Construction Industry Advancement Program Sample Clauses

Construction Industry Advancement Program. One (1) check to the Glens Falls National Bank for payment of contributions to: (1) Glens Falls Painters Pension Fund One (1) check payable to the IUPAT Industry Pension Fund for payment of contributions to: (1) The International Union of Painters and Allied Trades Industry Pension Fund (for Pension and Annuity Plans); One (1) check payable to the Painting Industry Insurance Fund for payment of contributions to: (1) Painting Industry Insurance Fund; (2) District Council No. 9 Finishing Trades Institute of New York and International Union of Painters Allied Trades Finishing Trades Institute; (3) IUPAT Labor Management Cooperation Initiative; (4) IUPAT Political Action Together; (5) Dues Check off; (6) Construction Industry Advancement Program.
Sample 1Sample 2
AutoNDA by SimpleDocs
Construction Industry Advancement Program. Each Employer signatory to this agreement agrees to pay into the Construction Industry Advancement Program Trust Fund (CIAP) $.10 for each hour worked by all employees covered by this Agreement an amount as specified in Article XVII of the Wage Schedule in this Agreement. Each Employer signatory to this Agreement shall pay to the Construction Industry Advancement Program Trust Fund (CIAP) cents per hour as shown on the Remittance report for each hour worked by the Employer to their employees within the bargaining unit. Payment shall be made with such instructions and on such forms as are furnished by the Trustees. Delinquent contributions shall be subject to such penalties or assessments as the Trustees may prescribe from time to time. It is agreed by the Employer that the Construction Industry Advancement Program Trust Fund shall not be used for lobbying in support of anti-labor legislation of any kind at municipal, state or national levels or to subsidize any Contractor or Contractor Association in connection with any work stoppage or strike, nor shall it be used to support any anti-union activity. The Trustees of said program shall comply with all present and future Federal Laws Governing the same. The Union shall have no participation or control of any kind or degree whatever, nor shall the Union be connected in any way whatever with the Construction Industry Advancement Program. Payments shall be mailed directly to: AGC/Painters CIAP 0000 X. Xxxxx, PO Box 27005 Lansing, MI 48906
Sample 1
Construction Industry Advancement Program. Each Employer covered by this Agreement shall pay to the Construction Industry Advancement Program (CIAP) an amount as stated in Article III – Wage Rates & Classifications, per hour for each hour paid by the Employer to his Employees pursuant to this Collective Bargaining Agreement. Payment shall be made with such instructions and on such forms as are furnished by the Program. Delinquent contributions shall be subject to such penalties or assessments as the Program may prescribe from time to time. It is agreed by the Employer that the Construction Industry Advancement Program shall not be used for lobbying in support of anti-labor legislation of any kind at municipal, state, or national levels, or to subsidize any Contractor or Contractor Association in connection with any work stoppage or strike, nor shall it be used to support any anti- Union activity. The Program shall comply with all present and future federal laws governing the same. The Union shall have no participation or control of any kind or degree whatever, nor shall the Union be connected in any way with the Construction Industry Advancement Program. Construction Industry Advancement amounts may be changed by the Association and Employers at their discretion on any anniversary date of the Agreement.
Sample 1
Construction Industry Advancement Program. ZONE 2 (1) Painting Industry Annuity Fund; (2) Painting Industry Insurance Fund; (3) District Council No. 9 Finishing Trades Institute of New York and International Union of Painters Allied Trades Finishing Trades Institute; (4) IUPAT Labor Management Cooperation Initiative; (5) IUPAT Political Action Together; (6) Dues Check-off;
Sample 1
Construction Industry Advancement Program. Each Employer covered by this Agreement shall pay to the Construction Industry Advancement Program (CIAP) an amount as stated in Article II – Wages and Fringe Benefits, per hour for each hour paid by the Employer to his Employees pursuant to this Collective Bargaining Agreement. Payment shall be made with such instructions and on such forms as are furnished by the Program. Delinquent contributions shall be subject to such penalties or assessments as the Program may prescribe from time to time. It is agreed by the Employer that the Construction Industry Advancement Program shall not be used for lobbying in support of anti-labor legislation of any kind at municipal, state, or national levels, or to subsidize any Contractor or Contractor Association in connection with any work stoppage or strike, nor shall it be used to support any anti-Union activity. The Program shall comply with all present and future federal laws governing the same. The Union shall have no participation or control of any kind or degree whatever, nor shall the Union be connected in any way with the Construction Industry Advancement Program. Construction Industry Advancement amounts may be changed by the Association and Employers at their discretion on any anniversary date of the Agreement.
