APPROVAL OF GENERAL COMMUNICATIONS Competitive Supplier shall cooperate with and assist the Town in the drafting and sending of messages and information to Eligible Consumers concerning the Program or any matter arising under or related to this Agreement or the Program. Competitive Supplier shall, prior to sending any direct mail, advertising, solicitation, bill insert, electronic mail, or other similar written or electronic communication (collectively, “General Communications”) to Participating Consumers (but excluding individually drafted or tailored communications responding to a specific complaint or communication of an individual consumer), provide a copy of such General Communication to the Town for its review (for consistency with the Town’s purposes and goals) and approval. The Town shall have the right to disapprove such General Communications and suggest revisions if it finds the communication inconsistent with the purposes and goals of the Town, factually inaccurate, or likely to mislead provided, however, that: (i) the communication shall be deemed approved if the Town fails to respond within ten (10) Business Days, and (ii) no approval shall be necessary for any communication (a) regarding any emergency situation involving any risk to the public health, safety or welfare; (b) that has been approved by the Department, the DOER; or (c) in the nature of routine monthly or periodic bills, or collection notices, except that any bill insert or message included at the bottom of such bill not within the scope of (a) or (b) above shall require advanced review and approval by the Town; and (iii) no approval or lack of approval shall relieve the Competitive Supplier of its obligations and responsibility for its actions and omissions under this Agreement, or other than as set forth in sub-clause ‘i’ of this Section 7.6, result in a waiver of any rights, remedies or defenses of the Town. The Town may reject or exclude any proposed General Communication that, in its reasonable judgment, is contrary to the interests and objectives of the Program or the Town.
State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.
Contractor Approach The Contractor shall develop, document, and implement BIDM Data Exchanges to obtain BIDM Imports from and to send BIDM Exports to CDPHE's CEDRS. 17.47.2.1. This exchange shall occur on a period as determined by the Department
CONTRACTOR SUPERVISION Contractor shall provide competent supervision of personnel employed on the job Site, use of equipment, and quality of workmanship.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Procurement of Goods and Services (a) If the HSP is subject to the procurement provisions of the BPSAA, the HSP will abide by all directives and guidelines issued by the Management Board of Cabinet that are applicable to the HSP pursuant to the BPSAA. (b) If the HSP is not subject to the procurement provisions of the BPSAA, the HSP will have a procurement policy in place that requires the acquisition of supplies, equipment or services valued at over $25,000 through a competitive process that ensures the best value for funds expended. If the HSP acquires supplies, equipment or services with the Funding it will do so through a process that is consistent with this policy.
Independent Contractor; Authority Notwithstanding the Services provided by the Administrator pursuant to this Agreement, the Administrator shall be deemed to be an independent contractor with respect to the Services. The management, policies and operations of the Parties (including the ultimate approval of the making or disposition of the Painting by the Issuer or Masterworks Cayman, and the terms and conditions thereof) shall be the responsibility of the Parties other than the Administrator.
Procurement of Small Works Works estimated to cost $250,000 equivalent or less per contract, up to an aggregate amount not to exceed $800,000 equivalent, may be procured under lump-sum, fixed-price contracts awarded on the basis of quotations obtained from three (3) qualified domestic contractors in response to a written invitation. The invitation shall include a detailed description of the works, including basic specifications, the required completion date, a basic form of agreement acceptable to the Bank, and relevant drawings, where applicable. The award shall be made to the contractor who offers the lowest price quotation for the required work, and who has the experience and resources to complete the contract successfully. Part D: Review by the Bank of Procurement Decisions
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
