Payment Delay To the maximum extent permitted under section 409A of the Code, the severance benefits payable under this Agreement are intended to comply with the “short-term deferral exception” under Treas. Reg. §1.409A-1(b)(4), and any remaining amount is intended to comply with the “separation pay exception” under Treas. Reg. §1.409A-1(b)(9)(iii); provided, however, any amount payable to Executive during the six (6) month period following Executive’s Termination Date that does not qualify within either of the foregoing exceptions and constitutes deferred compensation subject to the requirements of section 409A of the Code, then such amount shall hereinafter be referred to as the “Excess Amount.” If at the time of Executive’s separation from service, the Company’s (or any entity required to be aggregated with the Company under section 409A of the Code) stock is publicly-traded on an established securities market or otherwise and Executive is a “specified employee” (as defined in section 409A of the Code and determined in the sole discretion of the Company (or any successor thereto) in accordance with the Company’s (or any successor thereto) “specified employee” determination policy), then the Company shall postpone the commencement of the payment of the portion of the Excess Amount that is payable within the six (6) month period following Executive’s Termination Date with the Company (or any successor thereto) for six (6) months following Executive’s Termination Date with the Company (or any successor thereto). The delayed Excess Amount shall be paid in a lump sum to Executive within ten (10) days following the date that is six (6) months following Executive’s Termination Date with the Company (or any successor thereto). If Executive dies during such six (6) month period and prior to the payment of the portion of the Excess Amount that is required to be delayed on account of section 409A of the Code, such Excess Amount shall be paid to the personal representative of Executive’s estate within sixty (60) days after Executive’s death.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Disbursements, Reimbursement Immediately upon the issuance of each Letter of Credit, each Lender shall be deemed to, and hereby irrevocably and unconditionally agrees to, purchase from the Issuing Lender a participation in such Letter of Credit and each drawing thereunder in an amount equal to such Lender’s Ratable Share of the maximum amount available to be drawn under such Letter of Credit and the amount of such drawing, respectively.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Reimbursements of Workout-Delayed Reimbursement Amounts The Master Servicer, the Special Servicer and the Trustee, as applicable, shall be entitled to reimbursement and payment for all Workout-Delayed Reimbursement Amounts in each Collection Period; provided that the aggregate amount (for all such Persons collectively) of such reimbursements and payments in such Collection Period shall not exceed (and the reimbursement and payment shall be made from) the aggregate amount in the Collection Account allocable to principal received with respect to the Mortgage Loans for such Collection Period contemplated by clause (I)(A) of the definition of Principal Distribution Amount (but not including any such amounts that constitute Advances) and net of any Nonrecoverable Advances then outstanding and reimbursable from such principal in accordance with Section 5.2(a)(II)(iv) below. As and to the extent provided in clause (II)(A) of the definition thereof, the Principal Distribution Amount for the Distribution Date related to such Collection Period shall be reduced to the extent that such payment or reimbursement of a Workout-Delayed Reimbursement Amount is made from the aggregate amount in the Collection Account allocable to principal pursuant to the preceding sentence.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursement shall be made pursuant to Landlord’s standard disbursement process), only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Identification of Workout-Delayed Reimbursement Amounts If any Advance made with respect to any Mortgage Loan on or before the date on which such Mortgage Loan becomes (or, but for the making of three monthly payments under its modified terms, would then constitute) a Corrected Mortgage Loan, together with (to the extent theretofore accrued and unpaid) Advance Interest thereon, is not pursuant to the operation of the provisions of Section 3.05(a)(I) reimbursed to the Person who made such Advance on or before the date, if any, on which such Mortgage Loan becomes a Corrected Mortgage Loan (or, but for the making of three monthly payments under its modified terms, would constitute a Mortgage Loan that is a Corrected Mortgage Loan), such Advance, together with such Advance Interest, shall constitute a “Workout-Delayed Reimbursement Amount” to the extent that such amount has not been determined to constitute a Nonrecoverable Advance. All references herein to “Workout-Delayed Reimbursement Amount” shall be construed always to mean the related Advance and (to the extent theretofore accrued and unpaid) any Advance Interest thereon, together with (to the extent it remains unpaid) any further Advance Interest that accrues on the unreimbursed portion of such Advance from time to time in accordance with the other provisions of this Agreement. That any amount constitutes all or a portion of any Workout-Delayed Reimbursement Amount shall not in any manner limit the right of any Person hereunder to determine that such amount instead constitutes a Nonrecoverable Advance.
Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.
Monthly Disbursements On or before the fifth (5th) day of each calendar month, during the design and construction of the Tenant Improvements (or such other date as Landlord may designate), Tenant shall deliver to Landlord: (i) a request for reimbursement of amounts paid to the “Contractor,” as that term is defined in Section 4.1.1 of this Tenant Work Letter, approved by Tenant, in a commercially reasonable form to be provided by Landlord, showing the schedule, by trade, of percentage of completion of the Tenant Improvements in the Premises, detailing the portion of the work completed and the portion not completed; (ii) invoices from all of “Tenant’s Agents,” as that term is defined in Section 4.1.2 of this Tenant Work Letter, for labor rendered and materials for the Premises; (iii) executed mechanic’s lien releases, as applicable, from all of Tenant’s Agents which shall comply with the appropriate provisions, as reasonably determined by Landlord, of California Civil Code Section 3262(d); and (iv) all other information reasonably requested by Landlord. Tenant’s request for payment shall be deemed Tenant’s acceptance and approval of the work furnished and/or the materials supplied as set forth in Tenant’s payment request. Within forty-five (45) days thereafter, Landlord shall deliver a check to Tenant made payable to Tenant in payment of the lesser of: (A) the amounts so requested by “tenant as set forth in this Section 2.2.3.1, above (or, subject to the terms of Section 4.2.1, below, a percentage thereof), and (B) the balance of any remaining available portion of the Tenant Improvement Allowance, provided that Landlord does not dispute any request for payment based on non-compliance of any work with the “Approved Working Drawings,” as that term is defined in Section 3.5 below, or due to any substandard work. Landlord’s payment of such amounts shall not be deemed Landlord’s approval or acceptance of the work furnished or materials supplied as set forth in Tenant’s payment request.
