Certification Regarding Prohibition of Certain Terrorist Organizations (Tex Gov. Code 2270) Certification Regarding Prohibition of Boycotting Israel (Tex. Gov. Code 2271) 5 Certification Regarding Prohibition of Contracts with Certain Foreign-Owned Companies (Tex. Gov. 5 Code 2274) 5 Certification Regarding Prohibition of Discrimination Against Firearm and Ammunition Industries (Tex.
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
Authority; Compliance With Other Agreements and Instruments and Government Regulations The execution, delivery and performance by Borrower and the Subsidiary Guarantors of the Loan Documents to which it is a Party have been duly authorized by all necessary corporate action, and do not and will not:
(a) Require any consent or approval not heretofore obtained of any partner, director, stockholder, security holder or creditor of such Party;
(b) Violate or conflict with any provision of such Party's charter, articles of incorporation or bylaws, as applicable;
(c) Result in or require the creation or imposition of any Lien (other than pursuant to the Loan Documents) or Right of Others upon or with respect to any Property now owned or leased or hereafter acquired by such Party;
(d) Violate any Requirement of Law applicable to such Party;
(e) Result in a breach of or constitute a default under, or cause or permit the acceleration of any obligation owed under, any material indenture or loan or credit agreement or any other Contractual Obligation to which such Party is a party or by which such Party or any of its Property is bound or affected; and such Party is not in violation of, or default under, any Requirement of Law or Contractual Obligation, or any material indenture, loan or credit agreement described in Section 4.2(e), in any respect that constitutes a Material Adverse Effect.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Existing utilities and roads Notwithstanding anything to the contrary contained herein, it shall be the responsibility of the Contractor to ensure that the respective entities owning the existing roads, right of way, level crossings, structures, or utilities on, under or above the Site are enabled by it to keep them in continuous satisfactory use, if necessary, by providing suitable temporary diversions with the authority of the controlling body of that road, right of way or utility.
Certification Regarding Business with Certain Countries and Organizations Pursuant to Subchapter F, Chapter 2252, Texas Government Code, PROVIDER certifies it is not engaged in business with Iran, Sudan, or a foreign terrorist organization. PROVIDER acknowledges this Purchase Order may be terminated if this certification is or becomes inaccurate.
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
OBLIGATIONS AND ACTIVITIES OF CONTRACTOR AS BUSINESS ASSOCIATE 1. CONTRACTOR agrees not to use or further disclose PHI COUNTY discloses to CONTRACTOR other than as permitted or required by this Business Associate Contract or as required by law.
2. XXXXXXXXXX agrees to use appropriate safeguards, as provided for in this Business Associate Contract and the Agreement, to prevent use or disclosure of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY other than as provided for by this Business Associate Contract.
3. XXXXXXXXXX agrees to comply with the HIPAA Security Rule at Subpart C of 45 CFR Part 164 with respect to electronic PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY.
4. CONTRACTOR agrees to mitigate, to the extent practicable, any harmful effect that is known to CONTRACTOR of a Use or Disclosure of PHI by CONTRACTOR in violation of the requirements of this Business Associate Contract.
5. XXXXXXXXXX agrees to report to COUNTY immediately any Use or Disclosure of PHI not provided for by this Business Associate Contract of which CONTRACTOR becomes aware. CONTRACTOR must report Breaches of Unsecured PHI in accordance with Paragraph E below and as required by 45 CFR § 164.410.
6. CONTRACTOR agrees to ensure that any Subcontractors that create, receive, maintain, or transmit PHI on behalf of CONTRACTOR agree to the same restrictions and conditions that apply through this Business Associate Contract to CONTRACTOR with respect to such information.
7. CONTRACTOR agrees to provide access, within fifteen (15) calendar days of receipt of a written request by COUNTY, to PHI in a Designated Record Set, to COUNTY or, as directed by COUNTY, to an Individual in order to meet the requirements under 45 CFR § 164.524. If CONTRACTOR maintains an Electronic Health Record with PHI, and an individual requests a copy of such information in an electronic format, CONTRACTOR shall provide such information in an electronic format.
8. CONTRACTOR agrees to make any amendment(s) to PHI in a Designated Record Set that COUNTY directs or agrees to pursuant to 45 CFR § 164.526 at the request of COUNTY or an Individual, within thirty (30) calendar days of receipt of said request by COUNTY. XXXXXXXXXX agrees to notify COUNTY in writing no later than ten (10) calendar days after said amendment is completed.
9. CONTRACTOR agrees to make internal practices, books, and records, including policies and procedures, relating to the use and disclosure of PHI received from, or created or received by CONTRACTOR on behalf of, COUNTY available to COUNTY and the Secretary in a time and manner as determined by COUNTY or as designated by the Secretary for purposes of the Secretary determining COUNTY’S compliance with the HIPAA Privacy Rule.
10. CONTRACTOR agrees to document any Disclosures of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY, and to make information related to such Disclosures available as would be required for COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
11. CONTRACTOR agrees to provide COUNTY or an Individual, as directed by COUNTY, in a time and manner to be determined by COUNTY, that information collected in accordance with the Agreement, in order to permit COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
12. XXXXXXXXXX agrees that to the extent CONTRACTOR carries out COUNTY’s obligation under the HIPAA Privacy and/or Security rules CONTRACTOR will comply with the requirements of 45 CFR Part 164 that apply to COUNTY in the performance of such obligation.
13. If CONTRACTOR receives Social Security data from COUNTY provided to COUNTY by a state agency, upon request by COUNTY, CONTRACTOR shall provide COUNTY with a list of all employees, subcontractors and agents who have access to the Social Security data, including employees, agents, subcontractors and agents of its subcontractors.
14. CONTRACTOR will notify COUNTY if CONTRACTOR is named as a defendant in a criminal proceeding for a violation of HIPAA. COUNTY may terminate the Agreement, if CONTRACTOR is found guilty of a criminal violation in connection with HIPAA. COUNTY may terminate the Agreement, if a finding or stipulation that CONTRACTOR has violated any standard or requirement of the privacy or security provisions of HIPAA, or other security or privacy laws are made in any administrative or civil proceeding in which CONTRACTOR is a party or has been joined. COUNTY will consider the nature and seriousness of the violation in deciding whether or not to terminate the Agreement.
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies.
2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
