Damage Destruction or Discontinued Use of Airport
Damage Destruction or Discontinued Use of Airport Sample Clauses
Related to Damage Destruction or Discontinued Use of Airport
Interruption of Use Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord's reasonable control; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant's use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for a loss of, or injury to, property or for injury to, or interference with, Tenant's business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow"). (b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement. (d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
DAMAGE OR DESTRUCTION OF PREMISES If the Premises are damaged by fire or other casualty, but are not rendered untenantable for Tenant’s business, either in whole or in part, Landlord shall cause such damage to be repaired without unreasonable delay and the Annual Rent shall not xxxxx. If by reason of such casualty the Premises are rendered untenantable for Tenant’s business, either in whole or in part, Landlord shall cause the damage to the physical structure of the Building (excluding any tenant improvements or alterations therein) to be repaired or replaced without unreasonable delay, and, in the interim, the Annual Rent shall be proportionately reduced as to such portion of the Premises as is rendered untenantable, however, Tenant must vacate the portion of the Premises deemed untenantable during the period of Landlord’s repairs for such abatement of Annual Rent to be effective. Any such abatement of rent shall not create an extension of the Term. Provided, however, if by reason of such casualty, the Premises are rendered untenantable in some material portion, and Landlord, in its commercially reasonable estimation, determines that the amount of time required to repair the damage using due diligence is in excess of two hundred ten (210) days (as measured from the date of casualty), then Landlord shall provide written notice thereof to Tenant, to be given to Tenant within seventy-five (75) days following the date of such casualty, and either party shall then have the right to terminate this Lease by giving written notice of termination within thirty (30) days after the date of said notice from Landlord. In such event, the Annual Rent shall (i) xxxxx as of the date of such casualty in proportion to the part of the Premises rendered untenantable, and (ii) xxxxx entirely as of the effective date of the termination of this Lease. Notwithstanding the foregoing, in the event the casualty giving rise to an election to terminate is caused by the negligence, misconduct or acts or omissions of Tenant or Tenant’s Invitees, Tenant shall have no right to terminate this Lease. Notwithstanding the other provisions of this Section, in the event there should be a casualty loss to the Premises during the last two (2) Lease Years of the Term, Landlord may, at its option, terminate this Lease by giving written notice to Tenant within thirty (30) days after the date of the casualty and the Annual Rent shall xxxxx as of the date of such notice. Except as provided herein, Landlord shall have no obligation to rebuild or repair in case of fire or other casualty, and no termination under this Section shall affect any rights of Landlord or Tenant hereunder arising from the prior defaults of the other party. Tenant shall give Landlord immediate notice of any fire or other casualty in the Premises. Notwithstanding anything contained in this Section to the contrary, in no event shall Landlord be required to expend more funds in connection with the repair or restoration of the Premises than the amount received by Landlord from the proceeds of any insurance policies maintained by Landlord.
Destruction or Damage (a) If the Premises or the Building is partially damaged by fire, earthquake, other insured peril, or other act of God, Landlord shall repair the same at Landlord’s expense, subject to the provisions of this Article and provided such repairs can, in Landlord’s reasonable opinion, be made within sixty (60) days. During such repairs, this Lease shall remain in full force and effect, except that if there shall be damage to the Premises or the Building and such damage is not the result of the negligence or willful misconduct of Tenant, Tenant’s employees, agents, or invitees, Rent shall be abated for such portion of Premises and period of time as the Premises was unusable by Tenant, provided that such abated rent is a covered loss payable to Landlord under its insurance policy. (b) If in Landlord’s reasonable opinion the partially damaged Premises or the Building can be repaired, but not within sixty (60) days, the Landlord may elect, upon written notice to Tenant within thirty (30) days of such damages, to repair such damages over a longer time period and continue this Lease in full force and effect, subject to rent abatement as described in the foregoing paragraph. Landlord’s notice shall include a good faith estimate of the expected completion date of such repair based on the best information reasonably available to Landlord prior to sending the notice. In the event such repairs cannot be made within an additional sixty (60) days, Tenant shall have the option to terminate this Lease provided that written notice is given to Landlord within thirty (30) days of receipt of Landlord’s notice stated in this paragraph. (c) If the partially damaged Premises or the Building is to be repaired under this Article, Landlord at its sole cost and expense shall repair such damages to the Building, the Premises and the Tenant Improvements supplied by Landlord herein. Except in the event of Landlord’s gross negligence or willful misconduct or the extent that Landlord receives insurance proceeds therefor, Tenant shall be responsible for repairing and/or replacing any damage to Tenant’s equipment, furniture and fixtures, and other Alterations, additions and improvements made by Tenant to the Premises and the Building. (d) If in Landlord’s reasonable opinion, the Premises or the Building is totally or substantially destroyed (i.e. cannot be repaired within sixty (60) days and Landlord does not elect to repair anyway or Tenant elects to terminate as provided above) by fire or other casualty, this Lease shall terminate upon notice by Landlord.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement. (b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of: (i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or (ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election. (c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the ISO OATT.
Repair of Damage If the Premises shall be damaged by fire or other casualty, then Landlord shall proceed to repair and restore (subject to receipt of insurance proceeds) the Premises to its condition preceding the damage, subject to the provisions of this Article 10. Landlord shall have no liability to Tenant, and Tenant shall not be entitled to terminate this Lease, if such repairs and restoration are not in fact completed within Landlord's estimated time period, so long as Landlord shall have proceeded with reasonable due diligence. The Rent until such repairs shall be made shall be reduced in the proportion which the area of the part of the Premises which is not usable by Tenant bears to the total area of the Premises; provided, however, should Tenant reoccupy a portion of the Premises for the conduct of its business prior to the date such repairs are made, the Rent shall be reinstated with respect to such reoccupied portion of the Premises and shall be payable by Tenant from the date of such occupancy. Further, should Landlord, at its sole option, make available to Tenant, during the period of such repair, other space in the Building which is reasonably suitable for the temporary carrying on of Tenant's business, the Rent shall be reinstated with respect to such temporarily occupied space and shall be payable by Tenant from the date such space is occupied by Tenant. Whenever in this Article 10 reference is made to restoration of the Premises, (i) Tenant's obligation shall be as to all property within the Premises including Tenant's furniture, fixtures, equipment and other personal property, any and all Alterations, construction or other improvements made to the Premises by or on behalf of Tenant and any other leasehold improvements existing in the Premises on the date hereof, all of which shall be restored and replaced at Tenant's sole cost and expense and (ii) Landlord's obligation, if any, shall be as to the shell, which constitutes the structure of the Building and the mechanical, electrical, plumbing, air-conditioning and other building systems up to the point of connection into the Premises. Landlord's obligation to repair or rebuild, and Tenant's right to rent abatement, as described in this Article 10, are only effective provided the damage or destruction is not due to the intentional or negligent acts or omissions of Tenant, its agents, employees, licensees or invitees. During any period of Tenant's repair and restoration following substantial completion of a Landlord's repair and restoration work, Rent and additional rent shall be payable as if said fire or other casualty had not occurred.
Union Activity on Premises and/or Access to Premises The Union agrees that neither it, nor its officers, agents, representatives and members will engage in the solicitation of members, holding of meetings or any other Union activities on Hospital premises or on Hospital time without the prior approval of the Hospital, except as specifically provided for in this Agreement. Such approval will not be unreasonably denied.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral. (b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies. (c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in (i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
