Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Direct Claim Procedures In the event an Indemnified Party has a claim for indemnity under Section 7.02 against the Indemnifying Party that does not involve a Third Party Claim, the Indemnified Party agrees to give notice in writing of such claim to the Indemnifying Party. Such notice shall set forth in reasonable detail such claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party. If the Indemnifying Party does not notify the Indemnified Party within thirty (30) days following the receipt of a notice with respect to any such claim that the Indemnifying Party disputes its indemnity obligation to the Indemnified Party for any Losses with respect to such claim, such Losses shall be conclusively deemed a liability of the Indemnifying Party and the Indemnifying Party shall promptly pay to the Indemnified Party any and all Losses arising out of such claim. If the Indemnifying Party has timely disputed its indemnity obligation for any Losses with respect to such claim, the parties shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through such negotiations, such dispute shall be resolved by arbitration determined pursuant to Section 9.06.
Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.
Additional Matters Indemnification payments in respect of any Liabilities for which an Indemnified Party is entitled to indemnification under this Section 12.5 shall be paid by the Indemnifying Party to the Indemnified Party as such Liabilities are incurred upon demand by the Indemnified Party, including reasonably satisfactory documentation setting forth the basis for the amount of such indemnification payment, including documentation with respect to calculations made on an After-Tax Basis and consideration of any Insurance Proceeds that actually reduce the amount of such Liabilities. The indemnities contained in this Section 12.5 shall remain operative and in full force and effect, regardless of (i) any investigation made by or on behalf of any Indemnified Party; (ii) the knowledge by the Indemnified Party of Liabilities for which it might be entitled to indemnification hereunder; (iii) any termination of this Agreement or any PSA; and (iv) the sale or other transfer by any party of any assets or businesses or the assignment by it of any liabilities. If payment is made by or on behalf of any Indemnifying Party to any Indemnified Party in connection with any Third Party Claim, such Indemnifying Party shall be subrogated to and shall stand in the place of such Indemnified Party as to any events or circumstances in respect of which such Indemnified Party may have any right, defense or claim relating to such Third Party Claim against any claimant or plaintiff asserting such Third Party Claim or against any other Person. Such Indemnified Party shall cooperate with such Indemnifying Party in a reasonable manner, and at the cost and expense of such Indemnifying Party, in prosecuting any subrogated right, defense or claim. In an Action in which the Indemnifying Party is not a named defendant, if either the Indemnified Party or Indemnifying Party shall so request, the parties shall endeavor to substitute the Indemnifying Party for the named defendant if they conclude that substitution is desirable and practical. If such substitution or addition cannot be achieved for any reason or is not requested, the named defendant shall allow the Indemnifying Party to manage the Action as set forth in this section, and the Indemnifying Party shall fully indemnify the named defendant against all costs of defending the Action (including court costs, sanctions imposed by a court, attorneys’ fees, experts fees and all other external expenses), the costs of any judgment or settlement, and the cost of any interest or penalties relating to any judgment or settlement.
Litigation Matters If the FDIC Party and the Assuming Institution do not agree to submit the Dispute Item to arbitration, the Dispute Item may be resolved by litigation in accordance with Federal or state law, as provided in Section 13.10 of the Purchase and Assumption Agreement. Any litigation shall be filed in a United States District Court in the proper district.
Transitional Matters (a) Each of the parties acknowledges and agrees that the transition of the Business from the Selling Companies to Buyer will require that certain transactions and relationships will need to be entered into, restructured and reorganized in connection with the transition of the Business from the Selling Companies to Buyer. The parties agree that prior to the Closing Date, the parties shall cooperate with each other to identify all such transactions and relationships and negotiate in good faith to enter into a mutually acceptable Transitional Agreement effective as of the Closing Date, which agreement shall provide for all such transactions and relationships as are reasonably necessary to provide,
(i) for (A) the operation of the Business and use of the Purchased Assets by Buyer, (B) the operation and use of the Excluded Assets by Sellers and the Selling Subsidiaries and (C) the separation of the Business, the Purchased Assets and the Assumed Liabilities from Parent and its Affiliates (including the Selling Companies), in each case during the period commencing on and after the Closing Date and ending no later than the one year anniversary of the Closing Date or such longer period as the parties may agree, including the following:
(1) the transitioning of the financial systems, assets and hedging valuation systems, asset management systems, payroll and employee benefits systems and any other applicable business operating systems;
(2) the provision of rights of access (provided that access to the ALSS Platform shall be governed and limited by the Intellectual Property Rights Agreement and the Services Agreement) to the Parent and its Affiliates to Intellectual Property currently owned (or licensed) by the Selling Companies (and included in the Purchased Assets) and used by Parent or the Selling Companies in the ordinary course of their business, or required by the Selling Companies for the operation and use of the Excluded Assets or Excluded Liabilities; provided, that access to the ALSS Platform and other Software shall be governed solely by the Intellectual Property Rights Agreement and the Services Agreement and, provided further, anything foregoing to the contrary notwithstanding, Buyer shall not be required to disclose or deliver trade secret or confidential information regarding the ALSS Platform, Software or Acquired Intellectual Property unless required by the Intellectual Property Rights Agreement, the Services Agreement or required by law or legal proceedings and under the type of protective provisions in the Intellectual Property Rights Agreement.
