Business utilizing normal procedures and without discounting or accelerating payment of such accounts or Liabilities utilizing all available cash and any available line of credit, and (C) comply with all contractual and other obligations of the Company;
(v) comply with the capital expenditure plan of the Company for 2009 set forth on Company Disclosure Schedule 6.2(a)(v), including making such capital expenditures in the amounts and at the times set forth in such plan;
(vi) comply in all material respects with all applicable Laws;
(vii) take steps to renew all Permits in a timely manner prior to their lapse; and
(viii) pay all maintenance and similar fees and take all other appropriate actions as necessary to prevent the abandonment, loss or impairment of all Intellectual Property of the Company.
(b) Without limiting the generality of the foregoing, except as otherwise expressly provided by this Agreement or with the prior written consent of Newco, the Company shall not:
(i) (A) increase the salary or other compensation of any director or Employee of the Company except for normal year-end increases in the Ordinary Course of Business, (B) grant any bonus, benefit or other direct or indirect compensation to any Employee or director, (C) increase the coverage or benefits available under any (or create any new) severance pay, termination pay, vacation pay, company awards, salary continuation for disability, sick leave, deferred compensation, bonus or other incentive compensation, insurance, pension or other employee benefit plan or arrangement made to, for, or with any of the directors, officers, Employees, agents or representatives of the Company or otherwise modify or amend or terminate any such plan or arrangement (D) enter into any employment, deferred compensation, stay bonus, severance, special pay, consulting, non-competition or similar agreement or arrangement with any directors or officers of the Company (or amend any such agreement) to which the Company is a party; or (E) pay or make any dividend or distribution of cash or other property with respect to the units or other equity interests of the Company;
(ii) (A) create, incur, assume, guarantee, endorse or otherwise become liable or responsible with respect to (whether directly, contingently or otherwise) any Indebtedness except (u) the Indebtedness related to the Permitted Exceptions, (x) the Indebtedness reflected in the Balance Sheet, (y) the Indebtedness incurred in the Ordinary Course of Business since the Balance Sheet Date, or (z) the Indebtedness set forth on Company Disclosure Schedule 4.5; (B) except in the Ordinary Course of Business, pay, prepay, accelerate, discharge, purchase, repurchase or satisfy any Indebtedness issued or guaranteed by the Company; (C) materially modify the terms of any Indebtedness or other Liability; or (D) make any loans, advances of capital contributions to, or investments in, any other Person;
(iii) subject to any Lien or otherwise encumber or, except for Permitted Exceptions, permit, allow or suffer to be subjected to any Lien or otherwise encumbered, any of the Purchased Assets;
(iv) acquire any material properties or assets or sell, assign, license, transfer, convey, lease or otherwise dispose of any of the Purchased Assets (except for fair consideration in the Ordinary Course of Business) of the Company;
(v) except as provided in Section 6.6 hereof, enter into or agree to enter into any merger or consolidation with any Person, and not engage in any new business or invest in, make a loan, advance or capital contribution to, or otherwise acquire the securities of any Person;
(vi) cancel or compromise any debt or claim, or waive or release any material right of the Company except in the Ordinary Course of Business;
(vii) enter into, modify or terminate any labor or collective bargaining agreement or, through negotiation or otherwise, make any commitment or incur any Liability to any labor organization with respect to any Employee;
(viii) introduce any material change with respect to the operation of the Business, including any material change in the types, nature, composition or quality of products or services, or, other than in the Ordinary Course of Business, make any change in product specifications or prices or terms of distributions of such products;
(ix) enter into any transaction or enter into, modify or renew any Contract which by reason of its size or otherwise is not in the Ordinary Course of Business;
(x) enter into any Contract, understanding or commitment that restrains, restricts, limits or impedes the ability of the Business, or the ability of Newco or Purchaser, to compete with or conduct any business or line of business in any geographic area or solicit the employment of any persons;
(xi) terminate, amend, restate, supplement or waive any rights under any (A) Material Contract, Real Property Lease, Personal Property Lease or Intellectual Property License, other than in the Ordinary Course of Business or (B) Permit;
