Delay by the Operator Sample Clauses

Delay by the Operator. In the event of non-fulfilment in full by the Operator of any of the Conditions Precedent contemplated in Clause 4.2 within the stipulated time period or within such extended time that the Parties have agreed upon, and provided such Conditions Precedent has not been waived through mutual agreement of the Parties, then: a. The Authority shall have the right to: (A) refuse handing over of 11 Sidhi Lawn, in respect of which the Conditions Precedents have not been satisfied; or (B) take over the possession of 11 Sidhi Lawn in relation to which have already been handed by the Operator but in respect of which the conditions precedent have not been satisfied; until the fulfilment of the Conditions Precedent by the Authority to its satisfaction; and b. the Operator shall pay to the Authority damages that shall be calculated at twice of the daily rate payable by the operator for each day of delay until the fulfilment of the Conditions Precedent, c. In the event the Conditions Precedent are not fulfilled by the Operator and the Operator has paid damages to the Authority to the maximum of [20%] of the Security Deposit then the Authority may terminate the Agreement in accordance with the terms contained herein.
Sample 1
AutoNDA by SimpleDocs
Delay by the Operator. 4.5.3.1 In the event of non fulfilment in full by the Operator of any of the Conditions Precedent contemplated in Clause 4.2 within the stipulated time period or within such extended time that the Parties have agreed upon, and provided such 19Drafting Note: Authority to specify. 20Drafting Note: Authority to specify. 21Drafting Note: Authority to specify. Conditions Precedent has not been waived through mutual agreement of the Parties, then: a. the Authority shall have the right to: (A) refuse handing over of Contracted Buses, in respect of which the Conditions Precedents have not been satisfied; or (B) take over the possession of Contracted Buses in relation to such Contracted Buses which have already been handed by the Operator but in respect of which the conditions precedent have not been satisfied; until the fulfilment of the Conditions Precedent by the Authority to its satisfaction; and b. the Operator shall pay to the Authority damages that shall be calculated at the rate of [0.2%] 22 of the Performance Security for each day of delay until the fulfilment of the Conditions Precedent, subject to a maximum of [20%]23 of the Performance Security. 4.5.3.2 In the event the Conditions Precedent are not fulfilled by the Operator and the Operator has paid damages to the Authority to the maximum of [20%]24 of the Performance Security as provided in Clause 4.2.1 damages to the maximum of [20%]25, then the Authority may terminate the Agreement in accordance with the terms contained herein.
Sample 1

Related to Delay by the Operator

  • Partial Terminations by the Purchasers In the event so instructed by the Purchasers in writing after the Closing Date and at the Purchasers’ sole expense, each Seller shall execute documents prepared by the Purchasers and reasonably acceptable to such Seller resigning or appointing a successor Appointed Trustee under any Serviced Appointment for which such Seller acts as Appointed Trustee (other than with respect to any Serviced Appointment that is an Excluded Appointment), and shall reasonably cooperate, at the Purchasers’ sole expense, as instructed by the Purchasers, in finding a qualified successor Appointed Trustee, including executing any documents prepared by the Purchasers in connection with the application to a court of competent jurisdiction to appoint a successor Appointed Trustee.