Sample 1
Construction Industry Advancement Program. The Employer shall contribute to the Construction In- dustry Advancement Fund as required by the schedule of contributions at Article 18 hereof. These contribu- tions shall be paid to the Administrator at the same time and together with other contributions made by the Employer for said benefit funds. The Administra- tor shall receive and deposit the Construction Industry Advancement Program monies in a separate account, and, on a monthly basis, after deducting a reasonable amount to defray administration costs, pay the balance to the Construction Industry Advancement Program, heretofore established and administered by Trustees appointed by the several multi-employer Associations. These monies shall be utilized by said Trustees solely for the advancement, improvement and betterment of the industry covered by this Agreement so as to improve conditions and increase opportunity for em- ployment. It is agreed and understood that the Program will not be used for any anti-union purposes, that the Trustees of 472-172 Funds shall receive minutes of all Construction Industry Advancement Program Meetings and that the collection of contributions is conditioned at all times upon approval of the Trustees of 472-172 Funds established under Article 33 and 34 herein. The said Trustees shall be permitted to attend Con- struction Industry Advancement Program meetings as nonvoting observers. The collection of contributions is conditioned upon these understandings. E.R.I.S.A.
Sample 1
Construction Industry Advancement Program. Each Employer covered by this Agreement shall pay to the Construction Industry Advancement Program as stated in Article XIII, Wage and Fringe Benefits, the cents per hour for each hour paid by the Employer to his employees pursuant to this Collective Bargaining Agreement. Payments shall be made with such instructions and on such forms as are furnished by the program. Delinquent contributions shall be subject to such penalties or assessments as the Program may prescribe from time to time. It is agreed by the Employer that the Construction Industry Advancement Program Trust Fund shall not be used for lobbying in support of anti-labor legislation of any kind at municipal, state or national levels or to subsidize any Contractor or Contractor Association in connection with any work stoppage or strike, nor shall it be used to support any anti-Union activity. The Program shall comply with all present and future Federal Laws governing the same. The Union shall have no participation or control of any kind or degree whatsoever, nor shall the Union be connected in any way with the Construction Industry Advancement Program.
Sample 1
AutoNDA by SimpleDocs
Construction Industry Advancement Program. Each Employer covered by this Agreement, including non-AGC members, shall pay to the Construction Industry Advancement Program (CIAP) an amount as stated in Article VII – Wages and Fringe Benefits, per hour for each hour paid by the Employer to his Employees pursuant to this Collective Bargaining Agreement. Construction Industry Advancement amounts may be changed by the Association and Employers at their discretion on any anniversary date of the Agreement. Payment shall be made with such instructions and on such forms as are furnished by the Program. Delinquent contributions shall be subject to such penalties or assessments as the Program may prescribe from time to time.
Sample 1
Construction Industry Advancement Program. The Employer and the Union agree to and approve the establishment of a Construction Industry Advancement Program to promote the common good of the construction industry by providing financial support for activities which may include, but not necessarily be restricted to: 1 promotion of safety 2 market development 3 protection of legitimate markets 4 public relations 5 industry relations 6 collection and distribution of information from and to all segments of the construction industry and related groups or authorities 7 to promote, encourage and advocate needed and helpful legislation for our industry, for the general good of all 8 education and training 9 research into new methods and materials
Sample 1

