DATE OF COMMENCEMENT AND COMPLETION OF THE SERVICES Sample Clauses

DATE OF COMMENCEMENT AND COMPLETION OF THE SERVICES. The [DMS/CPC] Non-Exhibit Services shall begin on _________________, proceeding diligently, until all Services have been completed, which date of completion shall be no later than ___________________.
Sample 1
AutoNDA by SimpleDocs
DATE OF COMMENCEMENT AND COMPLETION OF THE SERVICES. The [WPC/CPC] Non- Exhibit Services shall begin on ____________________, proceeding diligently, until all Services have been completed, which date of completion shall be no later than ________________________.
Sample 1

Related to DATE OF COMMENCEMENT AND COMPLETION OF THE SERVICES

  • COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein.

  • Commencement of Work Upon Contractor’s receipt from Owner of the limited notice to proceed (“Limited Notice to Proceed” or “LNTP”), Contractor shall promptly commence with the performance of the portion of the Work specified in such LNTP; provided that the Parties have executed a Change Order defining the LNTP Work. The LNTP shall be issued in the form attached hereto as Attachment H, Schedule H-1. Contractor shall not, and shall not be obligated to, commence performance of such Work until receipt from Owner of such LNTP.

  • Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.

  • Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

  • Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.

  • Litigation and Unilateral Commencement of Arbitration Notwithstanding the foregoing provisions of this Article VII, (a) a Party may seek preliminary provisional or injunctive judicial relief with respect to a Dispute without first complying with the procedures set forth in Section 7.1, Section 7.2 and Section 7.3 if such action is reasonably necessary to avoid irreparable damage and (b) either Party may initiate arbitration before the expiration of the periods specified in Section 7.2 and Section 7.3 if (i) such Party has submitted a Mediation Request or Arbitration Request, as applicable, and the other party has failed, within the applicable periods set forth in Section 7.3, to agree upon a date for the first mediation session to take place within thirty (30) days after the appointment of such mediator or such longer period as the Parties may agree to in writing or (ii) such Party has failed to comply with Section 7.3 in good faith with respect to commencement and engagement in arbitration. In such event, the other Party may commence and prosecute such arbitration unilaterally in accordance with the CPR Arbitration Procedure.

  • Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.

Time is Money Join Law Insider Premium to draft better contracts faster.