Delivery Date the date (or period) for delivery of the Goods or Services as specified and agreed in the Contract.
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
DATE OF DELIVERY OF PUT NOTICE A Put Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by Investor if such notice is received on or prior to 12:00 noon New York time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon New York time on a Trading Day or at anytime on a day which is not a Trading Day.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Delivery Time Vendors shall specify the estimated delivery time in calendar days for each item. The purchaser should consult the vendor regarding vehicle production schedules. Delivery shall be within the normal working hours of the user, Monday through Friday, excluding holidays.
DELIVERY OUT The Custodian shall release and deliver out domestic securities and other financial assets of a Portfolio held in a U.S. Securities System, or in an account at the Underlying Transfer Agent, only upon receipt of Proper Instructions on behalf of the applicable Portfolio, specifying the domestic securities or financial assets held in the United States to be delivered out and the person or persons to whom delivery is to be made. The Custodian shall pay out cash of a Portfolio upon receipt of Proper Instructions on behalf of the applicable Portfolio, specifying the amount of the payment and the person or persons to whom the payment is to be made.
Share Delivery Delivery of any shares in connection with settlement of the Award will be by book-entry credit to an account in the Grantee’s name established by the Company with the Company’s transfer agent, or upon written request from the Grantee (or his personal representative, beneficiary or estate, as the case may be), in certificates in the name of the Grantee (or his personal representative, beneficiary or estate).
Delivery of Documents; Delivery Dates (a) The Trustee is hereby directed (i) to execute and deliver the Intercreditor Agreement, the Escrow Agreement and the NPA on or prior to the Issuance Date, each in the form delivered to the Trustee by the Company, and (ii) subject to the respective terms thereof, to perform its obligations thereunder. Upon request of the Company and the satisfaction or waiver of the closing conditions specified in the Underwriting Agreement, the Trustee shall execute, deliver, authenticate, issue and sell Applicable Certificates in authorized denominations equaling in the aggregate the amount set forth, with respect to the Applicable Trust, in Schedule I to the Underwriting Agreement evidencing the entire ownership interest in the Applicable Trust, which amount equals the maximum aggregate principal amount of Equipment Notes which may be purchased by the Trustee pursuant to the NPA. Except as provided in Sections 3.03, 3.04, 3.05 and 3.06 of the Basic Agreement, the Trustee shall not execute, authenticate or deliver Applicable Certificates in excess of the aggregate amount specified in this paragraph. The provisions of this Section 5.01(a) supersede and replace the first sentence of Section 3.02(a) of the Basic Agreement, with respect to the Applicable Trust.
(b) After the Issuance Date, the Company may deliver from time to time to the Trustee a Closing Notice relating to one or more Equipment Notes. After receipt of a Closing Notice and in any case no later than one Business Day prior to a Scheduled Closing Date as to which such Closing Notice relates (the “Applicable Closing Date”), the Trustee shall (as and when specified in the Closing Notice) instruct the Escrow Agent to provide a Notice of Purchase Withdrawal to the Depositary requesting (A) the withdrawal of one or more Deposits on the Applicable Closing Date in accordance with and to the extent permitted by the terms of the Escrow Agreement and the Deposit Agreement and (B) the payment of all, or a portion, of such Deposit or Deposits in an amount equal in the aggregate to the purchase price of such Equipment Notes to or on behalf of the Company, all as shall be described in the Closing Notice. The Trustee shall (as and when specified in such Closing Notice), subject to the conditions set forth in Section 2 of the NPA, enter into and perform its obligations under the Participation Agreement specified in such Closing Notice (the “Applicable Participation Agreement”) and cause such certificates, documents and legal opinions relating to the Trustee to be duly delivered as required by the Applicable Participation Agreement. If at any time prior to the Applicable Closing Date, the Trustee receives a notice of postponement pursuant to Section 1(e) or 1(f) of the NPA, then the Trustee shall give the Depositary (with a copy to the Escrow Agent) a notice of cancellation of such Notice of Purchase Withdrawal relating to such Deposit or Deposits on such Applicable Closing Date. Upon satisfaction of the conditions specified in the NPA and the Applicable Participation Agreement, the Trustee shall purchase the applicable Equipment Notes with the proceeds of the withdrawals of one or more Deposits made on the Applicable Closing Date in accordance with the terms of the Deposit Agreement and the Escrow Agreement. The purchase price of such Equipment Notes shall equal the principal amount of such Equipment Notes. Amounts withdrawn from such Deposit or Deposits in excess of the purchase price of the Equipment Notes or to the extent not applied on the Applicable Closing Date to the purchase price of the Equipment Notes, shall be re-deposited by the Trustee with the Depositary on the Applicable Closing Date in accordance with the terms of the Deposit Agreement. The provisions of this Section 5.01(b) supersede and replace the provisions of Section 2.02 of the Basic Agreement with respect to the Applicable Trust, and all provisions of the Basic Agreement relating to Postponed Notes and Section 2.02 of the Basic Agreement shall not apply to the Applicable Trust.
(c) The Trustee acknowledges its acceptance of all right, title and interest in and to the Trust Property to be acquired pursuant to Section 5.01(b) of this Trust Supplement, the NPA and each Applicable Participation Agreement, and declares that it holds and will hold such right, title and interest for the benefit of all present and future Applicable Certificateholders, upon the trusts set forth in the Agreement. By its acceptance of an Applicable Certificate, each initial Applicable Certificateholder, as a grantor of the Applicable Trust, joins with the Trustee in the creation of the Applicable Trust. The provisions of this Section 5.01(c) supersede and replace the provisions of Section 2.03 of the Basic Agreement, with respect to the Applicable Trust.
