Required Repairs Borrower shall perform all of the repairs (on an Individual Property by Individual Property basis) at the applicable Individual Properties, as more particularly set forth on Schedule 5.1.32 hereto (such repairs hereinafter referred to as “Required Repairs”) (i) in compliance with all applicable Legal Requirements, (ii) in a Lien-free, good and workmanlike manner and (iii) prior to the date set forth on Schedule 5.1.32 with respect to such Required Repairs (each such date, a “Required Repair Deadline”). It shall constitute an Event of Default if Borrower does not complete each Required Repair by the applicable Required Repair Deadline, provided that, if Borrower shall have been unable to complete a Required Repair by the applicable Required Repair Deadline, after using commercially reasonable efforts to do so, including, without limitation, if caused by delays due to weather or force majeure, such Required Repair Deadline shall be automatically extended solely as to such Required Repair to permit Borrower to complete such Required Repair so long as Borrower is at all times thereafter diligently and expeditiously proceeding to complete the same. Notwithstanding the foregoing, to the extent any Required Repair is the responsibility of a Tenant pursuant to a Lease, Borrower shall be obligated only to use commercially reasonably efforts to have such Tenant complete such Required Repair on or prior to the Required Repair Deadline.
Release of Required Repair Funds Lender shall disburse to Borrower the Required Repair Funds from the Required Repair Account from time to time upon satisfaction by Borrower of each of the following conditions: (i) Borrower shall submit a written request for payment to Lender at least fifteen (15) days prior to the date on which Borrower requests such payment be made and specifies the Required Repairs to be paid, (ii) on the date such request is received by Lender and on the date such payment is to be made, no Default or Event of Default shall exist and remain uncured, (iii) Lender shall have received a certificate from Borrower (A) stating that all Required Repairs at the Property to be funded by the requested disbursement have been completed in good and workmanlike manner and in accordance with all applicable federal, state and local laws, rules and regulations, such certificate to be accompanied by a copy of any license, permit or other approval by any Governmental Authority required to commence and/or complete the Required Repairs, (B) identifying each Person that supplied materials or labor in connection with the Required Repairs performed at the Property to be funded by the requested disbursement under a contract in excess of $50,000, and (C) stating that each Person who has supplied materials or labor in connection with the Required Repairs to be funded by the requested disbursement has been paid in full or will be paid in full upon such disbursement, such certificate to be accompanied by lien waivers or other evidence of payment satisfactory to Lender, (iv) at Lender’s option, a title search for the Property indicating that the Property is free from all liens, claims and other encumbrances not previously approved by Lender, and (v) Lender shall have received such other evidence as Lender shall reasonably request that the Required Repairs at the Property to be funded by the requested disbursement have been completed and are paid for or will be paid upon such disbursement to Borrower. Lender shall not be required to make disbursements from the Required Repair Account with respect to the Property more than once each calendar month and such disbursement shall be made only upon satisfaction of each condition contained in this Section 7.1.2.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process, which disbursement process shall require the Architect to make field verifications and written certifications as required by Landlord in connection with Landlord’s disbursements to Contractor (as defined below)) only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
(a) Payment of (i) the fees of the Architect and the Engineers (as defined below), (ii) charges for Landlord’s construction consultant and Building engineer, and (iii) the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the Construction Drawings (as defined below);
(b) The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
(c) The cost of construction of the Tenant Improvements, including, without limitation, any cost of after-hours freight elevator usage;
(d) The cost of any changes in the Base, Shell, and Core when such changes are required by the Construction Drawings, such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
(e) The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
(f) Sales and use taxes; and
(g) All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. In no event shall the Tenant Improvement Allowance Items include any costs of procuring or installing in the Premises any trade fixtures, equipment, furniture, furniture partitions or systems, furnishings, telephone, telecommunications, data and security wiring, cabling and equipment, or other personal property (“Personal Property”) to be used in the Premises by Tenant, and the cost of such Personal Property shall be paid by Tenant.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Disbursement of Advance Proceeds All Advances shall be disbursed from whichever office or other place Agent may designate from time to time and, together with any and all other Obligations of Borrowers to Agent or Lenders, shall be charged to Borrowers' Account on Agent's books. During the Term, Borrowers may use the Revolving Advances by borrowing, prepaying and reborrowing, all in accordance with the terms and conditions hereof. The proceeds of each Revolving Advance requested by Borrowers or deemed to have been requested by Borrowers under Section 2.2(a) hereof shall, with respect to requested Revolving Advances to the extent Lenders make such Revolving Advances, be made available to the applicable Borrower on the day so requested by way of credit to such Borrower's operating account at PNC, or such other bank as Borrowing Agent may designate following notification to Agent, in immediately available federal funds or other immediately available funds or, with respect to Revolving Advances deemed to have been requested by any Borrower, be disbursed to Agent to be applied to the outstanding Obligations giving rise to such deemed request.
