Contractual Considerations Sample Clauses

Contractual Considerations. It is imperative that we manage our rights as well as those of our clients and industry partners as outlined in Prime Contracts and Subcontract Agreements. Should disruption of our work occur, our Contracts likely contain provisions that address unforeseen delay such as “Force Majeure” or “Delays” clauses. Force Majeure is defined as a contract provision excusing a party from performing its contractual obligations when it becomes impossible or impracticable due to an event or effect that the parties could not have anticipated or controlled when the contract was signed. Please ensure all project management staff does a review of all delay provisions outlined in their Contracts and immediately prepare for the appropriate next steps such as formal notice to our Clients. It is critical to provide protection to us as afforded under Contract in a timely and reasonable manner. Please also note that our standard Subcontracts allow for such provisions to our Subcontractors. As such, if we receive a notification from our subs it also needs to trigger the notification noted above as a flow through. As this is not standard operating practice, we encourage anyone with questions to elevate them to your supervisor or management to ensure that we get it right.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Contractual Considerations. The agreement recognises that Transco as Manager has a significant interest in maintaining a high reputation as a safe, reliable and efficient operator above and beyond its liability in law and in respect of the SOMSA.
Sample 1
Contractual Considerations 
Sample 1

Related to Contractual Considerations

  • Special Considerations Special considerations in determining allowability of compensation will be given to any change in a non-Federal entity's compensation policy resulting in a substantial increase in its employees' level of compensation (particularly when the change was concurrent with an increase in the ratio of Federal awards to other activities) or any change in the treatment of allowability of specific types of compensation due to changes in Federal policy.

  • Financial Considerations 5.1 In the event aggregate funding provided to SCDDO from county, state and/or federal sources is reduced or in any way becomes insufficient to fund this Agreement, the obligations of both SCDDO and the CSP must thereupon be: (1) reduced on a pro rata basis, or (2) renegotiated or terminated, provided that any termination of this Agreement must be without prejudice to any obligations or liabilities of the parties accrued prior to the termination.

  • General Considerations a. All reports, drawings, designs, specifications, notebooks, computations, details, and calculation documents prepared by Vendor and presented to the Board pursuant to this Agreement are and remain the property of the Board as instruments of service.

  • FINANCIAL CONSIDERATION A. The College/University and the Facility shall each bear their own costs associated with this Agreement and no payment is required by either the College/University or the Facility to the other party, except that, where applicable, the Facility shall pay the tuition and other educational fees of students it places in the clinical experience program.

  • Additional Considerations For each mediation or arbitration:

  • Ethical Considerations The study will be conducted in accordance with ethical principles founded in the Declaration of Helsinki. The Institutional Review Board (IRB)/Independent Ethics Committee (IEC) will review all appropriate study documentation in order to safeguard the rights, safety and well-being of the subjects. The study can only be conducted at study sites where IRB/IEC approval has been obtained. The protocol, informed consent form, Investigator’s Brochure, advertisements (if applicable), and all other forms of information given to subjects will be provided to the IRB/IEC by the Investigator. In addition, reports on the progress of the study will be submitted to the IRB/IEC by the Investigator at the appropriate intervals.

  • Other Considerations A. Changes to an Approved Scope of Work: The Recipient shall notify FEMA and shall require a sub-recipient to notify it immediately when a sub-recipient proposes changes to an approved scope of work for an Undertaking.

  • Environmental Considerations A. Company, its officers, agents, servants, employees, invitees, independent contractors, successors, and assigns will not discharge or spill any Hazardous Substance, as defined herein, into any component of the storm drainage system or onto any paved or unpaved area within the boundaries of the Premises. In addition, Company will not discharge or spill any Hazardous Substance into any component of the sanitary sewer system without first neutralizing or treating same as required by applicable anti-pollution laws or ordinances, in a manner satisfactory to Authority and other public bodies, federal, state, or local, having jurisdiction over or responsibility for the prevention of pollution of canals, streams, rivers, and other bodies of water. Company’s discharge, spill or introduction of any Hazardous Substance onto the Premises or into any component of Authority’s sanitary or storm drainage systems will, if not remedied by Company with all due dispatch, at the sole discretion of Authority, be deemed a default and cause for termination of this Agreement by Authority, subject to notice and cure. Such termination will not relieve Company of or from liability for such discharge or spill.

  • Additional Consideration Retrocessionaire agrees to pay under the Inuring Retrocessions all future premiums Retrocedant is obligated to pay pursuant to the terms of the Inuring Retrocessions to the extent that such premiums are allocable to Retrocessionaire in the manner set forth in Exhibit E hereto, and not otherwise paid by Retrocessionaire and to indemnify Retrocedant for all such premiums paid directly by Retrocedant, net of any ceding commissions and similar amounts paid by Third Party Retrocessionaires to Retrocedant.

  • Settlement Consideration 2. In consideration of the full settlement, satisfaction, compromise and release of the Released Plaintiffs’ Claims, an aggregate $115 million in cash (the “Escrow Amount”) shall be paid on behalf of the Settling Defendants to Freeport by the D&O Carriers. The Settling Defendants shall cause the Escrow Amount to be deposited by the D&O Carriers into an interest-bearing escrow account controlled by an agreed upon representative of Plaintiffs and of the Settling Defendants (the “Escrow Account”) within fifteen (15) business days after the Stipulation is submitted to the Court. Upon the Effective Date, the Escrow Amount, together with any and all interest thereon, shall be paid to Freeport from the Escrow Account. For the avoidance of doubt, the Settling Defendants shall have no obligation to deposit any portion of the Escrow Amount into the Escrow Account but shall have an obligation to take all reasonably available steps to seek to cause the D&O Carriers to deposit the Escrow Amount into the Escrow Account.

Time is Money Join Law Insider Premium to draft better contracts faster.