(3) the provision of rights of access (to the extent not covered by the Intellectual Property Rights Agreement) to Buyer to Intellectual Property currently owned (or licensed) by Parent (or the Selling Companies) and used by the Selling Companies in connection with the Purchased Assets or Assumed Liabilities;
(4) moving corporate records related to the Selling Companies; and
(5) the provision of office space, computer equipment and supplies sufficient to enable the Selling Companies to complete any transition services; and
(ii) for such services and facilities as Sellers and Selling Subsidiaries may require to monitor compliance with, and implementation of the Subservicing Agreement, during its term, including the provision of office space, computer equipment and supplies sufficient to enable Sellers to monitor compliance with the Retained Portfolio Subservicing Agreement throughout its term.
(b) In addition to the matters to be identified pursuant to paragraph (a) of this Section 5.12, the Transition Agreement shall specifically provide for the transactions and matters outlined in Section 5.12 of Sellers' Disclosure Schedule.
(c) For the purpose of facilitating the transition of the financial system, on or prior to the 15th day prior to the Closing Date, the Selling Companies shall create on their general ledger, a separate general ledger company ("GL Company"), as well as accounts for such GL Company ("Buyer GL Accounts"), which accounts shall be duplicative of the Selling Companies' own accounts ("Seller GL Accounts") and are intended to be used by the Buyer in the operation of the Business, the Purchased Assets and the Assumed Liabilities from and after the Closing Date. From and after the creation of the Buyer GL Accounts, until Closing, the Selling Companies shall maintain such accounts (as duplicate entries on the books of the Selling Companies in the name of the GL Company). From and after Closing until the completion of the transition of the financial system of the Selling Companies, the Buyer shall operate the Business by recording entries using the Buyer GL Accounts, and shall maintain on behalf of the Selling Companies, the Seller GL Accounts on its general ledger.
(d) The party receiving service under the Transitional Agreement shall pay to the party providing service the costs incurred by such providing party. Services provided under the Transitional Agreement shall be performed at the same standard as the providing party performs such service for its own account.
Certain Additional Matters (a) Any arbitration award shall be a bare award limited to a holding for or against a party and shall be without findings as to facts, issues or conclusions of law (including with respect to any matters relating to the validity or infringement of patents or patent applications) and shall be without a statement of the reasoning on which the award rests, but must be in adequate form so that a judgment of a court may be entered thereupon. Judgment upon any arbitration award hereunder may be entered in any court having jurisdiction thereof.
(b) Prior to the time at which an arbitrator is appointed pursuant to Section 8.4, any party may seek one or more temporary restraining orders in a court of competent jurisdiction if necessary in order to preserve and protect the status quo. Neither the request for, or grant or denial of, any such temporary restraining order shall be deemed a waiver of the obligation to arbitrate as set forth herein and the arbitrator may dissolve, continue or modify any such order. Any such temporary restraining order shall remain in effect until the first to occur of the expiration of the order in accordance with its terms or the dissolution thereof by the arbitrator.
(c) Except as required by law, the parties shall hold, and shall cause their respective officers, directors, employees, agents and other representatives to hold, the existence, content and result of mediation or arbitration in confidence in accordance with the provisions of Article VIII and except as may be required in order to enforce any award. Each of the parties shall request that any mediator or arbitrator comply with such confidentiality requirement.
(d) If at any time the sole arbitrator shall fail to serve as an arbitrator for any reason, the parties shall select a new arbitrator who shall be disinterested as to the parties and the matter in accordance with the procedures set forth herein for the selection of the initial arbitrator. The extent, if any, to which testimony previously given shall be repeated or as to which the replacement arbitrator elects to rely on the stenographic record (if there is one) of such testimony shall be determined by the replacement arbitrator.
Claims and Disputes A. Claims by CONTRACTOR shall be made in writing to the COUNTY within two (2) business days after the commencement of the event giving rise to such claim or CONTRACTOR shall be deemed to have waived the claim. All claims shall be priced in accordance with the section in this document entitled “Changes in Work”.
B. CONTRACTOR shall proceed diligently with its performance as directed by the COUNTY, regardless of any pending claim, action, suit, or administrative proceeding, unless otherwise agreed to by the COUNTY in writing. The COUNTY shall continue to make payments on the undisputed portion of the contract in accordance with the contract documents during the pendency of any claim.
