Sub-Consultants All sub-consultants shall comply with each and every insurance provision of this Section 3.
Subconsultants Whichever of the following is marked applies to this Approved Service Order: The Consultant can not use any subconsultants. The Consultant can use the following subconsultants to assist in providing the required services and deliverables:
2. 3.
Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.
Individual Consultants Services for assignments that meet the requirements set forth in the first sentence of paragraph 5.1 of the Consultant Guidelines may be procured under contracts awarded to individual consultants in accordance with the provisions of paragraphs 5.2 through 5.3 of the Consultant Guidelines. Under the circumstances described in paragraph 5.4 of the Consultant Guidelines, such contracts may be awarded to individual consultants on a sole-source basis.
Other Consultants The City reserves the right to employ other consultants in connection with the Work.
Employees and Consultants Pubco does not have any employees or consultants, except as disclosed in the Pubco SEC Documents.
Consultants Any and all consultant(s), sub-consultant(s), subcontractor(s), or agent(s) to the Architect.
Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA.
(b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA.
(c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein.
(d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors.
(e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.
EMPLOYEES, SUBCONTRACTORS & AGENTS All employees, Subcontractors or agents performing work under the Contract must be trained staff or technicians who meet or exceed the professional, technical and training qualifications set forth in the Bid Specifications or the Bid Documents, whichever is more restrictive, and must comply with all security and administrative requirements of the Authorized User. The Commissioner reserves the right to conduct a security background check or otherwise approve any employee, Subcontractor or agent furnished by Contractor and to refuse access to or require replacement of any personnel for cause based on, including but not limited to, professional, technical or training qualifications, quality of work or change in security status or non- compliance with Authorized User’s security or other requirements. Such approval shall not relieve the Contractor of the obligation to perform all work in compliance with the Contract terms. The Commissioner reserves the right to reject and/or bar from the facility for cause any employee, Subcontractor, or agents of the Contractor.
Consultant’s Personnel Consultant has, or will secure at its own expense, all personnel required to perform the Services required under this Agreement. All of the Services required under this Agreement shall be performed by Consultant or under its supervision, and all personnel engaged in the Services shall be qualified to perform such Services. Consultant shall make every reasonable effort to maintain the stability and continuity of Consultant’s staff and sub-contractors, if any, assigned to perform the Services required under this Agreement. Consultant shall notify City of all changes in Consultant’s staff and sub-contractors, if any, assigned to perform the Services required under this Agreement, prior to and during any such performance. In the event that City, in its sole discretion, at any time during the term of this Agreement, desires to reassign any staff or sub-contractor of Consultant, City shall give notice as set forth in Section 8.1. Consultant shall, immediately upon the receipt of the notice to re-assign staff from City, reassign such person or persons.
