Construction Liens (a) Tenant will not suffer or permit any contractor’s, subcontractor’s or supplier’s lien (a “Construction Lien”) to be filed against the Premises or any part thereof by reason of work, labor services or materials supplied or claimed to have been supplied to Tenant; and if any Construction Lien shall at any time be filed against the Premises or any part thereof, Tenant, within ten (10) days after notice of the filing thereof, shall cause it to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If Tenant shall fail to cause such Construction Lien to be discharged within the period aforesaid, then in addition to any other right or remedy, Landlord may, but shall not be obligated to, discharge it either by paying the amount claimed to be due or by procuring the discharge of such lien by deposit or by bonding proceedings. Any amount so paid by Xxxxxxxx, plus all of Landlord’s costs and expenses associated therewith (including, without limitation, reasonable legal fees), shall constitute Additional Rent payable by Tenant under this Lease and shall be paid by Tenant to Landlord on demand with interest from the date of advance by Landlord at the Default Rate.
Project Financing Tenant acknowledges that as a material inducement to Landlord to execute this Lease, (i) Tenant shall timely acknowledge and deliver to Landlord all such documents and instruments as may be customarily those documents and instruments which may be required under Paragraph 16, and (iii) if any prospective lender to Landlord shall request or require in connection with the placement of any financing to Landlord or pursuant to the provisions of any Security Document any modification of this Lease, Tenant shall not delay or withhold its agreement to such proposed modification provided in the same shall not modify the Basic Annual Rent payable hereunder nor materially and adversely affect the obligations of Tenant hereunder. Tenant shall be responsible for any and all liability, loss, cost, damage and expense, including, without limitation, attorneys' fees, which Landlord shall incur in connection with Tenant's failure or delay in executing, acknowledging and delivering such documents and instrument or Tenant's breach of any other covenant or agreement embodied in this Lease that results in the delay, impairment or cancellation of such financing.
Construction Contract On each Borrowing Date, the Borrower shall have certified that all conditions and requirements under the Construction Contract required to be satisfied on such Borrowing Date, including in connection with the respective payment installments to be made to the Yard on such Borrowing Date, shall have been satisfied (including, but not limited to, the Borrower’s payment to the Yard of the portion of the payment installment on the Vessel that is not being financed with proceeds of the Loans), other than those that are not materially adverse to the Lenders, it being understood that any litigation between the Yard and the Parent and/or Borrower shall be deemed to be materially adverse to the Lenders.
Construction Contracts Lessee has entered into contracts with the Contractors or separate contracts with materialmen and laborers providing for the construction of the Improvements. Lessee will cause the Contractors to promptly furnish Lessor with the complete list of all Sub-contractors or entities as and when under contract, which Contractors propose to engage to furnish labor and/or materials in constructing the Improvements (such list containing the names, addresses, and amounts of such sub-contracts as written in excess individually of $5,000, and prior to disbursement of funds to or for the benefit of such Subcontractors, affidavits of authorized signatory and other documents commercially reasonably required by Title to insure that the Leased Premises remain lien free) and will from time to time furnish Lessor or Title with true copies of all Contracts entered into by Lessee and with the terms of all verbal agreements therefor, if any, and as to subcontractors, letters signed by sub-contractors whose contracts are in excess of $5,000 setting forth the present amount of their contract and the amounts remaining to be paid under that contract, if the same information is not stated on a lien waiver reflecting the most currently requested payment to such subcontractor.
Lease Modification Tenant agrees to modify this Lease in any way requested by a mortgagee which does not cause increased expense to Tenant or otherwise materially adversely affect Tenant's interests under this Lease.
Property Management Agreement The Property Management Agreement is in full force and effect and, to Borrower's Knowledge, there are no defaults thereunder by any party thereto and no event has occurred that, with the passage of time and/or the giving of notice would constitute a default thereunder.
Leasehold Financing Notwithstanding anything to the contrary contained in the Lease, Tenant shall have the right, without Landlord’s consent to encumber the leasehold estate created under the Lease and/or to grant a security interest in Tenant’s removable trade fixtures, furnishings and equipment located within the Leased Premises (but not to encumber Landlord’s fee interest in the Premises), to secure financing provided to Tenant by any bank, thrift institution, insurance company or other institutional lender. Tenant agrees to notify Landlord of any such encumbrance. With respect to any such leasehold financing (and provided that Tenant is not in default under the Lease beyond any applicable notice or cure period), upon thirty (30) days’ prior written request from Tenant, Landlord will execute and deliver to the secured lender a “Landlord’s Agreement” in the form attached hereto as Exhibit “A-1”.
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
LEASE OF EQUIPMENT Lessor leases to Lessee, and Lessee leases from Lessor, all the property described in the Lease Schedules which are signed from time to time by Lessor and Lessee.
Project The Land and all improvements thereon, including the Building, the Parking Facilities, and all Common Areas.