(xii) settle or compromise any pending or threatened Legal Proceeding or any claim or claims for, or that would result in a loss of revenue of, an amount that could, individually or in the aggregate, reasonably be expected to be greater than $50,000;
(xiii) change or modify its credit, collection or payment policies, procedures or practices, including acceleration of collections or receivables (whether or not past due) or fail to pay or delay payment of payables or other liabilities;
(xiv) take any action which would adversely affect the ability of the parties to consummate the transactions contemplated by this Agreement;
(xv) amend the operating agreement of the Company;
(xvi) agree to materially increase Liabilities from the amounts set forth on the Balance Sheet except in the Ordinary Course of Business under loan or credit agreements or arrangements up to the maximum amounts and other terms as in effect on the date of this Agreement; or
(xvii) agree to do anything (A) prohibited by this Section 6.2, (B) that would make any of the representations and warranties of the Company in this Agreement or any of the Company Documents untrue or incorrect in any material respect or could result in any of the conditions to the Closing not being satisfied or (C) that could be reasonably expected to have a Material Adverse Effect with respect to the Company.
Conduct of Business Prior to Closing Between the date of the execution of this Agreement and the Closing, the Borrower and the Guarantor Parties: (a) shall not enter into any agreements of any nature relating to or affecting the Loan Collateral or the business of the Borrower or Guarantor, including any agreement which may restrict the Borrower or Guarantor, as applicable, from operating its business as currently conducted unless the written consent of the Lender shall first be obtained, (b) shall not convey or remove from any location where now located, any of the Loan Collateral to be conveyed under the Conveyance Documents, (c) shall not cancel any insurance policies with respect to the Loan Collateral and shall preserve and maintain its permits and licenses including any cannabis related licenses, (d) shall use commercially reasonable efforts to continue to operate the Cannabis Business and the Loan Collateral in the ordinary course consistent with past practice, subject to the availability of sufficient working capital and the Borrower and Guarantor’s reasonable business judgment, (e) shall use commercially reasonable efforts to preserve the rights, franchises, goodwill and relationships of its employees, customers, lenders, suppliers, regulators and others having business relationships with the Borrower and Guarantor and shall maintain the Loan Collateral in a state of repair and condition that is consistent with the requirements and normal conduct of the business of the Borrower and Guarantor, subject to the availability of sufficient working capital and the Borrower and Guarantor’s reasonable business judgment, (f) shall maintain its books and records in accordance with past practice, (g) shall not incur any Indebtedness other than Permitted Indebtedness or authorize or commit to the same, (h) shall not lend money to or guarantee the debts of any other Person or authorize or commit to the same, (i) shall not issue or amend any securities or authorize or commit to the same, except as contemplated by the Call Option Agreement, (j) shall not take any action that would materially delay, prohibit or impede the transactions contemplated by this Agreement or the Call Option Agreement, (k) shall fully cooperate with any reasonable requests of appraisers retained by the Lender or its counsel, (l) shall comply in all material respects with applicable laws, (m) shall not lend money to, or guarantee the debts of, any other Person, (n) shall not settle or commence any claim, action, cause of action, demand, lawsuit, arbitration, inquiry, audit, notice of violation, proceeding, litigation, citation, summons, subpoena or investigation of any nature, civil, criminal, administrative, regulatory or otherwise, whether at law or in equity commenced to which the Borrower or Guarantor is a party, (o) shall not amend its constating documents, (p) shall not effect any split, consolidation, reclassification, redemption or repurchase of its securities, (q) shall not reorganize, amalgamate or merge, (r) shall not undertake any voluntary dissolution, liquidation or winding-up or any other disposition of its assets for the purpose of winding up, (s) shall not declare, set aside or pay any dividend or other disposition of any kind or nature (whether in cash, stock or property or any combination thereof) in respect of any securities, (t) shall not make any bonus or profit sharing distribution or similar payment of any kind, (u) except as required by applicable law, shall not agree to or make any severance, change of control or termination payment or increase the compensation of any employee, officer, director or consultant, (v) shall not