Deposit of Moneys Acquisition of the Improvements Sample Clauses

Open Split View

Download

Share

Cite

Deposit of Moneys Acquisition of the Improvements 

Sample 1Sample 2Sample 3See All (4)

Save

Copy

Related to Deposit of Moneys Acquisition of the Improvements

• Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.

• Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on

• Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.

• Remedies; Disposition of the Collateral If any Event of Default shall have occurred and be continuing, then any Collateral repossessed by the Collateral Agent under or pursuant to Section 7.1 hereof and any other Collateral whether or not so repossessed by the Collateral Agent, may be sold, assigned, leased or otherwise disposed of under one or more contracts or as an entirety, and without the necessity of gathering at the place of sale the property to be sold, and in general in such manner, at such time or times, at such place or places and on such terms as the Collateral Agent may, in compliance with any mandatory requirements of applicable law, determine to be commercially reasonable. Any of the Collateral may be sold, leased or otherwise disposed of, in the condition in which the same existed when taken by the Collateral Agent or after any overhaul or repair at the expense of the relevant Assignor which the Collateral Agent shall determine to be commercially reasonable. Any such disposition which shall be a private sale or other private proceedings permitted by such requirements shall be made upon not less than 10 days' prior written notice to the relevant Assignor specifying the time at which such disposition is to be made and the intended sale price or other consideration therefor, and shall be subject, for the 10 days after the giving of such notice, to the right of the relevant Assignor or any nominee of such Assignor to acquire the Collateral involved at a price or for such other consideration at least equal to the intended sale price or other consideration so specified. Any such disposition which shall be a public sale permitted by such requirements shall be made upon not less than 10 days' prior written notice to the relevant Assignor specifying the time and place of such sale and, in the absence of applicable requirements of law, shall be by public auction (which may, at the Collateral Agent's option, be subject to reserve), after publication of notice of such auction (where required by applicable law) not less than 10 days prior thereto. The Collateral Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for the sale, and such sale may be made at any time or place to which the sale may be so adjourned. To the extent permitted by any such requirement of law, the Collateral Agent may bid for and become the purchaser of the Collateral or any item thereof, offered for sale in accordance with this Section without accountability to the relevant Assignor. If, under mandatory requirements of applicable law, the Collateral Agent shall be required to make disposition of the Collateral within a period of time which does not permit the giving of notice to the relevant Assignor as hereinabove specified, the Collateral Agent need give such Assignor only such notice of disposition as shall be reasonably practicable in view of such mandatory requirements of applicable law. Each Assignor agrees to do or cause to be done all such other acts and things as may be reasonably necessary to make such sale or sales of all or any portion of the Collateral valid and binding and in compliance with any and all applicable laws, regulations, orders, writs, injunctions, decrees or awards of any and all courts, arbitrators or governmental instrumentalities, domestic or foreign, having jurisdiction over any such sale or sales, all at such Assignor's expense.

