Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not xxx or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Tenants Selection of Contractors Tenant shall retain Landlord’s contractor, Commerce Construction Co., L.P. (the “Contractor”), as general contractor for the performance of the Work.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Liability for Unauthorized Use If any Card is lost or stolen or otherwise may be used without your permission (express or implied), you must immediately notify us orally or in writing at the following phone number or address: 0-000-000-0000 or at TIB, National Association, P.O Box 569120, Dallas, Texas 75356-9120. If unauthorized use of a Card occurs before you notify us of the loss, theft or unauthorized use, you may be liable up to a maximum amount of $50. If unauthorized use of a Credit Device occurs, you may be liable for all of the unauthorized use.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Recall to Work 5.6.2.1 An employee recalled to work overtime after leaving the company’s premises (whether notified before or after leaving the premises) will be paid for a minimum of three hours work at the appropriate rates for each time the employee is so recalled. Except in the case of unforeseen circumstances arising, the employee will not be required to work the full three hours if the job the employee was recalled to perform is completed within a shorter period.
Contracts Concerning Use of Project The Recipient agrees that during the Agreement Term it will not contract with any Private Person for use of the Project or any portion thereof or the facility or facilities of which the Project is a part for any Private Business Use unless all of the conditions of subparagraph F.3.a., subparagraph F.3.b. or subparagraph F.3.c. are met:
a. If the compensation of the Private Person is based entirely on a periodic, fixed fee that contains no incentive adjustments, all of the following conditions must be met: (A) no amount of compensation is based on a share of the net profits; (B) the compensation is reasonable; (C) the term of the contract does not exceed five (5) years (including any renewal option periods provided for in the contract);
Access to Work District representatives shall at all times have access to the Work, wherever it is, in preparation or in progress. Contractor shall provide safe and proper facilities for such access.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