Construction Loan Subject to the terms and conditions of this Agreement and in reliance upon the representations and warranties set forth in this Agreement, the Lender has agreed to lend to Borrower and Borrower has agreed to borrow from Lender the lesser of: (i) $27,000,000.00; or (ii) 55% of the Project Costs. Such amount shall be loaned by Lender pursuant to the terms and conditions set forth in this Agreement and the First Supplement to this Agreement.
Disbursement of the Loan Disbursements will be made by and at the discretion of SBA Counsel, in accordance with this Loan Authorization and Agreement and the general requirements of SBA. · Disbursements may be made in increments as needed. · Other conditions may be imposed by SBA pursuant to general requirements of SBA. · Disbursement may be withheld if, in SBA's sole discretion, there has been an adverse change in Borrower's financial condition or in any other material fact represented in the Loan application, or if Borrower fails to meet any of the terms or conditions of this Loan Authorization and Agreement. · NO DISBURSEMENT WILL BE MADE LATER THAN 6 MONTHS FROM THE DATE OF THIS LOAN AUTHORIZATION AND AGREEMENT UNLESS SBA, IN ITS SOLE DISCRETION, EXTENDS THIS DISBURSEMENT PERIOD. · This Loan Authorization and Agreement will be binding upon Borrower and Borrower's successors and assigns and will inure to the benefit of SBA and its successors and assigns.
Disbursements from Replacement Reserve Account (a) Lender shall make disbursements from the Replacement Reserve Account to pay Borrower only for the costs of the Replacements. Lender shall not be obligated to make disbursements from the Replacement Reserve Account to reimburse Borrower for the costs of routine maintenance to the Property or for costs which are to be reimbursed from the Required Repair Fund (if any).
(b) Lender shall, upon written request from Borrower and satisfaction of the requirements set forth in this Section 7.3.2, disburse to Borrower amounts from the Replacement Reserve Account necessary to pay for the actual approved costs of Replacements or to reimburse Borrower therefor, upon completion of such Replacements (or, upon partial completion in the case of Replacements made pursuant to Section 7.3.2(f)) as determined by Lender. In no event shall Lender be obligated to disburse funds from the Replacement Reserve Account if a Default or an Event of Default exists.
(c) Each request for disbursement from the Replacement Reserve Account shall be in a form specified or approved by Lender and shall specify (i) the specific Replacements for which the disbursement is requested, (ii) the quantity and price of each item purchased, if the Replacement includes the purchase or replacement of specific items, (iii) the price of all materials (grouped by type or category) used in any Replacement other than the purchase or replacement of specific items, and (iv) the cost of all contracted labor or other services applicable to each Replacement for which such request for disbursement is made. With each request Borrower shall certify that all Replacements have been made in accordance with all applicable Legal Requirements of any Governmental Authority having jurisdiction over the Property to which the Replacements are being provided and, unless Lender has agreed to issue joint checks as described below, each request shall include evidence of payment of all such amounts. Each request for disbursement shall include copies of invoices for all items or materials purchased and all contracted labor or services provided. Except as provided in Section 7.3.2(e), each request for disbursement from the Replacement Reserve Account shall be made only after completion of the Replacement for which disbursement is requested. Borrower shall provide Lender evidence of completion satisfactory to Lender in its reasonable judgment.