terminate, dismiss, demote or otherwise decrease the job requirement of any officer, (w) shall not appoint any officer, (x) shall complete on a timely basis all requisite filings with Governmental Authorities or as may otherwise be required under applicable law, (y) shall allow a representative of the Lender to attend and observe any meeting of the board of directors of the Borrower or Guarantor, (z) shall not make or enter into any commitment or agreement in contravention of the foregoing and (aa) shall use best efforts to satisfy the conditions to Closing set forth in Section 3 of this Agreement. Notwithstanding the Existing Events of Default, the Borrower and Guarantor Parties shall comply with all covenants contained in the Loan Agreement and the other Loan Documents subject to the continuation of the Existing Events of Default; provided, that the Lender hereby consents to the Transfer of the Loan Collateral to the Designee and such Transfer shall not constitute a Default or Event of Default under the Loan Documents. Notwithstanding the foregoing, to the extent the Modesto Planning Department informs the Lender that any covenant contained in Section 4 of this Agreement constitutes “control” requiring thirty (30) day prior written consent from the Modesto Planning Department, the parties hereto agree that (i) upon written notice from the Lender such covenant shall be deemed to be of no force and effect until such thirty (30) day prior written notice from the Modesto Planning Department has been obtained, (ii) to the extent requested by the Lender in writing, the parties shall agree to amend this Agreement to remove or modify such covenant only to the extent required so as to not trigger such thirty (30) day prior written consent requirement, and (iii) solely to the extent the Lender elects in its sole discretion by written notice to the other parties, this Agreement shall be deemed terminated.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
Conduct of Business Pending Closing Between the date of this Agreement and the Funding and Consummation Date, the Company will, except as set forth on Schedule 7.2:
(i) carry on its business in substantially the same manner as it has heretofore and not introduce any material new method of management, operation or accounting;
(ii) use its reasonable efforts to maintain its properties and facilities, including those held under leases, in as good working order and condition as at present, ordinary wear and tear excepted;
(iii) perform in all material respects all of its obligations under agreements relating to or affecting its respective assets, properties or rights;
(iv) use its reasonable efforts to keep in full force and effect present insurance policies or other comparable insurance coverage;
(v) use its reasonable efforts to maintain and preserve its business organization intact, retain its respective present key employees and maintain its relationships with suppliers, customers and others having business relations with the Company;
(vi) use its reasonable efforts to maintain compliance with all Licenses, laws, rules and regulations, consent orders, and all other orders of applicable courts, regulatory agencies and similar governmental authorities applicable to it;
(vii) maintain present debt and lease instruments and not enter into new or amended debt or lease instruments without the knowledge and consent of TCI (which consent shall not be unreasonably withheld), provided that debt and/or lease instruments may be replaced without the consent of TCI if such replacement instruments are on terms at least as favorable to the Company as the instruments being replaced; and
(viii) maintain or reduce present salaries and commission levels for all officers, directors, employees and agents except for ordinary and customary bonus and salary increases for employees in accordance with past practices.
Conduct of Businesses Prior to the Effective Time (a) During the period from the date of this Agreement to the Effective Time or earlier termination of this Agreement, except as expressly contemplated or permitted by this Agreement or as otherwise required by Law or regulatory directive, each of FNB and HBI shall, and shall cause each of their respective Subsidiaries to (i) conduct its business in the ordinary course in all material respects, (ii) use reasonable best efforts to maintain and preserve intact its business organization, employees and advantageous business relationships and retain the services of its key officers and key employees and (iii) take no action that would reasonably be likely to prevent or materially impede or delay the obtaining of, or materially adversely affect the ability of the parties expeditiously to obtain, any necessary approvals of any Regulatory Agency, Governmental Entity or any other person or entity required for the transactions this Agreement contemplates or to perform its respective covenants and agreements under this Agreement or to consummate the transactions contemplated by this Agreement.
