CORRECTION AFTER COMPLETION Sample Clauses
CORRECTION AFTER COMPLETION. If, within one (1) year after the date of issuance of the Authorization to Enter or within one (1) year after the date for commencement of warranties established under this Agreement or any other written agreement between the Owner and the Construction Manager or by terms of an applicable special warranty required by the Contract Documents (whichever one-year period expires later being applicable hereunder) any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Construction Manager shall correct such Work promptly after receipt of a written notice from the Owner to do so.
CORRECTION AFTER COMPLETION. Subject to any special provisions in the Contract Documents, the Contractor covenants and agrees to remedy any defects due to faulty materials or workmanship appearing within a period of one year from the date of Substantial Performance of the work, as set out in the Engineer's Certificate of Substantial Performance, and shall pay for any damage to other work resulting therefrom which appears within such period, and neither the Completion Certificate nor payment thereunder shall relieve the Contractor from responsibility hereunder. The Owner shall promptly give written notice of observed defects. Should the Contractor fail to comply, or delay in complying with their obligation herein the Owner may, after giving the Contractor seven (7) days written notice, perform the necessary corrections; provided that in the event of an emergency endangering life, the structure or neighbouring property arising out of such defects, the Owner may make immediate arrangement for emergency repairs as they deem fit and will inform the Contractor of their actions in that respect. The costs of all repairs performed hereunder, including any costs incurred by the Owner by reason of either the failure or delay of the Contractor in complying with their obligations herein, or the necessity of the Owner's making emergency repairs as provided for herein, shall be borne by the Contractor and shall be a debt, due and owing by the Contractor to the Owner. Any disputes arising out of the provisions of this section may be resolved by recourse to arbitration under Section 44 hereof.