Delivery of Unlegended Shares (a) Within seven business days (such seventh business day being the “Unlegended Shares Delivery Date”) after the business day on which the Company has received (i) a notice that Shares or Warrant Shares, or any other Common Stock held by a Subscriber have been sold pursuant to a registration statement, if any, or Rule 144, (ii) a representation that the prospectus delivery requirements, or the requirements of Rule 144, as applicable and if required, have been satisfied, (iii) the original share certificates representing the shares of Common Stock that have been sold, and (iv) in the case of sales under Rule 144, customary representation letters of the Subscriber and/or a Subscriber’s broker regarding compliance with the requirements of Rule 144, the Company at its expense, (y) shall deliver, and shall cause legal counsel selected by the Company to deliver to its transfer agent (with copies to Subscriber) an appropriate instruction and opinion of such counsel, directing the delivery of shares of Common Stock without any legends including the legend set forth in Section 4(i) above (the “Unlegended Shares”); and (z) cause the transmission of the certificates representing the Unlegended Shares together with a legended certificate representing the balance of the submitted certificate, if any, to the Subscriber at the address specified in the notice of sale, via express courier, by electronic transfer or otherwise on or before the Unlegended Shares Delivery Date. In the event that the Shares are sold in a manner that complies with an exemption from registration, the Company will promptly instruct its counsel to issue to the Company’s transfer agent an opinion permitting removal of the legend indefinitely if pursuant to Rule 144(b)(1).
(b) In lieu of delivering physical certificates representing the Unlegended Shares, upon request of a Subscriber, so long as the certificates therefor do not bear a legend and the Subscriber is not obligated to return such certificate for the placement of a legend thereon, the Company will cause its transfer agent to electronically transmit the Unlegended Shares by crediting the account of Subscriber’s prime broker with the Depository Trust Company through its Deposit Withdrawal Agent Commission system, if such transfer agent participates in such DWAC system. Such delivery must be made on or before the Unlegended Shares Delivery Date.
(c) The Company understands that a delay in the delivery of the Unlegended Shares pursuant to Section 11 hereof later than the Unlegended Shares Delivery Date could result in economic loss to a Subscriber. As compensation to a Subscriber for such loss, the Company agrees to pay late payment fees (as liquidated damages and not as a penalty) to the Subscriber for late delivery of Unlegended Shares in the amount of $100 per business day after the Delivery Date for each $10,000 of purchase price of the Unlegended Shares subject to the delivery default. In the event damages are payable pursuant to the foregoing sentence, then the Subscriber may elect to receive liquidated damages under this Section 11.1(c) or Section 12(g) below. If during any 360 day period, the Company fails to deliver Unlegended Shares as required by this Section 11.1 for an aggregate of 30 days, then each Subscriber or assignee holding Securities subject to such default may, at its option, require the Company to redeem all or any portion of the Shares and Warrant Shares subject to such default at a price per share equal to the greater of (i) 120%, or (ii) a fraction in which the numerator is the highest closing price of the Common Stock during the aforedescribed 30 day period and the denominator of which is the purchase price of the Shares or exercise price of such Warrant Shares during such 30 day period, multiplied by the purchase price of the Shares or exercise price of such Warrant Shares (“Unlegended Redemption Amount”). The Company shall pay any payments incurred under this Section in immediately available funds upon demand.
(d) In addition to any other rights available to a Subscriber, if the Company fails to deliver to a Subscriber Unlegended Shares as required pursuant to this Agreement, within three business days after the Unlegended Shares Delivery Date and the Subscriber or a broker on the Subscriber’s behalf, purchases (in an open market transaction or otherwise) shares of common stock to deliver in satisfaction of a sale by such Subscriber of the shares of Common Stock which the Subscriber was entitled to receive from the Company (a "Buy-In"), then the Company shall pay in cash to the Subscriber (in addition to any remedies available to or elected by the Subscriber) the amount by which (A) the Subscriber's total purchase price (including brokerage commissions, if any) for the shares of Common Stock so purchased exceeds (B) the aggregate purchase price of the shares of Common Stock delivered to the Company for reissuance as Unlegended Shares together with interest thereon at a rate of 15% per annum accruing until such amount and any accrued interest thereon is paid in full (which amount shall be paid as liquidated damages and not as a penalty). For example, if a Subscriber purchases shares of Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to $10,000 of purchase price of shares of Common Stock delivered to the Company for reissuance as Unlegended Shares, the Company shall be required to pay the Subscriber $1,000, plus interest. The Subscriber shall provide the Company written notice indicating the amounts payable to the Subscriber in respect of the Buy-In.
(e) In the event a Subscriber shall request delivery of Unlegended Shares as described in Section 11.1 or Warrant Shares upon exercise of Warrants and the Company is required to deliver such Unlegended Shares pursuant to Section 11.1 or the Warrant Shares pursuant to the Warrant, the Company may not refuse to deliver Unlegended Shares or Warrant Shares based on any claim that such Subscriber or any one associated or affiliated with such Subscriber has been engaged in any violation of law, or for any other reason, unless, an injunction or temporary restraining order from a court, on notice, restraining and or enjoining delivery of such Unlegended Shares or exercise of all or part of said Warrant shall have been sought and obtained by the Company or at the Company’s request or with the Company’s assistance, and the Company has posted a surety bond for the benefit of such Subscriber in the amount of 120% of the amount of the aggregate purchase price of the Shares and Warrant Shares which are subject to the injunction or temporary restraining order, which bond shall remain in effect until the final unappealable disposition of the litigation of the dispute and the proceeds of which shall be payable to such Subscriber to the extent Subscriber obtains judgment in Subscriber’s favor.
Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.
