Contractors Responsibilities Indemnities
Contractors Responsibilities Indemnities Sample Clauses
Related to Contractors Responsibilities Indemnities
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance. 1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement. 1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services. 1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. 1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict. 1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.
Supplier’s Responsibilities 14.1 The Supplier shall supply all the Goods and Related Services included in the Scope of Supply in accordance with GCC Clause 12, and the Delivery and Completion Schedule, as per GCC Clause 13.
PROVIDER’S RESPONSIBILITIES A DBE prime may receive credit toward the DBE goal for work performed by his-her own forces and work subcontracted to DBEs. A DBE prime must make a good faith effort to meet the goals. In the event a DBE prime subcontracts to a non-DBE, that information must be reported to the Department. a. A Provider who cannot meet the contract goal, in whole or in part, shall document the “Good Faith Efforts” taken to obtain DBE participation. The following is a list of the types of actions that may be considered as good faith efforts. It is not intended to be a mandatory checklist, nor is it intended to be exclusive or exhaustive. Other factors or types of efforts may be relevant in appropriate cases. (1) Soliciting through all reasonable and available means the interest of all certified DBEs who have the capability to perform the work of the contract. The solicitation must be done within sufficient time to allow the DBEs to respond to it. Appropriate steps must be taken to follow up initial solicitations to determine, with certainty, if the DBEs are interested. (2) Selecting portions of the work to be performed by DBEs in order to increase the likelihood that the DBE goals will be achieved. This includes, where appropriate, breaking out contract work items into economically feasible units to facilitate DBE participation, even when the Provider might otherwise prefer to perform the work items with its own forces. (3) Providing interested DBEs with adequate information about the plans, specifications, and requirements of the contract in a timely manner to assist them in responding to a solicitation. (4) Negotiating in good faith with interested DBEs by making a portion of the work available to DBE subproviders and suppliers and selecting those portions of the work or material needs consistent with the available DBE subproviders and suppliers. (5) The ability or desire of the Provider to perform the work of a contract with its own organization does not relieve the Provider’s responsibility to make a good faith effort. Additional costs involved in finding and using DBEs is not in itself sufficient reason for a Provider’s failure to meet the contract DBE goal, as long as such costs are reasonable. Providers are not, however, required to accept higher quotes from DBEs if the price difference is excessive or unreasonable. (6) Not rejecting DBEs as being unqualified without sound reasons based on a thorough investigation of their capabilities. (7) Making efforts to assist interested DBEs in obtaining bonding, lines of credit, or insurance as required by the recipient or Provider. (8) Making efforts to assist interested DBEs in obtaining necessary equipment, supplies, materials or related assistance or services. (9) Effectively using the services of available minority/women community organizations; minority/women contractors’ groups; local, state, and Federal minority/women business assistance offices; and other organizations as allowed on a case-by-case basis to provide assistance in the recruitment and placement of DBEs. (10) If the Department’s Director of the Business Opportunity Programs Office determines that the Provider has failed to meet the good faith effort requirements, the Provider will be given an opportunity for reconsideration by the Director of the appropriate Division. NOTE: The Provider must not cause or allow subproviders to bid their services. b. The preceding information shall be submitted directly to the Chair of the Consultant Selection Team responsible for the project. c. The Provider shall make all reasonable efforts to honor commitments to DBE subproviders named in the commitment submitted under Section 2.c. of this attachment. Where the Provider terminates or removes a DBE subprovider named in the initial commitment, the Provider must demonstrate on a case-by-case basis to the satisfaction of the department that the originally designated DBE was not able or willing to perform. d. The Provider shall make a good faith effort to replace a DBE subprovider that is unable or unwilling to perform successfully with another DBE, to the extent needed to meet the contract goal. The Provider shall submit a completed Exhibit H-2 Form for the substitute firm(s). Any substitution of DBEs shall be subject to prior written approval by the Department. The Department may request a statement from the firm being replaced concerning its replacement prior to approving the substitution. e. The Provider shall designate a DBE liaison officer who will administer the DBE program and who will be responsible for maintenance of records of efforts and contacts made to subcontract with DBEs. f. Providers are encouraged to investigate the services offered by xxxxx owned and controlled by disadvantaged individuals and to make use of these banks where feasible.
Customer’s Responsibilities 9.1 If and to the extent applicable or under the control of the Customer, Customer shall provide complete and accurate information regarding requirements for the Project and the Site(s), including, without limitation, constraints, space requirements, underground or hidden facilities and structures, and all applicable drawings and specifications. 9.2 Customer shall prepare, file for, and use commercially reasonable efforts to obtain all Required Approvals necessary to perform its obligations under this Agreement. 9.3 Customer shall reasonably cooperate with Company as required to facilitate Company’s performance of the Work.
OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
SELLER’S RESPONSIBILITIES (a) Seller shall act in performance of this Agreement as an independent contractor and not as an agent for Company or the Government in performing this Agreement, maintaining complete control over its employees and all lower-tier subcontractors. Nothing contained in this Agreement or any lower-tier subcontract shall create any contractual relationship between any such lower-tier subcontractor and the Government or Company. Seller is solely responsible for the actions of itself and its lower-tier subcontractors, agents or employees. (b) Seller shall be responsible for all liability and related expenses resulting from (1) injury, death, damage to or loss of property or (2) violation of Part 1.12a Compliance with Laws, which is in any way connected with its performance of work under this Agreement. Seller's responsibility shall apply to activities of Seller, its agents, lower-tier subcontractors, or employees and such responsibility includes the obligation to indemnify, defend, and hold harmless the Government and the Company for Seller's conduct. However, such liability and indemnity does not apply to injury, death, or damage to property to the extent it arises from the negligent or willful misconduct of Company. (c) If Company’s costs are determined to be unallowable, its fee reduced, or it incurs any cost or damages as a result of Seller’s violation of applicable laws, orders, rules, regulations, or ordinances, or the submission of defective cost or pricing data, Company may make an equivalent reduction in amounts due Seller. (d) If Seller is a State agency, such as an Educational Institution, all liabilities and remedies shall be determined in accordance with the laws applicable to this Agreement under Part 1.2.
Vendor Responsibilities Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED IN C-M, O-S, V-W. Indemnification
Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require. (b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price. (c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work. (d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.
