Consequences of Employer's Risks. If and to the extent that any of the risks listed in sub-clause 17.3 above results in loss or damage to the Works, Goods or Contractor's Documents, the Contractor shall promptly give notice to the Engineer and shall rectify this loss or damage to the extent required by the Engineer. If the Contractor suffers delay and/or incurs Cost from rectifying this loss or damage, the Contractor shall give a further notice to the Engineer and shall be entitled subject to clause 20 [Claims and Disputes] to:
Appears in 10 contracts
Samples: Contract Agreement, STS Crane, Contract Agreement
Consequences of Employer's Risks. If and to the extent that any of the risks listed in sub-clause 17.3 above results in loss or damage to the Works, Goods or Contractor's Documents, the Contractor shall promptly give notice to the Engineer and shall rectify this loss or damage to the extent required by the Engineer. If the Contractor suffers delay and/or incurs Cost from rectifying this loss or damage, the Contractor shall give a further notice to the Engineer and shall be entitled subject to clause 20 [Claims Claims, Disputes and DisputesArbitration] to:
Appears in 2 contracts
Samples: STS Crane, www.dctgdansk.pl
Consequences of Employer's Risks. If and to the extent that any of the risks listed in subSub-clause Clause 17.3 above results in loss or damage to the Works, Goods or Contractor's Documents, the Contractor shall promptly give notice to the Engineer and shall rectify this loss or damage to the extent required by the Engineer. If the Contractor suffers delay and/or incurs Cost from rectifying this loss or damage, the Contractor shall give a further notice to the Engineer and shall be entitled subject to clause 20 Sub-Clause 20.1 [Claims and DisputesContractor’s Claims] to:
Appears in 1 contract
Samples: Contract Agreement
Consequences of Employer's Risks. If and to the extent that any of the risks listed in subSub-clause Clause 17.3 above results in loss or damage to the Works, Goods or Contractor's ’s Documents, the Contractor shall promptly give notice to the Engineer and shall rectify this loss or damage to the extent required by the Engineer. If the Contractor suffers delay and/or incurs Cost from rectifying this loss or damage, the Contractor shall give a further notice to the Engineer and shall be entitled subject to clause 20 Sub-Clause 20.1 [Claims and DisputesContractor’s Claims] to:
Appears in 1 contract