Correction, Rejection Sample Clauses

Correction, Rejection. If any goods and services are in XXXXX'x reasonable business judgment defective in material or workmanship or not in conformity with the drawings, specifications, samples or other requirements of the relevant purchase order, XXXXX shall notify Supplier. If Supplier fails to correct the defect or non-conformity within a timeframe appropriate to support XXXXX manufacturing needs after such notice or is unable to correct the defect or non- conformity, XXXXX may, in addition to any other rights under the purchase order, these Terms and Conditions or otherwise, correct or have corrected the defect or nonconformity at Supplier's expense. Rejected goods may be returned by XXXXX to Supplier at Supplier's risk and expense, including without limitation all costs (including XXXXX'x personnel costs) of unpacking, examining, repacking and reshipping, and transportation of, such goods.
Sample 1Sample 2
AutoNDA by SimpleDocs
Correction, Rejection. If any goods and services are in GSP's reasonable business judgment defective in material or workmanship or not in conformity with the drawings, specifications, samples or other requirements of the relevant purchase order, GSP shall notify Supplier. If Supplier fails to correct the defect or non-conformity within a timeframe appropriate to support GSP manufacturing needs after such notice or is unable to timely correct the defect or non- conformity (as solely determined by GSP), GSP may, in addition to any other rights under the purchase order, these Terms and Conditions or otherwise, correct or have corrected the defect or nonconformity at Supplier's expense. Rejected goods may be returned by GSP to Supplier at Supplier's risk and expense, including without limitation all costs (including GSP's personnel costs) of unpacking, examining, repacking and reshipping, and transportation of, suchgoods.
Sample 1

Related to Correction, Rejection

  • Correction No corrections shall be made in the tender documents. Any corrections that are to be made shall be made by crossing the incorrect portion and writing the correct portions above with the initials of tenderer.

  • Nonconforming Work 23.1.1 Developer shall promptly remove from Premises all Work identified by District as failing to conform to the Contract Documents whether incorporated or not. Developer shall promptly replace and re-execute its own Work to comply with the Contract Documents without additional expense to the District and shall bear the expense of making good all work of other contractors destroyed or damaged by any removal or replacement pursuant hereto and/or any delays to the District or other contractors caused thereby.

  • Rejection State Street reserves the right to decline to process or delay the processing of a payment order which (a) is in excess of the collected balance in the account to be charged at the time of State Street's receipt of such payment order; (b) if initiating such payment order would cause State Street, in State Street's sole judgment, to exceed any volume, aggregate dollar, network, time, credit or similar limits upon wire transfers which are applicable to State Street; or (c) if State Street, in good faith, is unable to satisfy itself that the transaction has been properly authorized.

  • Correction of Defective Work 2.10.1 Design-Builder agrees to correct any Work that is found to not be in conformance with the Contract Documents, including that part of the Work subject to Section 2.9 hereof, within a period of one (1) year from the date of Final Acceptance of the Work or any portion of the Work, or within such longer period to the extent required by the Contract Documents or applicable Legal Requirements or Government Approvals.

  • Inspection and Rejection of Nonconforming Goods (a) Buyer shall inspect the goods within five days of receipt (“Inspection Period”). Xxxxx will be deemed to have accepted the goods unless it notifies Seller in writing of any Nonconforming Goods during the Inspection Period and furnishes documentation reasonably required by Seller. “

  • Pack Rejection 6.4.1 <<customer_name>> will notify BellSouth within one business day of rejected packs (via the mutually agreed medium). Packs could be rejected because of pack sequencing discrepancies or a critical edit failure on the Pack Header or Pack Trailer records (i.e. out-of-balance condition on grand totals, invalid data populated). Standard ATIS EMI Error Codes will be used. <<customer_name>> will not be required to return the actual rejected data to BellSouth. Rejected packs will be corrected and retransmitted to <<customer_name>> by BellSouth.

  • INSPECTION, ACCEPTANCE AND REJECTION a. All Goods will be subject to Mercy Corps' inspection and testing (which may be done by a third party authorized by Mercy Corps), at any time and place, including the period of manufacture/production/creation and before final acceptance. If Mercy Corps inspects or tests at Supplier's premises, Supplier, without additional charge, will provide all reasonable facilities and assistance for the safety and convenience of Mercy Corps' inspectors. No inspection or testing done or not done before final inspection and acceptance will relieve Supplier from responsibility for defects or for other failure to meet the requirements of this Agreement. Notwithstanding any prior inspections or payments made, all Goods will be subject to final inspection and acceptance at the Delivery Location within a reasonable time after delivery (but in no event, less than three days after the date of delivery).

  • Error Correction The Manager shall make adjustments to charges as required to reflect the discovery of errors or omissions in charges; provided, however, that any errors or omissions the correction of which would result in additional or increased charges or fees for Services must be corrected within [ ] years after the date of the related invoice.

  • Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.

  • Order Rejections 53.11.1 CenturyLink shall reject and return to CLEC any order that CenturyLink cannot provision, due to technical reasons, missing information, or jeopardy conditions resulting from CLEC ordering service at less than the standard order interval.

Time is Money Join Law Insider Premium to draft better contracts faster.