CLEC Requested Changes 58.9.1 CLEC may submit a request to negotiate and pay for changes in the content and format of the usage data transmitted by CenturyLink.
Owner-Requested Changes If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.
New Survey Requested Buyer will, at the ☐ Seller’s ☐ Buyer’s ☐ Shared expense and within a timeframe allowed to deliver and examine title evidence, obtain a certified survey of the Property from a certified and registered surveyor within the State. If the survey reveals encroachments on the Property or that the improvements encroach on the lands of another, such encroachments will constitute a title defect. The Buyer shall have the right to terminate this Agreement with written notice to the Seller within calendar days of being notified of said title defect.
Minor Administrative Changes System Agency is authorized to provide written approval of mutually agreed upon Minor Administrative Changes to the Project or the Contract that do not increase the fees or term. Upon approval of a Minor Administrative Change, HHSC and Grantee will maintain written notice that the change has been accepted in their Contract files.
Precedence of Documents and Changes In the event of conflict, the Contract takes precedence over the Supplementary Conditions, and the Supplementary Conditions take precedence over the General Conditions. No change to the Contract Documents is effective unless notice shall have been issued by the Owner bearing the imprimatur of the Owner as follows: “By order of The Board of Public Education for the City of Savannah and the County of Chatham.” The Design Professional has no authority to amend the Contract Documents, orally or in writing, either expressly or by implication.
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Expedited Process (a) Where an Employer has made a selection pursuant to Clause 24.3 (Appointment Policy) and the employee disagrees with the Employer's decision, the employee may grieve the decision under the process set out below within seven days of being notified of the results.
CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.
Notification of Changes Subscriber agrees and covenants to notify the Company immediately upon the occurrence of any event prior to the consummation of this Offering that would cause any representation, warranty, covenant or other statement contained in this Agreement to be false or incorrect or of any change in any statement made herein occurring prior to the consummation of this Offering.
Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.