Effect of Review Interconnected Transmission Owner's and Transmission Provider’s reviews of Interconnection Customer's initial drawings of the Customer Interconnection Facilities shall not be construed as confirming, endorsing or providing a warranty as to the fitness, safety, durability or reliability of such facilities or the design thereof. At its sole cost and expense, Interconnection Customer shall make such changes to the design of the Customer Interconnection Facilities as may reasonably be required by Transmission Provider, in consultation with the Interconnected Transmission Owner, to ensure that the Customer Interconnection Facilities meet Applicable Standards and, to the extent that design of the Customer Interconnection Facilities is included in the Facilities Study, to ensure that such facilities conform with the Facilities Study.
Effect of Restatement This Agreement shall, except as otherwise expressly set forth herein, supersede the First Restated Credit Agreement from and after the Second Restatement Date with respect to the transactions hereunder and with respect to the Loans and Letters of Credit outstanding under the First Restated Credit Agreement as of the Second Restatement Date. The parties hereto acknowledge and agree, however, that (a) this Agreement and all other Loan Documents executed and delivered herewith do not constitute a novation, payment and reborrowing or termination of the Obligations under the First Restated Credit Agreement and the other Loan Documents as in effect prior to the Second Restatement Date, (b) such Obligations are in all respects continuing with only the terms being modified as provided in this Agreement and the other Loan Documents, (c) the liens and security interests in favor of the Agent for the benefit of the Secured Parties securing payment of such Obligations are in all respects continuing and in full force and effect with respect to all Obligations and (d) all references in the other Loan Documents to the Credit Agreement shall be deemed to refer without further amendment to this Agreement.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Notification of litigation The Borrower will provide the Agent with details of any legal or administrative action involving the Borrower, any Security Party, the Approved Manager, any Ship or the Earnings or the Insurances of any Ship as soon as such action is instituted or it becomes apparent to the Borrower that it is likely to be instituted, unless it is clear that the legal or administrative action cannot be considered material in the context of any Finance Document.
Effect of Replacement In the event of the substitution of an Airframe or of a Replacement Engine pursuant to Section 10 of the Lease, all provisions of this Trust Indenture relating to the Airframe or Engine or Engines being replaced shall be applicable to such Replacement Airframe or Replacement Engine or Engines with the same force and effect as if such Replacement Airframe or Replacement Engine or Engines were the same airframe or engine or engines, as the case may be, as the Airframe or Engine or Engines being replaced but for the Event of Loss with respect to the Airframe or Engine or Engines being replaced.
Binding Effect of Resolutions Every resolution and every Extraordinary Resolution passed in accordance with the provisions of this Article 7 at a meeting of Registered Warrantholders shall be binding upon all the Warrantholders, whether present at or absent from such meeting, and every instrument in writing signed by Registered Warrantholders in accordance with Section 7.14 shall be binding upon all the Warrantholders, whether signatories thereto or not, and each and every Warrantholder and the Warrant Agent (subject to the provisions for indemnity herein contained) shall be bound to give effect accordingly to every such resolution and instrument in writing.
Procedures for Notification and Defense of Claim (a) Indemnitee shall notify the Company in writing of any matter with respect to which Indemnitee intends to seek indemnification or advancement of Expenses as soon as reasonably practicable following the receipt by Indemnitee of notice thereof. The written notification to the Company shall include, in reasonable detail, a description of the nature of the Proceeding and the facts underlying the Proceeding. The failure by Indemnitee to notify the Company will not relieve the Company from any liability which it may have to Indemnitee hereunder or otherwise than under this Agreement, and any delay in so notifying the Company shall not constitute a waiver by Indemnitee of any rights, except to the extent that such failure or delay materially prejudices the Company. (b) If, at the time of the receipt of a notice of a Proceeding pursuant to the terms hereof, the Company has directors’ and officers’ liability insurance in effect that may be applicable to the Proceeding, the Company shall give prompt notice of the commencement of the Proceeding to the insurers in accordance with the procedures set forth in the applicable policies. The Company shall thereafter take all commercially-reasonable action to cause such insurers to pay, on behalf of Indemnitee, all amounts payable as a result of such Proceeding in accordance with the terms of such policies. (c) In the event the Company may be obligated to make any indemnity in connection with a Proceeding, the Company shall be entitled to assume the defense of such Proceeding with counsel approved by Indemnitee, which approval shall not be unreasonably withheld, conditioned or delayed, upon the delivery to Indemnitee of written notice of its election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee for any fees or expenses of counsel subsequently incurred by Indemnitee with respect to the same Proceeding. Notwithstanding the Company’s assumption of the defense of any such Proceeding, the Company shall be obligated to pay the fees and expenses of Indemnitee’s separate counsel to the extent (i) the employment of separate counsel by Indemnitee is authorized by the Company, (ii) counsel for the Company or Indemnitee shall have reasonably concluded that there is a conflict of interest between the Company and Indemnitee in the conduct of any such defense such that Indemnitee needs to be separately represented, (iii) the Company is not financially or legally able to perform its indemnification obligations or (iv) the Company shall not have retained, or shall not continue to retain, counsel to defend such Proceeding. The Company shall have the right to conduct such defense as it sees fit in its sole discretion. Regardless of any provision in this Agreement, Indemnitee shall have the right to employ counsel in any Proceeding at Indemnitee’s personal expense. The Company shall not be entitled, without the consent of Indemnitee, to assume the defense of any claim brought by or in the right of the Company. (d) Indemnitee shall give the Company such information and cooperation in connection with the Proceeding as may be reasonably appropriate. (e) The Company shall not be liable to indemnify Indemnitee for any settlement of any Proceeding (or any part thereof) without the Company’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed. (f) The Company shall not settle any Proceeding (or any part thereof) in a manner that imposes any penalty or liability on Indemnitee without Indemnitee’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.
Limitation on Out-of-State Litigation Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Effect of the Plan This Award is subject to all of the provisions of the Plan and this Agreement, together with all of the rules and determinations from time to time issued by the Committee and/or the Board pursuant to the Plan, including the restrictions in the Plan on the transferability of awards. In the event of a conflict between any provision of the Plan and this Agreement, the provisions of this Agreement shall control but only to the extent such conflict is permitted under the Plan. By accepting this Award, the Participant acknowledges that he or she has received a copy of the Plan and agrees that the Participant will enter into such written representations, warranties and agreements and execute such documents as the Company may reasonably request in order to comply with applicable securities and other applicable laws, rules or regulations, or with this document or the terms of the Plan.
Effect of Settlement Neither the Grantee nor any of the Grantee’s successors, heirs, assigns or personal representatives shall have any further rights or interests in any Restricted Stock Units that have been paid and settled. Although a settlement date or range of dates for settlement are specified above in order to comply with Code Section 409A, the Company retains discretion to determine the settlement date, and no Grantee or beneficiary of a Grantee shall have any claim for damages or loss by virtue of the fact that the market price of Common Stock was higher on a given date upon which settlement could have been made as compared to the market price on or after the actual settlement date (any claim relating to settlement will be limited to a claim for delivery of Shares and related dividend equivalents).