• Title, Conservation and Disposition of REO Property (a) This Section shall apply only to REO Properties acquired for the account of the Trustee for the benefit of the Certificateholders and shall not apply to any REO Property relating to a Mortgage Loan which was purchased or repurchased from the Trustee pursuant to any provision hereof. In the event that title to any such REO Property is acquired, the applicable Servicer shall cause the deed or certificate of sale to be issued in the name of the Trustee, on behalf of the Certificateholders, or the Trustee's nominee. (b) Each Servicer shall manage, conserve, protect and operate each REO Property for the Trustee for the benefit of the Certificateholders solely for the purpose of its prompt disposition and sale. Each Servicer, either itself or through an agent selected by such Servicer, shall manage, conserve, protect and operate the REO Property in the same manner that it manages, conserves, protects and operates other foreclosed property for its own account, and in the same manner that similar property in the same locality as the REO Property is managed. Each Servicer shall attempt to sell the same (and may temporarily rent the same for a period not greater than one year, except as otherwise provided below) on such terms and conditions as such Servicer deems to be in the best interest of the Master Servicer. Each Servicer shall notify the Master Servicer from time to time as to the status of each REO Property. (c) Each Servicer shall use its best efforts to dispose of the REO Property as soon as possible (subject to the Master Servicer's right to veto any proposed sale of REO Property) and shall sell such REO Property in any event within three years after title has been taken to such REO Property, unless such Servicer determines, and gives an appropriate notice to the Trustee and the Master Servicer to such effect, that a longer period is necessary for the orderly liquidation of such REO Property. If a period longer than three years is permitted under the foregoing sentence and is necessary to sell any REO Property, such Servicer shall report monthly to the Securities Administrator and the Master Servicer as to the progress being made in selling such REO Property. Notwithstanding its veto rights, the Trustee has no obligation with respect to REO Dispositions. (d) Each Servicer shall segregate and hold all funds collected and received in connection with the operation of any REO Property separate and apart from its own funds and general assets and shall deposit such funds in the Collection Account. (e) Each Servicer shall deposit net of reimbursement to such Servicer for any related outstanding Servicing Advances and unpaid Servicing Fees provided in Section 3.11, or cause to be deposited, on a daily basis in the Collection Account all revenues received with respect to the related REO Property and shall withdraw therefrom funds necessary for the proper operation, management and maintenance of the REO Property. (f) Each Servicer, upon an REO Disposition, shall be entitled to reimbursement for any related unreimbursed Servicing Advances as well as any unpaid Servicing Fees from proceeds received in connection with the REO Disposition, as further provided in Section 3.11. (g) Any net proceeds from an REO Disposition which are in excess of the unpaid principal balance of the related Mortgage Loan plus all unpaid REO Imputed Interest thereon through the date of the REO Disposition shall be retained by the applicable Servicer as additional servicing compensation. (h) Each Servicer shall use its reasonable best efforts, to sell, or cause the Subservicer to sell, any REO Property as soon as possible, but in no event later than the conclusion of the third calendar year beginning after the year of its acquisition by the REMIC unless (i) such Servicer applies for an extension of such period from the Internal Revenue Service pursuant to the REMIC Provisions and Code Section 856(e)(3), in which event such REO Property shall be sold within the applicable extension period, or (ii) such Servicer, at its expense, obtains for and delivers to the Trustee and the Master Servicer an Opinion of Counsel, addressed to the Depositor, the Trustee, the Master Servicer and such Servicer, to the effect that the holding by the Pooling-Tier REMIC-1 of such REO Property subsequent to such period will not result in the imposition of taxes on "prohibited transactions" as defined in Section 860F of the Code or cause any Trust REMIC to fail to qualify as a REMIC under the REMIC Provisions or comparable provisions of relevant state laws at any time. Each Servicer shall manage, conserve, protect and operate each REO Property serviced by such Servicer for the Trustee solely for the purpose of its prompt disposition and sale in a manner which does not cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) or result in the receipt by the Pooling-Tier REMIC-1 of any "income from non-permitted assets" within the meaning of Section 860F(a)(2)(B) of the Code or any "net income from foreclosure property" which is subject to taxation under Section 860G(a)(1) of the Code. Pursuant to its efforts to sell such REO Property, the applicable Servicer shall either itself or through an agent selected by such Servicer protect and conserve such REO Property in the same manner and to such extent as is customary in the locality where such REO Property is located and may, incident to its conservation and protection of the interests of the Trustee on behalf of the Certificateholders, rent the same, or any part thereof, as such Servicer deems to be in the best interest of the Trustee on behalf of the Certificateholders for the period prior to the sale of such REO Property; provided, however, that any rent received or accrued with respect to such REO Property qualifies as "rents from real property" as defined in Section 856(d) of the Code.

• Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;

• Execution of the Project (a) The Borrower declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through the Directorate General of Community Empowerment of its Ministry of Home Affairs with due diligence and efficiency and in conformity with appropriate administrative, agricultural, engineering, and financial practices and sound environmental and social standards acceptable to the Association, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project. (b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Borrower and the Association shall otherwise agree, the Borrower shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement. (a) Except as the Association shall otherwise agree, procurement of the goods, works and services required for the Project and to be financed out of the proceeds of the Credit shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan. (b) The Borrower shall update the Procurement Plan in accordance with guidelines acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval. Section 3.03. For the purposes of Section 9.06 of the General Conditions and without limitation thereto, the Borrower shall: (a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Borrower and the Association, a plan designed to ensure the continued achievement of the objectives of the Project; and (b) afford the Association a reasonable opportunity to exchange views with the Borrower on said plan.

• Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Partiesfurther agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

• Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

• CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.