Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content. For purposes of Sections 2252.152, 2271.002, and 2274.002, Texas Government Code, as amended, C&T hereby verifies that C&T and any parent company, wholly owned subsidiary, majority-owned subsidiary, and affiliate:
a. Unless affirmatively declared by the United States government to be excluded from its federal sanctions regime relating to Sudan or Iran or any federal sanctions regime relating to a foreign terrorist organization, is not identified on a list prepared and maintained by the Texas Comptroller of Public Accounts under Sections 806.051, 807.051, or 2252.153 of the Texas Government Code.
b. If employing ten (10) or more full-time employees and this Agreement has a value of
Expenditure on Safety Requirements All costs and expenses arising out of or relating to Safety Requirements shall be borne by the Concessionaire to the extent such costs and expenses form part of the works and services included in the Scope of the Project, and works and services, if any, not forming part of the Scope of the Project shall be undertaken and funded in accordance with the provisions of Article 16.
Eligibility Requirements for the Trustee The Trustee hereunder shall at all times be a corporation or association organized and doing business under the laws of a state or the United States of America, authorized under such laws to exercise corporate trust powers, having a combined capital and surplus of at least $50,000,000, subject to supervision or examination by federal or state authority and with a credit rating which would not cause either of the Rating Agencies to reduce their respective then current ratings of the Certificates (or having provided such security from time to time as is sufficient to avoid such reduction) as evidenced in writing by each Rating Agency. If such corporation or association publishes reports of condition at least annually, pursuant to law or to the requirements of the aforesaid supervising or examining authority, then for the purposes of this Section 8.06 the combined capital and surplus of such corporation or association shall be deemed to be its combined capital and surplus as set forth in its most recent report of condition so published. In case at any time the Trustee shall cease to be eligible in accordance with this Section 8.06, the Trustee shall resign immediately in the manner and with the effect specified in Section 8.07. The entity serving as Trustee may have normal banking and trust relationships with the Depositor and its affiliates or the Master Servicer and its affiliates; provided, however, that such entity cannot be an affiliate of the Seller, the Depositor or the Master Servicer other than the Trustee in its role as successor to the Master Servicer.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Eligibility Requirements for the Owner Trustee The Owner Trustee shall at all times be a bank (i) authorized to exercise corporate trust powers, (ii) having a combined capital and surplus of at least $50,000,000 and (iii) subject to supervision or examination by Federal or state authorities. If such bank shall publish reports of condition at least annually, pursuant to law or to the requirements of the aforesaid supervising or examining authority, then for the purpose of this Section, the combined capital and surplus of such corporation shall be deemed to be its combined capital and surplus as set forth in its most recent report of condition so published. The Owner Trustee shall at all times be an institution satisfying the provisions of Section 3807(a) of the Statutory Trust Statute. In case at any time the Owner Trustee shall cease to be eligible in accordance with the provisions of this Section, the Owner Trustee shall resign immediately in the manner and with the effect specified in Section 10.2.
Compliance with Xxxxxxxx Act requirements The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.
Miscellaneous Requirements A. To comply with Texas Health and Safety Code, §85.113 and §85.115 concerning workplace and confidentiality guidelines for persons with AIDS or HIV.
B. To comply with applicable provisions of the Clean Air Act (42 U.S.C. §7401-7671q) and the Federal Water Pollution Control Act (33 U.S.C. §1251-1387), if funding for the Contract exceeds $100,000.
C. That in accordance with §2155.4441, Texas Government Code, the Contractor shall, in performing any service under this Contract, purchase products and materials produced in Texas when they are available at a comparable price and in a comparable period to products and materials produced outside of Texas.
D. To make a good faith effort to utilize historically underutilized businesses ("HUBs") when subcontracting. Some methods for locating HUBs include using searchable HUB databases at the Texas Comptroller of Public Accounts' website, using websites or other minority/women directory listings maintained by local xxxxxxxx of commerce, advertising subcontract work in local minority publications or contacting HHSC for assistance in locating available HUBs.
