Controllable Fleet Launch. “Controllable Fleet Launch Percentage” is defined as the percentage of the Aircraft fleet departing from the gate within [*] minutes of the scheduled departure time on its first flight of the day, excluding [*].
Controllable Fleet Launch Sample Clauses
Related to Controllable Fleet Launch
Operating Costs Tenant shall pay to Landlord the Tenant’s Percentage of Operating Costs (as hereinafter defined) incurred by Landlord in any calendar year. Tenant shall remit to Landlord, on the first day of each calendar month, estimated payments on account of Operating Costs, such monthly amounts to be sufficient to provide Landlord, by the end of the calendar year, a sum equal to the Operating Costs, as reasonably estimated by Landlord from time to time. The initial monthly estimated payments shall be in an amount equal to 1/12th of the Initial Estimate of Tenant’s Percentage of Operating Costs for the Calendar Year. If, at the expiration of the year in respect of which monthly installments of Operating Costs shall have been made as aforesaid, the total of such monthly remittances is greater than the actual Operating Costs for such year, Landlord shall promptly pay to Tenant, or credit against the next accruing payments to be made by Tenant pursuant to this subsection 4.2.3, the difference; if the total of such remittances is less than the Operating Costs for such year, Tenant shall pay the difference to Landlord within twenty (20) days from the date Landlord shall furnish to Tenant an itemized statement of the Operating Costs, prepared, allocated and computed in accordance with generally accepted accounting principles. Any reimbursement for Operating Costs due and payable by Tenant with respect to periods of less than twelve (12) months shall be equitably prorated.
Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.
Construction Period The term “Construction Period” shall mean the period from the date of this Lease to the date that Landlord completes construction of the Landlord’s Work (including any “Additional Base Building Items”, as defined in Section 3(f) of the Tenant Work Letter), and Common Areas, regardless of the occurrence of any Tenant Delay and without regard to the effect of any provision of this Lease pursuant to which the Premises are deemed to be Ready for Occupancy in advance of its actual occurrence. Notwithstanding any provision of this Lease to the contrary (including Exhibit B), during the Construction Period only, the following provisions shall be applicable:
Limit on Operating Expenses The Advisor hereby agrees to limit the Fund’s current Operating Expenses to an annual rate, expressed as a percentage of the Fund’s average daily net assets for the month, to the amounts listed in Appendix A (the “Annual Limit”). In the event that the current Operating Expenses of the Fund, as accrued each month, exceed its Annual Limit, the Advisor will pay to the Fund, on a monthly basis, the excess expense within the first ten days of the month following the month in which such Operating Expenses were incurred (each payment, a “Fund Reimbursement Payment”).
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Scheduled Maintenance No later than March 1, 2001, Seller shall submit to Buyer a proposed schedule of Scheduled Maintenance Outages scheduled by Seller for the following Contract Year for the Units, which schedule shall be updated by Seller by each March 31 and September 30 thereafter to cover the twelve month period following each such update; provided, however, that no Scheduled Maintenance Outage may be scheduled to cover the period from May 15 to September 15. Parameters within which Scheduled Maintenance Outages must be planned are included as Appendix I. If the OEM issues recommendations for changes to the parameters in Appendix I, the parties shall negotiate in good faith to revise Appendix I accordingly. Such schedule, and each supplement thereto, shall indicate the planned start and completion dates for each Scheduled Maintenance Outage during the period covered thereby and the amount of the Net Dependable Capacity of a Unit that will be affected. Within thirty (30) days of receipt of such schedule or any supplement thereto, Buyer may request reasonable modifications in the Scheduled Maintenance Outage schedule contained therein. Both parties agree to use reasonable efforts to develop a mutually acceptable final schedule for such Scheduled Maintenance Outages. If within six months prior to the scheduled start of a Scheduled Maintenance Outage, Buyer desires to change the scheduled start or duration of such Scheduled Maintenance Outage, Buyer shall notify Seller of Buyer's requested change and Seller shall use reasonable efforts to accommodate Buyer's requested change. Seller may propose compensation from Buyer to Seller for such change. Buyer shall then have the right to either direct such change and pay Seller such compensation, or withdraw the request for such change. At least one week prior to any Scheduled Maintenance Outage, Seller shall orally notify Buyer of the expected start date of such Scheduled Maintenance Outage, the amount of Capacity at the Units that will not be available to Buyer during such Scheduled Maintenance Outage, and the expected completion date of such Scheduled Maintenance Outage. Seller shall orally notify Buyer of any subsequent changes in such Capacity not available or any subsequent changes in the Scheduled Maintenance Outage completion date. As soon as practicable, all such oral notifications shall be confirmed in writing. Scheduled Maintenance Outages may be taken in any number of non-contiguous periods, subject to Buyer's approval, which shall not be unreasonably withheld or delayed. Subject to the foregoing, the duration, frequency and timing of Scheduled Maintenance Outages shall be based on OEM recommendations and the age and operation of the Units generally plus up to five (5) days per Unit on a semi-annual basis for Non-Summer Period balance of plant maintenance.
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Maintenance Program LESSEE's Maintenance Program
