Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Production of Witnesses; Records; Cooperation (a) After the Effective Time, each Party shall use its commercially reasonable efforts to make available to the other Party, upon written request, the former, current and future directors, officers, employees, other personnel and agents of the members of its respective Group as witnesses and any books, records or other documents within its control or which it otherwise has the ability to make available without undue burden, to the extent that any such Person (giving consideration to business demands of such directors, officers, employees, other personnel and agents) or books, records or other documents may reasonably be required in connection with any Action in which the requesting Party (or member of its Group) may from time to time be involved, regardless of whether such Action is a matter with respect to which indemnification may be sought hereunder. The requesting Party shall bear all costs and expenses in connection therewith. (b) If an Indemnifying Party chooses to defend or to seek to compromise or settle any Third-Party Claim, the other Party shall make available to such Indemnifying Party, upon written request, the former, current and future directors, officers, employees, other personnel and agents of the members of its respective Group as witnesses and any books, records or other documents within its control or which it otherwise has the ability to make available without undue burden, to the extent that any such Person (giving consideration to business demands of such directors, officers, employees, other personnel and agents) or books, records or other documents may reasonably be required in connection with such defense, settlement or compromise, or such prosecution, evaluation or pursuit, as the case may be, and shall otherwise cooperate in such defense, settlement or compromise, or such prosecution, evaluation or pursuit, as the case may be. (c) Without limiting the foregoing, the Parties shall cooperate and consult to the extent reasonably necessary with respect to any Actions. (d) Without limiting any provision of this Section 6.7, each of the Parties agrees to cooperate, and to cause each member of its respective Group to cooperate, with each other in the defense of any infringement or similar claim with respect any Intellectual Property and shall not claim to acknowledge, or permit any member of its respective Group to claim to acknowledge, the validity or infringing use of any Intellectual Property of a third Person in a manner that would hamper or undermine the defense of such infringement or similar claim. (e) The obligation of the Parties to provide witnesses pursuant to this Section 6.7 is intended to be interpreted in a manner so as to facilitate cooperation and shall include the obligation to provide as witnesses inventors and other officers without regard to whether the witness or the employer of the witness could assert a possible business conflict (subject to the exception set forth in the first sentence of Section 6.7(a)).
Good Offices, Conciliation or Mediation 1. The Parties may at any time agree to good offices, conciliation or mediation. They may begin at any time and be terminated by either Party at any time. 2. If the Parties agree, procedures for good offices, conciliation or mediation may continue while the dispute proceeds for resolution before an arbitral tribunal appointed under Article 15.5. 3. All proceedings under this Article shall be confidential and without prejudice to the rights of either Party in any further proceedings under the provisions of this Chapter.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
State of California Public Liability and Workers’ Compensation Program A. The Judicial Council has elected to be self-insured for its motor vehicle, aircraft liability and general liability exposures. B. The Judicial Council administers workers’ compensation benefits for its employees through a Third Party agreement.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Construction; Governing Law The headings used in this Agreement are for convenience only and shall not be deemed to constitute a part hereof. Whenever the context requires, words denoting singular shall be read to include the plural. This Agreement and the rights and obligations of the parties hereunder, shall be construed and interpreted in accordance with the laws of the State of Kansas, except to the extent that the laws of the State of Maryland apply with respect to share transactions.
Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.
File Management and Record Retention relating to CRF Eligible Persons or Households Grantee must maintain a separate file for every applicant, Eligible Person, or Household, regardless of whether the request was approved or denied. a. Contents of File: Each file must contain sufficient and legible documentation. Documents must be secured within the file and must be organized systematically.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “ (1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “ (1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.