Delivery Rejection Sample Clauses

Delivery Rejection. The State of Maine reserves the right to reject or refuse any salt or deliveries which do not conform to these specifications for screen size, chemical quality or moisture content, or which are not delivered in good condition. Shipments that are rejected will be returned to the Contractor at no cost to the state. Contractor shall promptly replace all deliveries of salt that are rejected.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Delivery Rejection. The State of Maine/Municipalities reserves the right to reject or refuse any salt or deliveries which do not conform to these specifications for screen size, chemical quality or moisture content, or which are not delivered in good condition. Shipments that are rejected will be returned to the Contractor at no cost to the state. Contractor shall promptly replace all deliveries of salt that are rejected. Invoicing: Separate invoices are required for each order number. Invoices shall include the stockpile location the order is taken from. Each load is to be listed separately with the date delivered on the invoice. Partial orders will not be paid for unless the State has over-ordered for a particular location. Matching delivery slip numbers for each order should be included on the invoice. Invoices received with the delivery slip numbers will be processed prior to invoices without delivery slip numbers.
Sample 1Sample 2
Delivery Rejection. The State of Maine reserves the right to reject or refuse any salt or deliveries which do not conform to these specifications for screen size, chemical quality or moisture content, or which are not delivered in good condition. Shipments that are rejected will be returned to the Contractor at no cost to the state. Contractor shall promptly replace all deliveries of salt that are rejected. Invoicing: Separate invoices are required for each order number. Invoices shall include the stockpile location the order is taken from. Each load is to be listed separately with the date delivered on the invoice. Partial orders will not be paid for unless the State has over-ordered for a particular location. Matching delivery slip numbers for each order should be included on the
Sample 1
Delivery Rejection 
Sample 1Sample 2Sample 3

Related to Delivery Rejection

  • No Transmission Delivery Service The execution of this Agreement does not constitute a request for, nor agreement to provide, any Transmission Service under the NYISO OATT, and does not convey any right to deliver electricity to any specific customer or Point of Delivery. If Developer wishes to obtain Transmission Service on the New York State Transmission System, then Developer must request such Transmission Service in accordance with the provisions of the NYISO OATT.

  • Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.

  • Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.

  • Response to Demand Letter Within 10 days after the receipt of the Demand Letter, RMC shall either: (a) cure the breach to OIG’s satisfaction and pay the applicable Stipulated Penalties or (b) request a hearing before an HHS administrative law judge (ALJ) to dispute OIG’s determination of noncompliance, pursuant to the agreed upon provisions set forth below in Section X.E. In the event RMC elects to request an ALJ hearing, the Stipulated Penalties shall continue to accrue until RMC cures, to OIG’s satisfaction, the alleged breach in dispute. Failure to respond to the Demand Letter in one of these two manners within the allowed time period shall be considered a material breach of this CIA and shall be grounds for exclusion under Section X.D.

  • ODUF Pack Rejection 6.4.1 Image Access will notify BellSouth within one (1) business day of rejected packs (via the mutually agreed medium). Packs could be rejected because of pack sequencing discrepancies or a critical edit failure on the Pack Header or Pack Trailer records (e.g., out-of-balance condition on grand totals, invalid data populated). Standard ATIS EMI error codes will be used. Image Access will not be required to return the actual rejected data to BellSouth. Rejected packs will be corrected and retransmitted to Image Access by BellSouth.

  • ACCEPTANCE AND REJECTION a. Buyer shall accept the Services or give Seller notice of rejection within a reasonable time after the date of delivery. No payment, prior test, inspection, passage of title, any failure or delay in performing any of the foregoing, or failure to discover any defect or other nonconformance shall relieve Seller of any obligations under this Contract or impair any rights or remedies of Buyer. b. If Seller delivers defective or non-conforming Services, Buyer may at its option and at Seller's expense: (i) require Seller to promptly reperform, correct or replace the Services; (ii) correct the Services; or (iii) obtain replacement Services from another source. Return to Seller of defective or non-conforming Services and redelivery to Buyer of corrected or replaced Services shall be at Seller's expense. c. Seller shall not redeliver corrected or rejected Services without disclosing the former rejection or requirement for correction. Seller shall disclose any corrective action taken. All repair, replacement and other correction and redelivery shall be completed as Buyer may reasonably direct.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • Transmission Delivery Service Implications Under ER Interconnection Service, Interconnection Customer will be eligible to inject power from the Generating Facility into and deliver power across the Transmission System on an “as available” basis up to the amount of MW identified in the applicable stability and steady state studies to the extent the upgrades initially required to qualify for ER Interconnection Service have been constructed. After that date FERC makes effective MISO’s Energy Market Tariff filed in Docket No. ER04-691-000, Interconnection Customer may place a bid to sell into the market up to the maximum identified Generating Facility output, subject to any conditions specified in the Interconnection Service approval, and the Generating Facility will be dispatched to the extent the Interconnection Customer’s bid clears. In all other instances, no transmission or other delivery service from the Generating Facility is assured, but Interconnection Customer may obtain Point-To-Point Transmission Service, Network Integration Transmission Service or be used for secondary network transmission service, pursuant to the Tariff, up to the maximum output identified in the stability and steady state studies. In those instances, in order for Interconnection Customer to obtain the right to deliver or inject energy beyond the Point of Interconnection or to improve its ability to do so, transmission delivery service must be obtained pursuant to the provisions of the Tariff. The Interconnection Customer’s ability to inject its Generating Facility output beyond the Point of Interconnection, therefore, will depend on the existing capacity of the Transmission or Distribution System as applicable, at such time as a Transmission Service request is made that would accommodate such delivery. The provision of Firm Point-To-Point Transmission Service or Network Integration Transmission Service may require the construction of additional Network or Distribution Upgrades.

  • Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.

  • Pack Rejection 6.4.1 <<customer_name>> will notify BellSouth within one business day of rejected packs (via the mutually agreed medium). Packs could be rejected because of pack sequencing discrepancies or a critical edit failure on the Pack Header or Pack Trailer records (i.e. out-of-balance condition on grand totals, invalid data populated). Standard ATIS EMI Error Codes will be used. <<customer_name>> will not be required to return the actual rejected data to BellSouth. Rejected packs will be corrected and retransmitted to <<customer_name>> by BellSouth.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!