DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for an initial one (1) year period. A price escalation/de-escalation will be considered at one (1) year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the effective date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% % of Change x 100 = Percentage Change CPI-U Calculation Example: A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.
Aircraft Basic Price The Aircraft Basic Price is listed in Table 1 and is subject to escalation in accordance with the terms of this Purchase Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Data Universal Number System (DUNS) number Requirement Grantee will provide their valid DUNS number contemporaneous with execution of this Agreement.
Commercial Price List Reductions Where NYS Net Prices are based on a discount from Contractor’s list prices, price decreases shall take effect automatically during the Contract term and apply to Purchase Orders submitted on or after the date Contractor lowers its pricing to its customers generally or to similarly situated government customers during the Contract term; or
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.
DELIVERY SCHEDULES In accordance with the "Non-State Agencies Participation in Centralized Contracts” and “Extension of Use” clauses herein, this Contract is extended to local governments, political subdivisions and others authorized by law as well as State agencies. The Delivery Schedules (based on Requirement Letter RL182) are available as a guide to indicate proposed delivery points and estimated annual requirements. Delivery Schedules may be revised or clarified as necessary. Any specific questions regarding the site conditions should be directed to the end-user at the telephone number shown on the Delivery Schedule. The Delivery Schedules are available upon request. Contractors shall be obligated to deliver under the Contract to any State agency which places a purchase order under the Contract, whether or not such delivery location is identified in the Delivery Schedules. Any political subdivision or other non-State entity which has not filed a requirement with OGS as of the date of the bid opening shall be eligible to receive deliveries at Contractor's option only, upon placement of a valid purchase order to the Contractor's address as indicated in the award. Contracts created by OGS in response to receipt of Filed Requirements are considered to be binding. At Contractor's request, Contractor will be advised in writing regarding political subdivisions or other Non-State entities which have filed on a timely basis but do not appear on the Delivery Schedule. Where “Standby” is indicated in the Delivery Schedule, this reflects those facilities which normally use a fuel supply (i.e. natural gas) other than fuel oil and will only use fuel oil when alternate fuel is unavailable.