Related to Construction Industry Advancement Program

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board of Education agrees to pay the actual tuition costs of courses taken by a teacher at accredited colleges or universities up to three courses per two (2) year fiscal periods from July 1, 2006 to June 30, 2008 and July 1, 2008 to June 30, 2010 respectively, except as follows: 1. No teacher may be reimbursed for courses taken during the first year of teaching in Vineland. 2. Teachers taking courses in the second and third years of employment in Vineland will not receive remuneration until tenure has been secured. The remuneration will then be retroactive and will be paid to the teacher in a lump sum within sixty (60) days after the teacher has secured tenure. 3. All courses must be pre-approved by the Superintendent or his designee subject to the following requirements: (a) A teacher must provide official documentation that he/she has obtained a grade of B or better; (b) Reimbursement shall be paid only for courses directly related to teacher’s teaching field which increase the teacher’s content knowledge and are related to the teacher’s current certification, as determined by the Superintendent or his/her designee in his/her sole discretion; no reimbursement shall be paid for courses leading to a post graduate or professional degree in a field other than education or teaching. Further, effective September 1, 2010, all newly hired teachers shall not be eligible for reimbursement until they are tenured, and they shall not be eligible for retroactive reimbursement upon gaining tenure for courses taken prior to being tenured. (c) The maximum total payments to be made by the Board shall not exceed $130,000.00. Courses shall be applied for no earlier than the following dates: Summer Session - April 1 Fall/Winter Session - June 1 Spring Session - October 1 Courses must, as set forth hereinabove in this sub-article 18.A.3, be pre-approved by the Superintendent or his designee, prior to the teacher commencing the course(s); and (d) Teacher taking courses shall sign a contract requiring them to reimburse the Board for all tuition paid for a course if the teacher shall voluntarily leave the employ of the Board within one (1) full school/academic year of completion of said course, except that reimbursement shall not be required when the teacher shall voluntarily leave the employ of the Board due to a significant, documented life change. 4. Tuition reimbursement costs shall be a sum not to exceed the actual cost of college credits charged in an accredited public State college/University of the State of New Jersey. B. When the Superintendent initiates in-service training courses, workshops, conferences and programs designed to improve the quality of instruction, the cooperation of the Vineland Education Association will be solicited. Notwithstanding the above, the initiation of in-service training courses, workshops, conferences and programs shall be determined solely at the discretion of the Board. C. One professional leave day may be granted to a teacher upon request, according to the following guidelines: 1. The professional day may be for attendance at a workshop, seminar or visit to another school for the expressed purpose of self professional improvement for the job. 2. The request shall arrive in the office of the Superintendent of Schools at least ten (10) working days prior to the date requested and shall be reviewed by the immediate supervisor prior to submission. The Board reserves the right to deny a professional leave day before or immediately following a holiday or on a day which by its nature suggests a hardship for providing a substitute. 3. No more than two teachers from any one elementary school or from any one department in the secondary schools may be granted a professional leave for a given day. 4. The teacher may be required to submit a report to the Superintendent of Schools, Assistant Superintendent, supervisor (s), principal and staff regarding the activity of the professional day. 5. Costs incurred by the teacher for the professional day authorized under this Section shall be the teacher’s responsibility. 6. A maximum of 90 professional leave days may be authorized for the school year which shall be apportioned as follows: elementary, 35; grades seven and eight, 20; and high school, 35. D. If the Board initiates a teacher’s attendance at a professional workshop, seminar or visit, the expenses shall be the responsibility of the Board. Further, this day shall not be subtracted from the 90 professional leave days granted to teachers of the Association. E. The Board agrees to pay the full cost of courses taken by secretaries related to skills and knowledge improvement when such courses are required and approved by the Board. F. The Board and the Association agree that it is important to communicate when developing and implementing current and future learning technologies, including but not limited to distance and on-line learning.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law. 3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5

  • Statewide HUB Program Statewide Procurement Division Note: In order for State agencies and institutions of higher education (universities) to be credited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identified above. Agencies, universities and prime contractors are encouraged to verify the company’s HUB certification prior to issuing a notice of award by accessing the Internet (xxxxx://xxxxx.xxx.xxxxx.xx.xx/tpasscmblsearch/index.jsp) or by contacting

  • DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!