Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Delivery and Control (i) With respect to any Investment Related Property consisting of Securities Accounts or Securities Entitlements, it shall cause the securities intermediary maintaining such Securities Account or Securities Entitlement to enter into an agreement substantially in the form of Exhibit C hereto pursuant to which it shall agree to comply with the Collateral Agent’s “entitlement orders” without further consent by such Grantor. With respect to any Investment Related Property that is a “Deposit Account,” it shall cause the depositary institution maintaining such account to enter into an agreement substantially in the form of Exhibit D hereto, pursuant to which the Collateral Agent shall have both sole dominion and control over such Deposit Account (within the meaning of the common law) and “control” (within the meaning of Section 9-104 of the UCC) over such Deposit Account. Each Grantor shall have entered into such control agreement or agreements with respect to: (i) any Securities Accounts, Securities Entitlements or Deposit Accounts that exist on the Credit Date, as of or prior to the Credit Date and (ii) any Securities Accounts, Securities Entitlements or Deposit Accounts that are created or acquired after the Credit Date, as of or prior to the deposit or transfer of any such Securities Entitlements or funds, whether constituting moneys or investments, into such Securities Accounts or Deposit Accounts. In addition to the foregoing, if any issuer of any Investment Related Property is located in a jurisdiction outside of the United States, each Grantor shall take such additional actions, including, without limitation, causing the issuer to register the pledge on its books and records or making such filings or recordings, in each case as may be necessary or advisable, under the laws of such issuer’s jurisdiction to insure the validity, perfection and priority of the security interest of the Collateral Agent. Upon the occurrence of an Event of Default, the Collateral Agent shall have the right, without notice to any Grantor, to transfer all or any portion of the Investment Related Property to its name or the name of its nominee or agent. In addition, the Collateral Agent shall have the right at any time, without notice to any Grantor, to exchange any certificates or instruments representing any Investment Related Property for certificates or instruments of smaller or larger denominations.
Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.
Delivery and Risk 4.1 Time of delivery shall not be of the essence in any agreement between the Parties. 4.2 WHILST EVERY EFFORT WILL BE MADE TO DISPATCH AND DELIVER THE GOODS AS ADVISED, THE SELLER DOES NOT GUARANTEE DISPATCH AND/OR DELIVERY ON ANY SPECIFIC DATE AND SHALL NOT BE LIABLE FOR ANY DAMAGES INCLUDING CONSEQUENTIAL DAMAGES THAT MAY BE SUFFERED BY THE PURCHASER AND/OR ANY THIRD PARTY AS A RESULT OF ANY DELAYS IN THE DELIVERY OF THE GOODS THAT MAY OCCUR, SAVE TO THE EXTENT THAT THE SELLER IS FOUND TO BE LIABLE FOR ANY LOSSES IN TERMS OF SECTION 47 OF THE CONSUMER PROTECTION ACT 68 OF 2008 AS AMENDED. 4.3 The Purchaser shall not be entitled to cancel any order as a result of any delay in delivery of the Goods. 4.4 Should the Seller be prevented from the performance of any of its obligations because of force majeure (which includes but is not limited to an event that prevents or delays the Seller from being able to perform an obligation, wars, insurrections, strikes, pandemics, acts of God, natural disasters, governmental actions or controls, government restrictions and/or water or energy supply restrictions), or any cause whatsoever beyond the control of the Seller, the Seller shall be entitled at its option to cancel the agreement with the Purchaser or to suspend performance of its obligations there under and shall not be liable whatsoever for any loss or damage, consequential or otherwise, resulting from such inability to perform its obligations, cancellation, or suspension. 4.5 Unless otherwise agreed in writing, delivery and passing of the risk in the Goods shall be deemed to have taken place when the Goods are offloaded at the Purchaser’s premises. 4.6 The Seller reserves the right to refuse an order within 10 (ten) business of such order being received by the Seller where costs have escalated due to any contingencies or circumstances not within the Seller’s control. 4.7 The Seller’s deliveries shall be effected “ex works” for the account and at the risk of the Purchaser. Transport insurance shall be arranged at the Purchaser’s written request and for its account. The Seller shall have the right to demand a prepayment on the insurance premium by the Purchaser. In the absence of specific instructions by the Purchaser, the Seller shall determine the shipping route and carrier. The transport packaging shall be product-related and consider the statutory regulations as may be made from time to time. The Seller shall bear the packing charges, which shall be determined at the Seller’s discretion. The packaging shall be taken back at the Purchaser’s request and expense.
Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas. A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below. 1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.