C. Claims by CONTRACTOR shall be resolved in the following manner:
1) Upon receiving the claim and supporting data, the COUNTY shall within fifteen (15) calendar days respond to the claim in writing stating that the claim is either approved or denied. If denied, the COUNTY shall specify the grounds for denial. The CONTRACTOR shall then have fifteen (15) calendar days in which to provide additional supporting documentation, or to notify the COUNTY that the original claim stands as is.
2) If the claim is not resolved, the COUNTY may, at its option, choose to submit the matter to mediation. A mediator shall be mutually selected by the parties and each party shall pay one-half (1/2) the expense of mediation. If the COUNTY declines to mediate the dispute, CONTRACTOR may bring an action in a court of competent jurisdiction in and for Lake County, Florida.
D. Claims by the COUNTY against CONTRACTOR shall be made in writing to the CONTRACTOR as soon as the event leading to the claim is discovered by the COUNTY. CONTRACTOR shall respond in writing within fifteen (15) calendar days of receipt of the claim. If the claim cannot be resolved, the COUNTY shall have the option to submit the matter to mediation as set forth in (C)(2) above.
E. Arbitration shall not be considered as a means of dispute resolution. F. NO CLAIM FOR DAMAGES OR ANY CLAIM OTHER THAN FOR AN EXTENSION OF TIME SHALL BE MADE OR ASSERTED AGAINST THE COUNTY BY REASON OF ANY DELAYS. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the work shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY. CONTRACTOR expressly acknowledges and agrees that CONTRACTOR shall receive no damages for delay. This provision shall not preclude recovery or damages by CONTRACTOR for hindrances or delays due solely to fraud, bad faith or active interference on the part of the COUNTY. Otherwise, CONTRACTOR shall be entitled to extensions of the contract time as the sole and exclusive remedy for such resulting delay, in accordance with and to the extent specifically provided above.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Third Party Claims The obligation of an indemnifying party to ------------------ indemnify another party to this Agreement under the provisions of this Article with respect to claims resulting from the assertion of liability by Persons not parties to this Agreement (including governmental claims for penalties, fines and assessments) shall be subject to the following terms and conditions:
(a) The indemnified party shall give prompt written notice to the indemnifying party of any assertion of liability by a third party which might give rise to a claim for indemnification, which notice shall state the nature and basis of the assertion and the amount thereof, to the extent known, provided, however, that no delay on the part of the indemnified party in giving notice shall relieve the indemnifying party of any obligation to indemnify unless (and then solely to the extent that) the indemnifying party is prejudiced by such delay.
(b) If any action, suit or proceeding (a "Legal Action") is brought against an indemnified party with respect to which the indemnifying party may have an obligation to indemnify, the Legal Action shall be defended by the indemnifying party and such defense shall include all proceedings and appeals which counsel for the indemnified party shall reasonably deem appropriate.
(c) Notwithstanding the provisions of the previous subsection of this Article, until the indemnifying party shall have assumed the defense of any such Legal Action, the defense shall be handled by the indemnified party. Furthermore, (i) if the indemnified party shall have reasonably concluded that there are likely to be defenses available to the indemnified party that are different from or in addition to those available to the indemnifying party; (ii) if the indemnifying party fails to provide the indemnified party with evidence reasonably acceptable to the indemnified party that the indemnifying party has sufficient financial resources to defend and fulfill its indemnification obligation with respect to the Legal Action; (iii if the Legal Action involves other than money damages and seeks injunctive or other equitable relief; or (iv) if a judgment against the indemnified party will, in the good faith opinion of the indemnified party, establish a custom or precedent which will be materially adverse to the best interests of its continuing business, the indemnifying party shall not be entitled to assume the defense of the Legal Action and the defense shall be handled by the indemnified party. If the defense of the Legal Action is handled by the indemnified party under the provisions of this subsection, the indemnifying party shall pay all legal and other expenses reasonably incurred by the indemnified party in conducting such defense.
(d) In any Legal Action initiated by a third party and defended by the indemnifying party (i) the indemnified party shall have the right to be represented by advisory counsel and accountants, at its own expense, (ii) the indemnifying party shall keep the indemnified party fully informed as to the status of such Legal Action at all stages thereof, whether or not the indemnified party is represented by its own counsel, (iii) the indemnifying party shall make available to the indemnified party, and its attorneys, accountants and other representatives, all books and records of the indemnifying party relating to such Legal Action and (iv) the parties shall render to each other such assistance as may be reasonably required in order to ensure the proper and adequate defense of the Legal Action.
(e) In any Legal Action initiated by a third party and defended by the indemnifying party, the indemnifying party shall not make any settlement of any claim without the written consent of the indemnified party, which consent shall not be unreasonably withheld. Without limiting the generality of the foregoing, it shall not be deemed unreasonable to withhold consent to a settlement involving injunctive or other equitable relief against the indemnified party or its assets, employees or business, or relief which the indemnified party reasonably believes could establish a custom or precedent which will be adverse to the best interests of its continuing business.
