Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Condemnation/Eminent Domain In the event that the Premises or any part thereof, or the whole or any part of the Building, shall be taken or appropriated by eminent domain or shall be condemned for any public or quasi-public use, or (by virtue of any such taking, appropriation or condemnation) shall suffer any damage (direct, indirect or consequential) for which Landlord or Tenant shall be entitled to compensation, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Landlord by a notice in writing of its election so to terminate which shall be given by Landlord to Tenant within sixty (60) days following the date on which Landlord shall have received notice of such taking, appropriation or condemnation. In the event that a material part of the Premises or the means of access thereto shall be so taken, appropriated or condemned, and in either case, the remainder of the Premises or the mode of access thereto is, in Tenant’s reasonable judgment, unsuitable for the operation of Tenant’s business in the Premises, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Tenant by a notice in writing of its election so to terminate which shall be given by Tenant to Landlord within sixty (60) days following the date on which Tenant shall have received notice of such taking, appropriation or condemnation. Upon the giving of any such notice of termination (either by Landlord or Tenant) this Lease and the Term hereof shall terminate on or retroactively as of the date on which Tenant shall be required to vacate any part of the Premises or shall be deprived of a substantial part of the means of access thereto, provided, however, that Landlord may in Landlord’s notice elect to terminate this Lease and the Term hereof retroactively as of the date on which such taking, appropriation or condemnation became legally effective. In the event of any such termination, this Lease and the Term hereof shall expire as of such effective termination date as though that were the Expiration Date as stated in Exhibit 1, and the Yearly Rent (together with Operating Costs Excess and Tax Excess) shall be apportioned as of such date. If neither party (having the right so to do) elects to terminate Landlord will, with reasonable diligence and at Landlord’s expense, restore the remainder of the Premises, or the remainder of the means of access, as nearly as practicably may be to the same condition as obtained prior to such taking, appropriation or condemnation in which event (i) the Total Rentable Area shall be equitably adjusted, (ii) a just proportion of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resulting permanent injury to the Premises and the means of access thereto, shall be permanently abated, and (iii) a just proportion of the remainder of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resultant injury sustained by the Premises and the means of access thereto, shall be abated until what remains of the Premises and the means of access thereto shall have been restored as fully as may be for permanent use and occupation by Tenant hereunder. Except for any award specifically reimbursing Tenant for moving or relocation expenses or for Tenant’s personal property, or for the unamortized value of any leasehold improvements paid for by Tenant (in excess of any Landlord contribution), there are expressly reserved to Landlord all rights to compensation and damages created, accrued or accruing by reason of any such taking, appropriation or condemnation, in implementation and in confirmation of which Tenant does hereby acknowledge that Landlord shall be entitled to receive all such compensation and damages, grant to Landlord all and whatever rights (if any) Tenant may have to such compensation and damages, and agree to execute and deliver all and whatever further instruments of assignment as Landlord may from time to time reasonably request. In the event of any taking of the Premises or any part thereof for temporary (i.e., not in excess of one (1) year) use, (i) this Lease shall be and remain unaffected thereby, and (ii) Tenant shall be entitled to receive for itself any award made to the extent allocable to the Premises in respect of such taking on account of such use, provided, that if any taking is for a period extending beyond the Term of this Lease, such award shall be apportioned between Landlord and Tenant as of the Expiration Date or earlier termination of this Lease.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Upon completion of the Project the Recipient shall make a full and complete accounting to the OPWC of the Eligible Project Cost.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Condemnation and Casualty (a) In the event of any condemnation or casualty of any Property in part or in the entirety, the proceeds of such condemnation or casualty, to the extent not retained or otherwise applied by the holder of any mortgage securing Senior Debt on such Property, or by the holder of the Construction Loan, applied as required pursuant to any Major Lease approved by the Lender at the Property or applied by such mortgagee or in accordance with such Major Lease either to restore the improvements on such Property or to reduce such Senior Debt or the Construction Loan, as applicable, applied as required pursuant to any condominium declaration and/or related by-laws affecting any Property that has previously been approved by Lender to restore the improvements on such Property or applied in accordance with the Loan Documents, shall be immediately deposited by Borrower in a cash collateral account to be maintained by Borrower at a depository designated by Lender and under the sole dominion and control of Lender (the "Cash Collateral Account") pursuant to a cash collateral agreement to be entered into between Borrower, Lender and such Depository (the "Cash Collateral Agreement"); (such proceeds of condemnation so deposited being herein called "Condemnation Proceeds"; such proceeds of casualty so deposited being herein called "Casualty Proceeds"; and Condemnation Proceeds and/or Casualty Proceeds being herein called "Proceeds") and shall constitute additional collateral for the Loan Obligations.
(b) Provided that no Default or Event of Default shall have occurred and be continuing, the Borrower shall be entitled to withdraw any Condemnation Proceeds from the Cash Collateral Account for the purpose of acquiring additional real estate assets with the consent of the Lender, which consent shall not be unreasonably withheld, provided that, subject to the Loan Documents, the Loan Agreements and the Other Vornado Loans (i) Borrower shall have delivered to Lender an appraisal for such real estate (x) for an amount at least equal to the amount of the Condemnation Proceeds sought to be withdrawn by the Borrower to purchase such real estate and (y) issued by an appraisal company and in form and substance reasonably satisfactory to the Lender; (ii) the Borrower shall have delivered to Lender environmental, engineering and such other studies, reports, documents, title reports, violation searches and other information relating to such real estate as would be generally required by the Lender in accordance with good institutional lending practices, all of which studies, reports, documents and other information shall be in form and substance reasonably satisfactory to the Lender; (iii) the Lender shall be granted a priority lien mortgage on said real estate to further secure the Guaranty (the "Additional Mortgage"); (iv) the Borrower shall have delivered to Lender a paid-up mortgage title insurance policy in favor of Lender, insuring the Additional Mortgage as a second priority mortgage on such real estate, subject to no encumbrances or other title exceptions except those title exceptions which Lender reasonably determines are acceptable based on good institutional lending practices; and (v) the Borrower shall have paid all reasonable costs and expenses of the Lender (including reasonable attorneys' fees and expenses) incurred by the Lender in connection with the review of any of the foregoing conditions.
(c) The Borrower shall also have the right to withdraw the Condemnation Proceeds remaining in the Cash Collateral Account to pay for the cost of constructing improvements on any Property covered by any Mortgage, and the Borrower shall have the right to withdraw any Casualty Proceeds in the Cash Collateral Account to pay for the repair and restoration of improvements whose damage or destruction generated such Casualty Proceeds, provided that, in all cases, subject to the Loan Documents, the Loan Agreements and any condominium declaration and/or related by-laws affecting such Property that has previously been approved by Lender and the Other Vornado Loans: (i) no Default or Event of Default shall be continuing; (ii) the Lender shall have approved the plans and specifications for the construction of such improvements as well as the general contract and other major contracts to be entered into by the Borrower in connection with such construction, which approval will not unreasonably be withheld; (iii) the Lender shall have received such certification and assurances as Lender shall reasonably request to assure it that the cost of constructing the improvements as shown on the plans approved by Lender does not exceed the amount of the Proceeds sought to be withdrawn by the Borrower to pay for such improvements; and (iv) the Lender may impose such further conditions and restrictions upon the disbursement of such Proceeds as the Lender deems necessary or desirable, consistent with prudent institutional construction lending practices, to assure the completion of the proposed improvements subject to no liens or encumbrances (except Permitted Liens) and in accordance with the aforesaid approved plans and all applicable laws.
