Construction of the Permanent Facilities
Construction of the Permanent Facilities Sample Clauses
Related to Construction of the Permanent Facilities
Construction of the Project The Corporation hereby represents that it has caused the Project to be completed and acknowledges that it shall not be entitled to any reimbursement for the cost of construction of the Project from the Authority, the Trustee or the Holders of the Bonds, nor shall it be entitled to any diminution or postponement of the payments required to be paid by the Corporation pursuant to this Participation Agreement or the Corporation Obligations. Section 3.04.
Completion of the Project (a) The completion of the Project shall be evidenced to the Trustee by a certificate signed by the Project Supervisor on behalf of the User stating that (1) construction of the Improvements has been completed in accordance with the plans and specifications approved by the User, (2) the Equipment has been acquired and installed in accordance with the User's instructions, (3) all Project Costs have been paid, and (4) all facilities and improvements necessary in connection with the Project have been acquired and installed and all costs and expenses incurred in connection therewith have been paid. Notwithstanding the foregoing, such certificate shall state that it is given without prejudice to any rights against any vendor, contractor, subcontractor or other person not a party to this Lease Agreement which exist at the date of such certificate or which may subsequently come into being. The Issuer and the User will cooperate in causing such certificate to be furnished to the Trustee.
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Access to Facilities Each of the Company and each of its Subsidiaries will permit any representatives designated by the Purchaser (or any successor of the Purchaser), upon reasonable notice and during normal business hours, at such person's expense and accompanied by a representative of the Company, to:
Working Facilities During the Term of Employment, the Company shall furnish the Executive with an office, secretarial help and such other facilities and services suitable to his position and adequate for the performance of his duties hereunder.
Common Facilities “Common Facilities” includes all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Property, and their employees, agents, customers and other invitees, including without limitation building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Property, comfort and first-aid stations, parcel pick-up stations and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord shall have the right, without liability to Tenant, to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time, and Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to enforce parking charges (by operation of meters or otherwise), with appropriate provisions for free parking ticket validating by tenants; to close all or any portion of the Common Facilities to such extent as may, in the opinion of Landlord’s counsel, be legally sufficient to prevent a dedication thereof or the accrual of any rights to any person or the public therein; to close temporarily all or any portion of the Common Facilities; to discourage non-customer parking; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, Tenant may use all Common Facilities not within the Premises, under a revocable license, on a nonexclusive basis in common with other tenants. If any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
