Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000-000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent flooring inspector to verify the Warranty Holder’s warranty claims. The determination of the flooring inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/geowood-flooring-warranty/. Warranty Exclusions and Limitations: This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s GeoWood flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and (ii) maintained in accordance with Cali Bamboo’s GeoWood flooring care and maintenance guidelines found online at xxxxx://xxx.xxxxxxxxxx.xxx/floor-care-and-maintenance/ (the “Maintenance Guide”). Cali Bamboo will provide copies of these guides upon request by the Warranty Holder. This limited warranty only applies when the Flooring is used under normal traffic and other usage conditions. The limited warranty for Manufacturing Defects does not apply after the Warranty Holder has installed the Flooring, and product variation or error that does not exceed the 5% industry standard is not considered a Manufacturing Defect for purposes of this limited warranty. This limited warranty does not extend to or cover:
The OCN, From XXX, and Invoice Number will control the invoice sequencing The From XXX will be used to identify to <<customer_name>> which BellSouth XXX is sending the message. BellSouth and <<customer_name>> will use the invoice sequencing to control data exchange. BellSouth will be notified of sequence failures identified by <<customer_name>> and resend the data as appropriate. THE DATA WILL BE PACKED USING ATIS EMI RECORDS.
PAYMENT TERMS/PRE-PAYMENT/QUANTITY DISOUNTS If discounts for accelerated payment, pre-payment, progress payment, or quantity discounts are offered, they must be clearly indicated in the Contractor’s submission prior to contract award. The applicability or acceptance of these terms is at the discretion of the Customer.
Transmission Delivery Service Implications Network Resource Interconnection Service allows Interconnection Customer's Large Generating Facility to be designated by any Network Customer under the Tariff on Transmission Provider's Transmission System as a Network Resource, up to the Large Generating Facility's full output, on the same basis as existing Network Resources interconnected to Transmission Provider's Transmission System, and to be studied as a Network Resource on the assumption that such a designation will occur. Although Network Resource Interconnection Service does not convey a reservation of transmission service, any Network Customer under the Tariff can utilize its network service under the Tariff to obtain delivery of energy from the interconnected Interconnection Customer's Large Generating Facility in the same manner as it accesses Network Resources. A Large Generating Facility receiving Network Resource Interconnection Service may also be used to provide Ancillary Services after technical studies and/or periodic analyses are performed with respect to the Large Generating Facility's ability to provide any applicable Ancillary Services, provided that such studies and analyses have been or would be required in connection with the provision of such Ancillary Services by any existing Network Resource. However, if an Interconnection Customer's Large Generating Facility has not been designated as a Network Resource by any load, it cannot be required to provide Ancillary Services except to the extent such requirements extend to all generating facilities that are similarly situated. The provision of Network Integration Transmission Service or firm Point-to-Point Transmission Service may require additional studies and the construction of additional upgrades. Because such studies and upgrades would be associated with a request for delivery service under the Tariff, cost responsibility for the studies and upgrades would be in accordance with FERC's policy for pricing transmission delivery services. Network Resource Interconnection Service does not necessarily provide Interconnection Customer with the capability to physically deliver the output of its Large Generating Facility to any particular load on Transmission Provider's Transmission System without incurring congestion costs. In the event of transmission constraints on Transmission Provider's Transmission System, Interconnection Customer's Large Generating Facility shall be subject to the applicable congestion management procedures in Transmission Provider's Transmission System in the same manner as Network Resources. There is no requirement either at the time of study or interconnection, or at any point in the future, that Interconnection Customer's Large Generating Facility be designated as a Network Resource by a Network Service Customer under the Tariff or that Interconnection Customer identify a specific buyer (or sink). To the extent a Network Customer does designate the Large Generating Facility as a Network Resource, it must do so pursuant to Transmission Provider's Tariff. Once an Interconnection Customer satisfies the requirements for obtaining Network Resource Interconnection Service, any future transmission service request for delivery from the Large Generating Facility within Transmission Provider's Transmission System of any amount of capacity and/or energy, up to the amount initially studied, will not require that any additional studies be performed or that any further upgrades associated with such Large Generating Facility be undertaken, regardless of whether or not such Large Generating Facility is ever designated by a Network Customer as a Network Resource and regardless of changes in ownership of the Large Generating Facility. However, the reduction or elimination of congestion or redispatch costs may require additional studies and the construction of additional upgrades. To the extent Interconnection Customer enters into an arrangement for long term transmission service for deliveries from the Large Generating Facility outside Transmission Provider's Transmission System, such request may require additional studies and upgrades in order for Transmission Provider to grant such request.
Billing, Payment, Milestones, and Financial Security 6.1 Billing and Payment Procedures and Final Accounting
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Conversion of Live Telephone Exchange Service to Analog 2W Loops The following coordination procedures shall apply to “live” cutovers of VERIZON Customers who are converting their Telephone Exchange Services to SPRINT Telephone Exchange Services provisioned over Analog 2W unbundled Local Loops (“Analog 2W Loops”) to be provided by VERIZON to SPRINT.
SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO.