Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the contractor, contractor's subcontractors, or their agents or employees.
Providing Notice of Breaches 8.1 If Covered Entity determines that an impermissible acquisition, access, use or disclosure of PHI for which one of Business Associate’s employees or agents was responsible constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity, Business Associate shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When requested to provide notice, Business Associate shall consult with Covered Entity about the timeliness, content and method of notice, and shall receive Covered Entity’s approval concerning these elements. The cost of notice and related remedies shall be borne by Business Associate.
8.2 If Covered Entity or Business Associate determines that an impermissible acquisition, access, use or disclosure of PHI by a Subcontractor of Business Associate constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity or Business Associate, Subcontractor shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When Covered Entity requests that Business Associate or its Subcontractor provide notice, Business Associate shall either 1) consult with Covered Entity about the specifics of the notice as set forth in section 8.1, above, or 2) require, by contract, its Subcontractor to consult with Covered Entity about the specifics of the notice as set forth in section 8.1
8.3 The notice to affected individuals shall be provided as soon as reasonably possible and in no case later than 60 calendar days after Business Associate reported the Breach to Covered Entity.
8.4 The notice to affected individuals shall be written in plain language and shall include, to the extent possible, 1) a brief description of what happened, 2) a description of the types of Unsecured PHI that were involved in the Breach, 3) any steps individuals can take to protect themselves from potential harm resulting from the Breach, 4) a brief description of what the Business Associate is doing to investigate the Breach, to mitigate harm to individuals and to protect against further Breaches, and 5) contact procedures for individuals to ask questions or obtain additional information, as set forth in 45 CFR § 164.404(c).
8.5 Business Associate shall notify individuals of Breaches as specified in 45 CFR § 164.404(d) (methods of individual notice). In addition, when a Breach involves more than 500 residents of Vermont, Business Associate shall, if requested by Covered Entity, notify prominent media outlets serving Vermont, following the requirements set forth in 45 CFR § 164.406.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.
Notice of Breaches The Company and the Purchaser shall give prompt written notice to the other of any breach by it of any representation, warranty or other agreement contained in any Transaction Document, as well as any events or occurrences arising after the date hereof, which would reasonably be likely to cause any representation or warranty or other agreement of such party, as the case may be, contained in the Transaction Document to be incorrect or breached as of such Closing Date. However, no disclosure by either party pursuant to this Section shall be deemed to cure any breach of any representation, warranty or other agreement contained in any Transaction Document. Notwithstanding the generality of the foregoing, the Company shall promptly notify the Purchaser of any notice or claim (written or oral) that it receives from any lender of the Company to the effect that the consummation of the transactions contemplated by the Transaction Documents violates or would violate any written agreement or understanding between such lender and the Company, and the Company shall promptly furnish by facsimile to the holders of the Debentures a copy of any written statement in support of or relating to such claim or notice.
Notice, Etc A Party required to make an indemnification payment pursuant to this Agreement (“Indemnifying Party”) shall have no liability with respect to Third Party Claims or otherwise with respect to any covenant, representation, warranty, agreement, undertaking or obligation under this Agreement unless the Party entitled to receive such indemnification payment (“Indemnified Party”) gives notice to the Indemnifying Party specifying (i) the covenant, representation or warranty, agreement, undertaking or obligation contained herein which it asserts has been breached, (ii) in reasonable detail, the nature and dollar amount (or estimate, if the magnitude of the Claim cannot be precisely determined at that time) of any Claim the Indemnified Party may have against the Indemnifying Party by reason thereof under this Agreement, and (iii) whether or not the Claim is a Third Party Claim. With respect to Third Party Claims, an Indemnified Party (i) shall give the Indemnifying Party prompt notice of any Third Party Claim, (ii) prior to taking any action with respect to such Third Party Claim, shall consult with the Indemnifying Party as to the procedure to be followed in defending, settling, or compromising the Third Party Claim, (iii) shall not consent to any settlement or compromise of the Third Party Claim without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed), and (iv) shall permit the Indemnifying Party, if it so elects, to assume the exclusive defense of such Third Party Claim (including, except as provided in the penultimate sentence of this Section, the compromise or settlement thereof) at its own cost and expense. If the Indemnifying Party shall elect to assume the exclusive defense of any Third Party Claim pursuant to this Agreement, it shall notify the Indemnified Party in writing of such election, and the Indemnifying Party shall not be liable hereunder for any fees or expenses of the Indemnified Party’s counsel relating to such Third Party Claim after the date of delivery to the Indemnified Party of such notice of election. The Indemnifying Party will not compromise or settle any such Third Party Claim without the written consent of the Indemnified Party (which consent shall not be unreasonably withheld or delayed) if the relief provided is other than monetary damages or such relief would have a Material Adverse Effect on the Indemnified Party. Notwithstanding the foregoing, if the Indemnifying Party elects to assume the defense with respect to any Third Party Claim, the Indemnifying Party shall have the right to compromise or settle for solely monetary damages such Third Party Claim, provided such settlement will not result in or have a Material Adverse Effect on the Indemnified Party. Notwithstanding the foregoing, the Party which defends any Third Party Claim shall, to the extent required by any insurance policies of the Indemnified Party, share or give control thereof to any insurer with respect to such Claim.
Environmental Notice Promptly after the assertion or occurrence thereof, notice of any action or proceeding against or of any noncompliance by any Loan Party or any of its Subsidiaries with any Environmental Law or Environmental Permit that could reasonably be expected to have a Material Adverse Effect.
Notice to Purchaser DO NOT SIGN THIS CONTRACT UNTIL YOU READ IT OR IF IT CONTAINS BLANK SPACES.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
