Owner-Requested Changes Sample Clauses

Owner-Requested Changes. If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.
AutoNDA by SimpleDocs
Owner-Requested Changes. If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The CM/GC expressly agrees that the CM/GC’s sole monetary remedy for such extensions of Contract Time shall remain limited by the maximum amount for Time Dependent Overhead Costs (as amended) in the Contract.
Owner-Requested Changes. If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Executive Administrator shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Design-Builder expressly agrees that the Design-Builder’s sole monetary remedy for such extensions of Contract Time shall be no greater than the actual direct costs incurred by Design-Builder. Actual compensation for such Compensable Delay shall be mutually agreed upon by Design-Builder and Owner.
Owner-Requested Changes. If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall recommend the appropriate number of additional days to be considered in the Change Order. Contractor agrees that any monetary remedy associated with such extensions of Contract Time shall be no greater than the actual direct costs incurred by the Contractor.

Related to Owner-Requested Changes

  • Work Schedule Changes 215. It is agreed that pursuant to the exercise of management rights, normal work schedules may be changed without mutual agreement, subject to compliance with other provisions of this Agreement. However, it is agreed that the effects of consequences of such changes are subject to the meet and confer obligation to the extent required by state law.

  • CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Project Changes 1.8.1. All changes shall be administered per the UGC.

  • Schedule Changes (a) If, in the course of a posted schedule, the Employer:

  • Room Changes No changes in room assignment will be based upon age, race, religion, national origin, disability, sexual orientation, and online profiles except as needed to provide a reasonable accommodation to residents with eligible disabilities registered with the University [Office of Disability Services]. Room change may only be made with the written approval of University Housing and is dependent upon space availability, timing of the request, and grounds for transfer. Residents who receive approval for a room change may be charged a room change fee as shown on the University Housing website, which will be posted to Resident’s account. Room changes that are not authorized by University Housing will result in a fine as shown on the University Housing website, which will be posted to Resident’s account.

  • Permanent Schedule Changes Employees’ workweeks and work schedules may be permanently changed with prior notice from the Employer. Overtime-eligible employees will receive ten (10) calendar days’ written notice of a permanent schedule change. The day notification is given is considered the first day of notice. Notice will normally be given to the affected employees during their scheduled working hours. If an affected employee is on extended leave, notice may be sent to the employee’s last known address.

  • Waiver Request Either Party may, in accordance with the Notice provision set out in Article A17.0, ask the other Party to waive an obligation under the Agreement.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!