Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Construction of Improvements Lessee shall construct its planned facilities and install therein all necessary fixtures, equipment, and accessories, all of which shall be in accordance with the terms and conditions of this Lease and any applicable city code or FAA requirements. Lessee shall complete construction of the new improvements within one (1) year after the Effective Date of this Lease. Existing improvements shall be deemed to have been appropriately constructed so long as they are well-maintained and meet all applicable city code and FAA requirements. It is expressly understood that upon the expiration of the Lease, all hangar improvements shall become property of Lessor. 8.1 Lessee agrees to reimburse Lessor for the apportioned costs of roadway improvements including, but not limited to: excavation, paving, drainage, and fencing required for all extensions of the access road to the Leased Premises. Lessee shall be responsible for the cost of all extensions, as applicable, of all water, sewer, and other utilities to the Leased Premises, as well as any fees for obtaining service. Lessee shall be responsible for payment at the time improvements are completed. Lessee shall remit payment to Lessor within thirty (30) days from the date of invoice. 8.2 Lessee agrees to construct, at Lessee’s expense, aircraft access improvements, including without limitation driveways, taxi lanes, aprons, and ramps to its planned facility. Construction and location of the access improvements shall comply with specifications set forth by Lessor at the time of plan’s approval. Lessee understands that those portions of the constructed Airport access improvements situated outside the boundaries of the Leased Premises shall become, immediately upon their completion to Lessor’s satisfaction, the property of Lessor. All construction and any connections to the runway of any apron or taxi lane shall in addition be governed by any rules or regulations regarding Airport operations and must be approved of and overseen by Airport management. Constructed facilities shall not be occupied until access is completed and accepted by Lessor. 8.3 Upon completion of improvements, Lessee shall provide an 8 ½” x 11” site plan detailing a scaled drawing of the Leased Premises, hangar foot print, office area, parking, landscaping, and any other improvements. 8.4 The provisions provided above do not relieve Lessee from compliance with all applicable building code requirements and acquiring all necessary licenses and permits from any governmental authority. 8.5 If the aircraft hangar or other improvements on the Leased Premises are damaged or destroyed, Lessee shall do whatever is necessary to repair, rebuild, or restore the structure and other improvements to substantially the same condition existing prior to the damage or destruction within 180 days of the date of destruction. Upon written request from Lessee, Lessor may extend the 180-day timeline to the extent reasonably necessary due to conditions beyond the control of Lessee.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
xxx/Xxxxxx/XXXXX- 19_School_Manual_FINAL pdf -page 101-102 We will continue to use the guidelines reflected in the COVID-19 school manual.
