CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is September 26, 2016. The completion date for this contract is October 31, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Contract Times A. Time of the Essence
Contract Time The period of time established for completion of the Project by the Contract Documents. Contract Time commences upon the date specified in the Proceed Order and ends upon the Material Completion and Occupancy Date, as it may be amended.
As to Contract Time Should the Design Professional disagree with the Contractor as to the amount of the adjustment to the Contract Time and such disagreement not be resolved between them within seven days, the decision of the Design Professional as to any adjustment in the Contract Time, including any designation by the Design Professional of such time as is eligible for Time Dependent Overhead Costs, shall be final, subject to protest to the Owner of the Design Professional’s decision as set forth in Section 5 Part 2.
Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
For Force Account or Indefinite Amount Change Order The payment and extension of time (if any) provided by this Change Order constitutes interim compensation to the Contractor and its Subcontractors and Suppliers for actual costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
Contract Distribution The Employer will provide all current and new employees with a link to the new Agreement. Each department or unit will maintain a paper copy of the contract accessible to all employees.
Contract Reconciliation Grantee, within 45 calendar days after the end of each fiscal term year, will submit to the System Agency email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx, financial and reconciliation reports required by System Agency in forms as determined by System Agency.
Rollovers of Settlement Payments From Bankrupt Airlines If you are a qualified airline employee who has received a qualified airline settlement payment from a commercial airline carrier under the approval of an order of a federal bankruptcy court, you are allowed to roll over up to 90 percent of the proceeds to your Traditional IRA, within 180 days after receipt of such amount, or by a later date if extended by federal law. If you make such a rollover contribution, you may exclude the amount rolled over from your gross income in the taxable year in which the airline settlement payment was paid to you. If you are a qualified airline employee who has received a qualified airline settlement payment from a commercial airline carrier under the approval of an order of a federal bankruptcy court in a case filed after September 11, 2001, and before January 1, 2007, you are allowed to roll over any portion of the proceeds into your Xxxx XXX within 180 days after receipt of such amount, or by a later date if extended by federal law. For further detailed information and effective dates you may obtain IRS Publication 590-A, Contributions to Individual Retirement Arrangements (IRAs), from the IRS or refer to the IRS website at xxx.xxx.xxx.
Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:
