Construction of Tenant Work by Tenants Agents Sample Clauses
Construction of Tenant Work by Tenants Agents
Construction of Tenant Improvements Tenant shall install the Tenant Improvements (as described in Paragraph 2(a) below) in accordance with the terms and conditions of this Work Letter. The quantities, character and manner of installation of all of the work related to the Tenant Improvements shall be subject to the limitations imposed by any applicable governmental regulations, laws, ordinances, codes and rules. Notwithstanding the foregoing, Landlord may at Landlord’s sole election itself (with Landlord’s contractor) construct the portion of the Tenant Improvements that consist of the restrooms and related improvements that will service Building 2 (the “Restroom Improvements”), at Tenant’s cost up to a maximum amount of $322,764 (subject to Section 9(b) below), provided that (a) Landlord notifies Tenant in writing of such election prior to Tenant’s commencement of construction of the Tenant Improvements, and (b) Landlord shall use commercially reasonable efforts to not unreasonably interfere with or delay Tenant’s installation of the Tenant Improvements. If a certificate of occupancy or equivalent permit sign-off for the Premises is delayed beyond the Building 2 Scheduled Commencement Date solely as a result of Landlord’s failure to substantially complete the Restroom Improvements prior to such date, which failure does not result from Tenant Delays (as defined below) or Force Majeure, then the Building 2 Commencement Date shall be extended day for day by the number of days after the Building 2 Scheduled Commencement Date until the issuance of a certificate of occupancy or equivalent permit sign-off (but in no event shall the Building 2 Commencement Date be delayed beyond the date Tenant commences business in the Premises), provided, however, that Tenant delivers written notice to Landlord at such time as Tenant becomes aware that Landlord is in danger of causing such delay. “Tenant Delays” shall mean (i) Tenant’s delay in submittal of Tenant’s Plans and/or responses to Landlord’s comments to Tenant’s Plans beyond the time periods provided in this Work Letter, (ii) Tenant’s delay in any submittals for permits or other governmental approvals with respect to the Tenant Improvements (including without limitation the Restroom Improvements), (iii) changes in Tenant’s Plans as they relate to the Restroom Improvements after they have been submitted to governmental authorities for permits, (iv) delay in obtaining materials for reasons outside Landlord’s reasonable control, and (v) Tenant’s failure to provide reasonable access to the Premises to Landlord’s contractors to install the Restroom Improvements, or unreasonable interference with such installation by Tenant or its contractors or agents.
Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans. (a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant. (b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent. (a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business. (b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans. (a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease. (b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding. 3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant. 3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Alterations by Tenant Tenant shall not make any alterations, additions, or improvements to the Premises without the written consent of Landlord. The kinds of alterations, additions or improvements referred to are those, which are of a more or less permanent nature, such as new floors, partitions, wallpaper and paneling. If consent of Landlord is given, then any or all such alterations, additions or improvements, may, if Landlord wishes, become the property of Landlord at the end of the term of the Lease. However, if Landlord wishes, Landlord may require Tenant to remove any or all of such alterations, additions or improvements at the end of the term of the Lease and restore the Premises to the condition it was in when the term of this Lease began fair wear and tear excepted. If initialed by Landlord here , Tenant has Landlord’s express written permission to paint the walls of the interior of the premises. However, Tenant shall be required to return the walls to their original condition by painting the walls to the same color as at the start of the Lease by the last day of the Lease Term. If Tenant does not repaint the walls to the same color as at the start of the Lease upon vacating the premises, Tenant shall be liable for Landlord’s expenses reasonably incurred for repainting the walls the same color as at the start of the Lease, which includes at Landlord’s option, hiring painters to paint the walls, along with the cost of any paint and paint supplies reasonable and necessary. If Landlord and Tenant initial here: (Landlord) (Tenant), then Landlord and Tenant intend and agree there is an Addendum (“Addendum”) attached and incorporated into this Lease outlining customization options or restrictions in greater detail, and both Landlord and Tenant agree to be bound to the terms and conditions contained in the Addendum as additional Terms of this Lease Agreement.