Contract Interpretation The Contract Documents completely describe the Services to be provided. Contractor will provide any Services that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result whether or not specifically called for or identified in the Contract Documents. Words or phrases which have a well-known technical or construction industry or trade meaning and are used to describe Services will be interpreted in accordance with that meaning unless a definition has been provided in the Contract Documents.
Interpretation of Contract Documents The Contract Documents shall be construed neither against nor in favor of either party, but shall be construed in a neutral manner.
Interpretation of Contract In the event of a conflict or question involving the provisions of any part of this Contract, interpretation and clarification as necessary shall be determined by the County’s assigned buyer. If disagreement exists between the Contractor and the County’s assigned buyer in interpreting the provision(s), final interpretation and clarification shall be determined by the County’s Purchasing Agent or his designee.
Construction; Governing Law The headings used in this Agreement are for convenience only and shall not be deemed to constitute a part hereof. Whenever the context requires, words denoting singular shall be read to include the plural. This Agreement and the rights and obligations of the parties hereunder, shall be construed and interpreted in accordance with the laws of the State of Kansas, except to the extent that the laws of the State of Maryland apply with respect to share transactions.
Interpretation of Agreement It is understood that the parties hereto intend this Agreement to be interpreted and enforced so as to provide indemnification to Indemnitee to the fullest extent now or hereafter permitted by law.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Construction; Interpretation The headings herein are for convenience only, do not constitute a part of this Agreement and shall not be deemed to limit or affect any of the provisions hereof. The language used in this Agreement will be deemed to be the language chosen by the parties to express their mutual intent, and no rules of strict construction will be applied against any party. This Agreement shall be construed as if drafted jointly by the parties, and no presumption or burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any provisions of this Agreement. Unless otherwise indicated to the contrary herein by the context or use thereof: (i) the words, “herein,” “hereto,” “hereof” and words of similar import refer to this Agreement as a whole, including the Schedules and exhibits, and not to any particular section, subsection, paragraph, subparagraph or clause contained in this Agreement; (ii) masculine gender shall also include the feminine and neutral genders, and vice versa; (iii) words importing the singular shall also include the plural, and vice versa; (iv) the words “include,” “includes” or “including” shall be deemed to be followed by the words “without limitation”; (v) financial terms shall have the meanings given to such terms under GAAP unless otherwise specified herein; (vi) references to “$” or “dollar” or “US$” shall be references to United States dollars; (vii) where the context permits, the use of the term “or” will be non-exclusive and equivalent to the use of the term “and/or”; (viii) the word “extent” in the phrase “to the extent” shall mean the degree to which a subject or other thing extends, and such phrase shall not mean simply “if”; and (ix) if any action under this Agreement is required to be done or taken on a day that is not a Business Day or on which a government office is not open with respect to which a filing must be made, then such action shall be required to be done or taken not on such day but on the first succeeding Business Day thereafter.
Severability; Interpretation If any provision of this Agreement is held invalid by a court decision, statute, rule or otherwise, the remainder of this Agreement shall not be affected thereby. This Agreement shall be binding upon and shall inure to the benefit of the parties hereto and their respective successors. Where the effect of a requirement of the 1940 Act reflected in any provision of this Agreement is altered by a rule, regulation or order of the SEC, whether of special or general application, such provision shall be deemed to incorporate the effect of such rule, regulation or order.
Interpretation; Severability (a) The Executive has carefully considered the possible effects on the Executive of the covenants not to compete, the confidentiality provisions and the other obligations contained in this Agreement, and the Executive recognizes that the Company has made every effort to limit the restrictions placed upon the Executive to those that are reasonable and necessary to protect the Company’s legitimate business interests. (b) The Executive acknowledges and agrees that the restrictive covenants set forth in this Agreement are reasonable and necessary in order to protect the Company’s valid business interests. It is the intention of the parties hereto that the covenants, provisions and agreements contained herein shall be enforceable to the fullest extent allowed by law. If any covenant, provision or agreement contained herein is found by a court having jurisdiction to be unreasonable in duration, scope or character of restrictions, or otherwise to be unenforceable, such covenant, provision or agreement shall not be rendered unenforceable thereby, but rather the duration, scope or character of restrictions of such covenant, provision or agreement shall be deemed reduced or modified with retroactive effect to render such covenant, provision or agreement reasonable or otherwise enforceable (as the case may be), and such covenant, provision or agreement shall be enforced as modified. If the court having jurisdiction will not review the covenant, provision or agreement, the parties hereto shall mutually agree to a revision having an effect as close as permitted by applicable law to the provision declared unenforceable. The parties hereto agree that if a court having jurisdiction determines, despite the express intent of the parties hereto, that any portion of the covenants, provisions or agreements contained herein are not enforceable, the remaining covenants, provisions and agreements herein shall be valid and enforceable. Moreover, to the extent that any provision is declared unenforceable, the Company shall have any and all rights under applicable statutes or common law to enforce its rights with respect to any and all Confidential Information or unfair competition by the Executive.
Construction and Interpretation Should any provision of this Agreement require judicial interpretation, the parties hereto agree that the court interpreting or construing the same shall not apply a presumption that the terms hereof shall be more strictly construed against one party by reason of the rule of construction that a document is to be more strictly construed against the party that itself, or through its agent, prepared the same, and it is expressly agreed and acknowledged that Company and Executive and each of his and its representatives, legal and otherwise, have participated in the preparation hereof.