  • TERMINATION BY THE OWNER The Owner may terminate this Contract in accordance with the following terms and conditions: (A) The Owner may, for any reason whatsoever, terminate performance under this Contract by the Contractor for convenience. The Owner shall give written notice of such termination to the Contractor specifying when termination becomes effective. The Contractor shall incur no further obligations in connection with the work and the Contractor shall stop work when such termination becomes effective. The Contractor shall also terminate outstanding orders and subcontracts. The Contractor shall settle the liabilities and claims arising out of the termination of subcontracts and orders. The Owner may direct the Contractor to assign the Contractor's right, title and interest under termination orders or subcontracts to the Owner or its designee. The Contractor shall transfer title and deliver to the Owner such completed or partially completed work and materials, equipment, parts, fixtures, information and Contract rights as the Contractor has. When terminated for convenience, the Contractor shall be compensated as follows: (1) The Contractor shall submit a termination claim to the Owner specifying the amounts due because of the termination for convenience together with costs, pricing or other data required by the Owner. If the Contractor fails to file a termination claim within one (1) year from the effective date of termination, the Owner shall pay the Contractor, an amount derived in accordance with Subparagraph (3) below; (2) The Owner and the Contractor may agree to the compensation, if any, due to the Contractor hereunder; (3) Absent agreement to the amount due to the Contractor, the Owner shall pay the Contractor the following amounts: (a) Contract prices for labor, materials, equipment and other services accepted under this Contract; (b) Reasonable costs incurred in preparing to perform and in performing the terminated portion of the work, and in terminating the Contractor's performance, plus a fair and reasonable allowance for direct jobsite overhead and profit thereon (such profit shall not include anticipated profit or consequential damages); provided however, that if it appears that the Contractor would have not profited or would have sustained a loss if the entire Contract would have been completed, no profit shall be allowed or included and the amount of compensation shall be reduced to reflect the anticipated rate of loss, if any; (c) Reasonable costs of settling and paying claims arising out of the termination of subcontracts or orders pursuant to Subparagraph 19(A) of this Paragraph. These costs shall not include amounts paid in accordance with other provisions hereof. The total sum to be paid the Contractor under this Subparagraph 19(A) shall not exceed the total Contract Price, as properly adjusted, reduced by the amount of payments otherwise made, and shall in no event include duplication of payment. (B) If the Contractor does not perform the work, or any part thereof, in a timely manner, supply adequate labor, supervisory personnel or proper equipment or materials, or if it fails to timely discharge its obligations for labor, equipment and materials, or proceeds to disobey applicable law, or otherwise commits a violation of a material provision of this Contract, then the Owner, in addition to any other rights it may have against the Contractor or others, may terminate the performance of the Contractor and assume possession of the Project site and of all materials and equipment at the site and may complete the work. In such case, the Contractor shall not be paid further until the work is complete. After final completion has been achieved, if any portion of the Contract Price, as it may be modified hereunder, remains after the cost to the Owner of completing the work, including all costs and expenses of every nature incurred, has been deducted by the Owner, such remainder shall belong to the Contractor. Otherwise, the Contractor shall pay and make whole the Owner for such cost. This obligation for payment shall survive the termination of the Contract. In the event the employment of the Contractor is terminated by the Owner for cause pursuant to this Subparagraph 19(B) and it is subsequently determined by a Court of competent jurisdiction that such termination was without cause, such termination shall thereupon be deemed a Termination for Convenience under Subparagraph 19(A) and the provisions of Subparagraph 19(A) shall apply.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Termination by the Manager This Agreement may be terminated by the Manager if: (a) the Resident fails to check into their assigned Room within five (5) days of the first day of the Semester; (b) the Resident abandons their Room as detailed in section 8.03 of this Agreement; (c) the Resident decides not to accept the Room they were assigned, or any alternate rooms offered to them during the course of this Agreement; or (d) the Resident violates any of the terms of this Agreement, including violations of the Residence Community Living Standards or Institution Standards. Written Notice of Termination of Residency will be delivered to the Resident, and if necessary, the Manager may notify the Primary or Secondary Contact by phone or e-mail of the termination of the Resident’s residency. If the Resident is unavailable to receive service of the notice in person, then delivery of the notice to the Resident’s Room shall be deemed proper service and delivery. The Resident will be allowed 24 hours from the date and time of delivery of the Notice of Termination of Residency to fully vacate and remove all personal belongings from the Residence.

  • Clean-Up Terminations by the Sellers (a) The Sellers shall have the right to elect to terminate this Agreement in the event that the remaining Serviced Appointments have generated LTM Fee Revenue that is less than 5% of the aggregate fee revenue generated by all Appointments that are Serviced Appointments as of January 1, 2024 in the twelve-month period prior to January 1, 2024. (b) In the event the Sellers elect to terminate this Agreement pursuant to clause (a) above, the Sellers shall, concurrently with such termination, pay to the Purchasers an amount equal to LTM Fee Revenue multiplied by 1.40. (c) For purposes of this Agreement, “LTM Fee Revenue” means the fee revenue (excluding net interest income but including money market fund fees) generated by all remaining Serviced Appointments in the last full twelve-month period prior to the time the Sellers elect to exercise their termination right pursuant to this Section 7.2.2.

  • EXPENSES BORNE BY THE MANAGER The Manager will pay: (a) The compensation and expenses of all officers and executive employees of the Fund; (b) The compensation and expenses of all directors of the Fund who are persons affiliated with the Manager; and (c) The expenses of the organization of the Fund, including its registration under the Investment Company Act of 1940, and the initial registration and qualification of its Capital Stock for sale under the Securities Act of 1933 and the Blue Sky laws of the states in which it initially qualifies.

  • Termination by the Owner for Cause § 16.2.1 The Owner may terminate the Contract if the Contractor .1 repeatedly refuses or fails to supply enough properly skilled workers or proper materials;

  • Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.

  • For Cause by the Company The Company may terminate the Employee's employment hereunder for cause immediately and with prompt notice to the Employee, which cause shall be determined in good faith solely by the Board of Directors. "Cause" for termination shall include, but is not limited to, the following conduct of the Employee:

  • Maintenance by the Manager Throughout the Term the Manager will inspect, maintain, repair and replace elements of the Residence in order to keep the Residence in a good condition and state of repair, complying with health, safety and fire standards required by law. This includes, but is not limited to, inspecting and testing fire safety equipment, major appliances, electrical, bathroom fixtures and plumbing.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!