Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
Contracting Parties The Government customer (Licensee) is the “Ordering Activity”, “defined as an entity authorized to order under GSA contracts as set forth in GSA ORDER 4800.2G ADM, as may be revised from time to time. The Licensee cannot be an individual because any implication of individual licensing triggers the requirements for legal review by Federal Employee unions. Conversely, because of competition rules, the contractor must be defined as a single entity even if the contractor is part of a corporate group. The Government cannot contract with the group, or in the alternative with a set of contracting parties.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Paid Claims without Supporting Documentation Any Paid Claim for which Practitioner cannot produce documentation shall be considered an error and the total reimbursement received by Practitioner for such Paid Claim shall be deemed an Overpayment. Replacement sampling for Paid Claims with missing documentation is not permitted.
Contracting Authors When the Author is more than one person then, unless otherwise indicated in this Agreement or agreed in writing by the Publisher: (a) the expression “Author” as used in this Agreement will apply collectively for all such persons (each a "co-author"); (b) the Corresponding Author hereby warrants and represents that all co-authors of the contribution have expressly agreed that the Corresponding Author has full right, power and authority to sign this Agreement on their behalf, that the Corresponding Author is entitled to act on their behalf, and that they shall be bound by the Corresponding Author, with respect to all matters, responsibilities, notices and communications related to this Agreement; the Corresponding Author shall obtain authorisations and make them available to the Publisher on request; and (c) each co-author is jointly and severally responsible for the Author’s obligations under this Agreement which apply to each co-author individually and to the co-authors collectively and the Publisher shall not be bound by any separate agreement or legal relationship as between the co-authors. Subject of the Agreement The Author will prepare a contribution provisionally entitled: [Title of the Contribution] The expression “Contribution” as used in this Agreement means the contribution as identified above, and includes without limitation all related material delivered to the Publisher by or on behalf of the Author whatever its media and form (including text, graphical elements, tables, videos and/or links) in all versions and editions in whole or in part. The Contribution may contain links (e.g. frames or in-line links) to media enhancements (e.g. additional documents, tables, diagrams, charts, graphics, illustrations, animations, pictures, videos and/or software) or to social or functional enhancements, complementing the Contribution, which are provided on the Author’s own website or on a third party website or repository (e.g. maintained by an institution) subject always to the Author providing to the Editor, at the latest at the delivery date of the manuscript for the Contribution, an accurate description of each media enhancement and its respective website or repository, including its/their owner, nature and the URL. The Publisher is entitled to reject the inclusion of, or suspend, or delete links to all or any individual media enhancements. In the event that an index is deemed necessary, the Author shall assist the Editor in its preparation (e.g. by suggesting index terms), if requested by the Editor.
Where a Contracting Party expropriates the assets of a company which is incorporated or constituted under the law in force in any part of its own territory, and in which investors of the other Contracting Party own shares, it shall ensure that the provisions of this Article are applied so as to guarantee prompt, adequate and effective compensation in respect of their investment to such investors of the other Contracting Party who are owners of those shares.
Contractor Licensing, etc. Notwithstanding Section 14.c, District may terminate this Contract immediately by written notice to Contractor upon denial, suspension, revocation, or non-renewal of any license, permit, or certificate that Contractor must hold to provide services under this Contract.
Where one Contracting Party or its designated agency has guaranteed any indemnity against non-commercial risks in respect of an investment by any of its investors in the territory of the other Contracting Party and has made payment to such investors in respect of their claims under this Agreement, the other Contracting Party agrees that the first Contracting Party or its designated agency is entitled by virtue of subrogation to exercise the rights and assert the claims of those investors. The subrogated rights or claims shall not exceed the original rights or claims of such investors.
Contracting Party Consent Each Contracting Party hereby gives its unconditional consent to the submission of a dispute to international arbitration in accordance with this Part.
Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