E. That except as provided in the paragraphs below, the Contractor must not use HHSC's name, the State of Texas or refer to HHSC or the State directly or indirectly in any media release, public announcement, or public disclosure relating to this Contract or its subject matter, including, but not limited to, in any promotional or marketing materials, customer lists or business presentations (other than those submitted to HHSC, an administrative agency of the State of Texas, or a governmental agency or unit of another state or the Federal Government). The Contractor may publish, at its sole expense, results of Contractor performance under this Contract with HHSC's prior review and approval, which HHSC may exercise at its sole discretion. Any publication (written, visual, or sound) will acknowledge the support received from HHSC and any Federal agency, as appropriate. The Contractor will provide HHSC at least 3 copies of such publication prior to public release. The Contractor will provide additional copies at the request of HHSC. The Contractor may include information concerning this Contract's terms, subject matter, and estimated value in any report to a governmental body to which the law requires the Contractor to report such information. The Contractor must not use HHSC’s logo under any circumstances.
Basic Requirements To be eligible for PayPal’s Seller Protection program, all of the following basic requirements must be met, as well as any applicable additional requirements: • The primary address for your PayPal account must be in the United States. • The item must be a physical, tangible good that can be shipped, except for items subject to the Intangible Goods Additional Requirements. Transactions involving items that you deliver in person in connection with payment made in your physical store, may also be eligible for PayPal’s Seller Protection program so long as the buyer paid for the transaction in person by using a PayPal goods and services QR code. • You must ship the item to the shipping address on the Transaction Details page in your PayPal account for the transaction. If you originally ship the item to the recipient’s shipping address on the Transaction Details page but the item is later redirected to a different address, you will not be eligible for PayPal’s Seller Protection program. We therefore recommend not using a shipping service that is arranged by the buyer, so that you will be able to provide valid proof of shipping and delivery. • The shipping requirement does not apply to eligible transactions involving items that you deliver in person; provided, however, that you agree to provide us with alternative evidence of delivery or such additional documentation or information relating to the transaction that we may request. • You must respond to PayPal’s requests for documentation and other information in a timely manner as requested in our email correspondence with you or in our correspondence with you through the Resolution Center. If you do not respond to PayPal’s request for documentation and other information in the time requested, you may not be eligible for PayPal’s Seller Protection program. • If the sale involves pre-ordered or made-to-order goods, you must ship within the timeframe you specified in the listing. Otherwise, it is recommended that you ship all items within 7 days after receipt of payment. • You provide us with valid proof of shipment or delivery. • The payment must be marked “eligible” or “partially eligible” in the case of Unauthorized Transaction claims, or “eligible” in the case of Item Not Received claims, for PayPal’s Seller Protection program on the Transaction Details page. • In the case of an Unauthorized Transaction claim, you must provide valid proof of shipment or proof of delivery that demonstrates that the item was shipped or provided to the buyer no later than two days after PayPal notified you of the dispute or reversal. For example, if PayPal notifies you of an Unauthorized Transaction claim on September 1, the valid proof of shipment must indicate that the item was shipped to the buyer no later than September 3 to be eligible for PayPal’s Seller Protection program. PayPal determines, in its sole discretion, whether your claim is eligible for PayPal’s Seller Protection program. PayPal will make a decision, in its sole discretion, based on the eligibility requirements, any information or documentation provided during the resolution process, or any other information PayPal deems relevant and appropriate under the circumstances. To be eligible for PayPal’s Seller Protection program for a buyer’s Item Not Received claim, you must meet both the basic requirements and the additional requirements listed below: • Where a buyer files a chargeback with the issuer for a card-funded transaction, the payment must be marked “eligible” for PayPal’s Seller Protection on the Transaction Details page. • You must provide proof of delivery as described below.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