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Tenant’s Alterations Tenant shall not make any Alterations, including, without limitation, Tenant’s installation and construction of the Premises to prepare the Premises for Tenant’s occupancy as well as fixturing, cabling and computer installations in connection therewith (collectively, “Tenant’s initial Installations”). without Landlord’s prior written consent in each instance; provided, however, that Tenant may make the following Alterations to the Premises without Landlord’s prior written consent (collectively, “Permitted Alterations”), (x) decorations consisting of furniture, painting, wall coverings and floor coverings in the Premises subject to the terms and conditions of the Lease (“Decorative Alterations”), and (y) other Alterations that satisfy the Alterations Criteria (as hereinafter defined), and which (together with any other Alterations performed by Tenant during the calendar year in which such other Alterations were performed) cost, in the aggregate, less than $30,000.00; provided, further, that Tenant shall provide Landlord with at least ten (10) (Business Days’ prior written notice prior to making any Permitted Alterations, which notice shall include (except in the case of Decorative Alterations) a set of plans and specifications for such Permitted Alterations, as described in Section 4.2(a) below. Landlord’s consent to Tenant’s Alterations shall be granted or denied in Landlord’s sole discretion; provided, however, that Landlord shall not unreasonably withhold or delay its consent to Tenant’s Initial Alterations to adapt the Premises for the Permitted Use provided that such Alterations (i) are non-structural and do not affect the Building Systems or services, or violate the design or engineering standards or criteria of Landlord for the Building, (ii) are performed only by contractors or mechanics approved in writing by Landlord, (iii) affect only the Premises and are not visible from outside of the Premises, (iv) do not adversely affect any service furnished by Landlord to Tenant or to any other tenant of the Building or the 000 Xxxxx Xxxxxxxx, (v) do not reduce the value or utility of the Building or the 000 Xxxxx Xxxxxxxx, (vi) do not violate any Legal Requirements or the Building Rules and Regulations, or cause the Premises or the Building or the 000 Xxxxx Xxxxxxxx to be non-compliant with any Legal Requirements, (vii) do not adversely affect any Common Areas or other tenant of the Building or the 900 North Building, or the premises of any such other tenant, and (viii) do not conflict with or violate any rules and regulations of Landlord’s insurance carrier (collectively, the “Alterations Criteria”). Tenant shall provide Landlord with a final complete set of Tenant’s Plans (defined below) for Tenant’s Initial Alterations, which Tenant shall cause to be prepared at Tenant’s sole cost and expense, within forty-five (45) days after the Effective Date. Landlord shall notify Tenant within five (5) Business Days after Tenant’s delivery of Tenant’s Plans, (i) whether Landlord consents or withholds its consent thereto, and (ii) if Landlord withholds its consent, the reason or reasons therefor. If Landlord fails to notify Tenant of its consent or withholding of consent within such five (5) Business Day period, and (x) Landlord further fails to notify Tenant of its consent or withholding of consent within five (5) Business Days after delivery (or attempted delivery) of a second written request by Tenant to Landlord, (y) Tenant has evidence that Landlord received or refused delivery of such second notice (in the form of a return receipt or proof of refusal of delivery), and (z) such second notice stated on its face that refusal to timely respond constitutes a “deemed consent”, then Landlord shall be deemed to have consented to Tenant’s Plans as submitted. If Landlord’s approval of a contractor is required, Landlord shall notify Tenant within five (5) Business Days after Tenant’s written request whether Landlord consents or withholds its consent to any contractor proposed by Tenant to perform Tenant’s Initial Alterations. If Landlord fails to notify Tenant of its consent or withholding of consent within such five (5) Business Day period, and Tenant has evidence that Landlord received the notice requesting such consent (in the form of a return receipt or proof of refusal of delivery), then Landlord shall be deemed to have consented to the contractor proposed by Tenant to perform such Tenant’s Alteration.
Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.