Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--
(i) In the contract price or delivery schedule or both; and
(ii) In such other provisions of the contract as may be affected.
(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Governing Law; Equitable Remedies THIS AGREEMENT SHALL BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH, THE LAWS OF THE STATE OF DELAWARE (WITHOUT GIVING EFFECT TO CONFLICT OF LAWS PRINCIPLES THEREOF). The parties hereto agree that irreparable damage would occur in the event that any of the provisions of this Agreement were not performed in accordance with its specific terms or was otherwise breached. It is accordingly agreed that the parties hereto shall be entitled to an injunction or injunctions and other equitable remedies to prevent breaches of this Agreement and to enforce specifically the terms and provisions hereof in any of the Selected Courts (as defined below), this being in addition to any other remedy to which they are entitled at law or in equity. Any requirements for the securing or posting of any bond with respect to such remedy are hereby waived by each of the parties hereto. Each party further agrees that, in the event of any action for an injunction or other equitable remedy in respect of such breach or enforcement of specific performance, it will not assert the defense that a remedy at law would be adequate.
Availability of Equitable Remedies Since a breach of the provisions of this Agreement could not adequately be compensated by money damages, any party shall be entitled, either before or after the Closing, in addition to any other right or remedy available to it, to an injunction restraining such breach or a threatened breach and to specific performance of any such provision of this Agreement, and in either case no bond or other security shall be required in connection therewith, and the parties hereby consent to the issuance of such an injunction and to the ordering of specific performance.
Section 754 Adjustments To the extent an adjustment to the adjusted tax basis of any Company asset, pursuant to Code Section 734(b) or Code Section 743(b) is required, pursuant to Regulations Section 1.704-1(b)(2)(iv)(m)(2) or 1.704-1(b)(2)(iv)(m)(4), to be taken into account in determining Capital Accounts as the result of a distribution to a Unit Holder in complete liquidation of such Unit Holder’s interest in the Company, the amount of such adjustment to Capital Accounts shall be treated as an item of gain (if the adjustment increases the basis of the asset) or loss (if the adjustment decreases such basis) and such gain or loss shall be specially allocated to the Unit Holders in accordance with their interests in the Company in the event Regulations Section 1.704-1(b)(2)(iv)(m)(2) applies, or to the Unit Holder to whom such distribution was made in the event Regulations Section 1.704-1(b)(2)(iv)(m)(4) applies.
Equitable Remedy Because of the difficulty of measuring economic losses to the Company as a result of a breach of the restrictive covenants set forth in Sections 5 and 6 hereof, and because of the immediate and irreparable damage that would be caused to the Company for which monetary damages would not be a sufficient remedy, it is hereby agreed that in addition to all other remedies that may be available to the Company or Executive at law or in equity, the Company or Executive shall be entitled to specific performance and any injunctive or other equitable relief as a remedy for any breach or threatened breach of the aforementioned restrictive covenants.
Equitable Remedies The parties hereto agree that irreparable harm would occur in the event that any of the agreements and provisions of this Agreement were not performed fully by the parties hereto in accordance with their specific terms or conditions or were otherwise breached, and that money damages are an inadequate remedy for breach of this Agreement because of the difficulty of ascertaining and quantifying the amount of damage that will be suffered by the parties hereto in the event that this Agreement is not performed in accordance with its terms or conditions or is otherwise breached. It is accordingly hereby agreed that the parties hereto shall be entitled to an injunction or injunctions to restrain, enjoin and prevent breaches of this Agreement by the other parties and to enforce specifically the terms and provisions hereof in any court of the United States or any state having jurisdiction, such remedy being in addition to and not in lieu of, any other rights and remedies to which the other parties are entitled to at law or in equity.
Section 754 Adjustment To the extent an adjustment to the adjusted tax basis of any Partnership asset pursuant to Code Section 734(b) or Code Section 743(b) is required, pursuant to Regulations Section 1.704-1(b)(2)(iv)(m)(2) or Regulations Section 1.704-1(b)(2)(iv)(m)(4), to be taken into account in determining Capital Accounts as the result of a distribution to a Holder in complete liquidation of his interest in the Partnership, the amount of such adjustment to the Capital Accounts shall be treated as an item of gain (if the adjustment increases the basis of the asset) or loss (if the adjustment decreases such basis) and such gain or loss shall be specially allocated to the Holders in accordance with their interests in the Partnership in the event that Regulations Section 1.704-1(b)(2)(iv)(m)(2) applies, or to the Holders to whom such distribution was made in the event that Regulations Section 1.704-1(b)(2)(iv)(m)(4) applies.
Contribution; Limitations on Liability; Non-Exclusive Remedy If the indemnification provided for in this Section 5 is unavailable or insufficient to hold harmless an indemnified party under subsection (a) or (b) above, then each indemnifying party shall contribute to the amount paid or payable by such indemnified party as a result of the losses, claims, damages or liabilities referred to in subsection (a) or (b) above, (i) in such proportion as is appropriate to reflect the relative benefits received by the Company on the one hand and the Agent on the other from the offering of the Shares, or (ii) if the allocation provided by clause (i) above is not permitted by applicable law, in such proportion as is appropriate to reflect not only the relative benefits referred to in clause (i) above but also the relative fault of the Company on the one hand and the Agent on the other in connection with the statements or omissions that resulted in such losses, claims, damages or liabilities, as well as any other relevant equitable considerations. The relative benefits received by the Company on the one hand and the Agent on the other shall be deemed to be in the same proportion as the total net proceeds from the offering (before deducting expenses) received by the Company bear to the total commissions received by the Agent (before deducting expenses) from the sale of the Shares. The relative fault shall be determined by reference to, among other things, whether the untrue or alleged untrue statement of a material fact or the omission or alleged omission to state a material fact relates to information supplied by the Company or the Agent, the intent of the parties and their relative knowledge, access to information and opportunity to correct or prevent such untrue statement or omission. The Company and the Agent agree that it would not be just and equitable if contributions pursuant to this subsection (d) were to be determined by pro rata allocation or by any other method of allocation which does not take account of the equitable considerations referred to in this subsection (d). The amount paid or payable by an indemnified party as a result of the losses, claims, damages or liabilities referred to in this subsection (d) shall be deemed to include any legal or other expenses reasonably incurred by such indemnified party in connection with investigating or defending against any action or claim which is the subject of this subsection (d). Notwithstanding the provisions of this subsection (d), the Agent shall not be required to contribute any amount in excess of the commissions received by it under this Agreement. No person guilty of fraudulent misrepresentation (within the meaning of Section 11(f) of the Securities Act) shall be entitled to contribution from any person who was not guilty of such fraudulent misrepresentation.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