(d) Borrower shall pay all invoices in connection with the Replacements with respect to which a disbursement is requested prior to submitting such request for disbursement from the Replacement Reserve Account or, at the request of Borrower, Lender will issue joint checks, payable to Borrower and the contractor, supplier, materialman, mechanic, subcontractor or other party to whom payment is due in connection with a Replacement. In the case of payments made by joint check, Lender may require a waiver of lien from each Person receiving payment prior to Lender's disbursement from the Replacement Reserve Account. In addition, as a condition to any disbursement, Lender may require Borrower to obtain lien waivers from each contractor, supplier, materialman, mechanic or subcontractor who receives payment in an amount equal to or greater than $100,000 for completion of its work or delivery of its materials. Any lien waiver delivered hereunder shall conform to the requirements of applicable law and shall cover all work performed and materials supplied (including equipment and fixtures) for the Property by that contractor, supplier, subcontractor, mechanic or materialman through the date covered by the current reimbursement request (or, in the event that payment to such contractor, supplier, subcontractor, mechanic or materialmen is to be made by a joint check, the release of lien shall be effective through the date covered by the previous release of funds request).
(e) If (i) the cost of a Replacement exceeds $100,000, (ii) the contractor performing such Replacement requires periodic payments pursuant to terms of a written contract, and (iii) Lender has approved in writing in advance such periodic payments, a request for reimbursement from the Replacement Reserve Account may be made after completion of a portion of the work under such contract, provided (A) such contract requires payment upon completion of such portion of the work, (B) the materials for which the request is made are on site at the Property and are properly secured or have been installed in the Property, (C) all other conditions in this Agreement for disbursement have been satisfied, (D) funds remaining in the Replacement Reserve Account are, in Lender's judgment, sufficient to complete such Replacement and other Replacements when required, and (E) if required by Lender, each contractor or subcontractor receiving payments under such contract shall provide a waiver of lien with respect to amounts which have been paid to that contractor or subcontractor.
(f) Borrower shall not make a request for disbursement from the Replacement Reserve Account more frequently than once in any calendar month and (except in connection with the final disbursement) the total cost of all Replacements in any request shall not be less than $5,000.00.
Disbursement of Loan Proceeds (a) The Trustee, as the agent of the Trust, shall disburse the amounts on deposit in the Project Loan Account to the Borrower upon receipt of a requisition executed by an Authorized Officer of the Borrower, and approved by the Trust, in a form meeting the requirements of Section 5.02(3) of the Bond Resolution.
(b) The Trust and Trustee shall not be required to disburse any Loan proceeds to the Borrower under this Loan Agreement, unless:
(i) the proceeds of the Trust Bonds shall be available for disbursement, as determined solely by the Trust;
(ii) in accordance with the Bond Act, and the Regulations, the Borrower shall have timely applied for, shall have been awarded and, prior to or simultaneously with the Loan Closing, shall have closed a Fund Loan for a portion of the Allowable Costs (as defined in such Regulations) of the Project in an amount not in excess of the amount of Allowable Costs of the Project financed by the Loan from the Trust;
(iii) the Borrower shall have on hand moneys to pay for the greater of (A) that portion of the total Costs of the Project that is not eligible to be funded from the Fund Loan or the Loan, or (B) that portion of the total Costs of the Project that exceeds the actual amounts of the loan commitments made by the State and the Trust, respectively, for the Fund Loan and the Loan; and
(iv) no Event of Default nor any event that, with the passage of time or service of notice or both, would constitute an Event of Default shall have occurred and be continuing hereunder.