(b) Subject to applicable Law, including Laws with respect to the exchange of information, the disclosure of confidential supervisory information, the protection of personally identifiable information and the exercise of a controlling influence over the management or policies of another Person, HBI agrees that between the date of this Agreement and the Effective Time:
(1) the materials to be presented at the meetings of any HBI Bank loan committee shall be provided to a designated representative of FNB at the same time such materials are provided to such loan committee; (2) HBI shall provide the minutes of each such meeting to the designated FNB representative promptly after such meeting; (3) HBI shall prepare and furnish to FNB at least quarterly an update of the reserves and other allowances for loan losses reflected in HBI’s financial statements included in the HBI Reports as of and for the year ended December 31, 2020 and for the three months ended March 31, 2021; (4) HBI shall promptly notify FNB if HBI or any HBI Subsidiary has been notified by any state or federal bank Regulatory Agency that its reserves are inadequate or that its practices for establishing its reserves or in accounting for delinquent and classified assets generally fail to comply with applicable accounting or regulatory requirements, or that any Regulatory Agency having jurisdiction over HBI or any HBI Subsidiary or HBI’s independent auditor believes such reserves to be inadequate or inconsistent with the historical loss experience of HBI; and (5) HBI shall prepare and furnish to FNB at least quarterly an updated list of all extensions of credit and OREO that have been classified by HBI or any HBI Subsidiary as other loans specifically mentioned, special mention, substandard, doubtful, loss, classified or criticized, credit risk assets, concerned loans or words of similar import;
(ii) upon request of FNB, HBI shall furnish to FNB such information to which HBI has access or prepares in the ordinary course of business as FNB may reasonably request regarding any loans, loan relationships and commitments of HBI Bank entered into between June 10, 2021, and the date hereof; and
(iii) upon request of FNB, HBI shall furnish to FNB such information to which HBI has access or prepares in the ordinary course of business as FNB may reasonably request regarding any loans, loan relationships and commitments of HBI Bank entered into after the date hereof in which the amount involved is equal to or greater than (i) $10,000,000 on a secured basis and (ii) $2,500,000 on an unsecured or undersecured basis.
Withdrawals during Concession Period 27.3.1 The Concessionaire shall, at the time of opening the Escrow Account, give irrevocable instructions, by way of an Escrow Agreement, to the Escrow Bank instructing, inter alia, that deposits in the Escrow Account shall be appropriated in the following order every month, or at shorter intervals as necessary, and if not due in a month then appropriated proportionately in such month and retained in the Escrow Account and paid out therefrom in the month when due:
(a) all taxes due and payable by the Concessionaire for and in respect of the Project;
(b) all payments relating to construction of the Project, subject to and in accordance with the conditions, if any, set forth in the Financing Agreements;
(c) O&M Expenses, subject to the ceiling, if any, set forth in the Financing Agreements;
(d) O&M Expenses and other costs and expenses incurred by the Authority in accordance with the provisions of this Agreement, and certified by the Authority as due and payable to it;
(e) Concession Fee or Annual Concession Fee, as the case may be, due and payable to the Authority;
(f) monthly proportionate provision of Debt Service due in an Accounting Year;
(g) all payments and Damages certified by the Authority as due and payable to it by the Concessionaire;
(h) monthly proportionate provision of debt service payments due in an Accounting Year in respect of Subordinated Debt;
(i) any reserve requirements set forth in the Financing Agreements; and
(j) balance, if any, in accordance with the instructions of the Concessionaire.
27.3.2 The Concessionaire shall not in any manner modify the order of payment specified in Clause 27.3.1, except with the prior written approval of the Authority.
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Allocations During the Revolving Period During the Revolving Period, the Servicer shall, prior to the close of business on the day any Collections are deposited in the Collection Account, allocate to the Investor Certificateholders or the Holder of the Seller Interest and pay or deposit from the Collection Account the following amounts as set forth below: (i) Allocate to the Investor Certificateholders the product of (y) the Investor Percentage on the Date of Processing of such Collections and (z) the aggregate amount of Collections of Finance Charge Receivables on such Date of Processing, and of that allocation, deposit in the Finance Charge Account an amount equal to either (I) (A) prior to the date on which the amount of Monthly Interest with respect to the related Interest Period is determined by the Servicer, an amount equal to the product of (1) the Investor Percentage on the Date of Processing of such Collections and (2) the aggregate amount of Collections of Finance Charge Receivables on such Date of Processing, and (B) at all other times, the difference between (1) the Monthly Interest with respect to the immediately following Transfer Date (plus, if the Seller is not the Servicer, the Certificateholder Servicing Fee for such Transfer Date plus the amount of any Certificateholder Servicing Fee due but not paid to the Servicer on any prior Transfer Date) and (2) the amounts previously deposited in the Finance Charge Account with respect to the current Monthly Period pursuant to this subsection 4.05(a)(i) or (II) the amount of Collections of Finance Charge Receivables allocated to the Investor Certificateholders on such Date of Processing pursuant to this subsection 4.05(a)(i); provided, that if a deposit pursuant to subsection 4.05(a)(i)(I) is made on any Date of Processing, on the related Transfer Date, the Servicer shall withdraw from the Collection Account and deposit into the Finance Charge Account an amount equal to the amount of Collections of Finance Charge Receivables that have been allocated to the Investor Certificateholders during the related Monthly Period but not previously deposited in the Finance Charge Account. Funds deposited into the Finance Charge Account pursuant to this subsection 4.05(a)(i) shall be applied in accordance with Section 4.09. (ii) Deposit into the Principal Account an amount equal to the product of (A) the Collateral Allocation on the Date of Processing of such Collections, (B) the Investor Percentage on the Date of Processing of such Collections and (C) the aggregate amount of Collections processed in respect of Principal Receivables on such Date of Processing to be applied first in accordance with Section 4.12 and then in accordance with subsection 4.09(d). (iii) Deposit into the Principal Account an amount equal to the product of (A) the Class B Investor Allocation on the Date of Processing of such Collections, (B) the Investor Percentage on the Date of Processing of such Collections and (C) the aggregate amount of Collections processed in respect of Principal Receivables on such Date of Processing to be applied first in accordance with Section 4.12 and then in accordance with subsection 4.09(d). (iv) (A) Deposit into the Principal Account an amount equal to the product of (1) the Class A Investor Allocation on the Date of Processing of such Collections, (2) the Investor Percentage on the Date of Processing of such Collections and (3) the aggregate amount of Collections processed in respect of Principal Receivables on such Date of Processing; provided, however, that the amount deposited into the Principal Account pursuant to this subsection 4.05(a)(iv)(A) shall not exceed the Daily Principal Shortfall, and (B) pay to the Holder of the Seller Interest an amount equal to the excess, if any, identified in the proviso to clause (A) above; provided, however, that the amount to be paid to the Holder of the Seller Interest pursuant to this subsection 4.05(a)(iv)(B) with respect to any Date of Processing shall be paid to the Holder of the Seller Interest if, and only to the extent that, the Seller Interest on such Date of Processing is equal to or greater than the Minimum Seller Interest (after giving effect to the inclusion in the Trust of all Receivables created on or prior to such Date of Processing and the application of payments referred to in subsection 4.03(b)) and otherwise shall be considered as Unallocated Principal Collections and deposited into the Principal Account in accordance with subsection 4.05(e). (b)
