Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans. (a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant. (b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent. (a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business. (b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans. (a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease. (b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding. 3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant. 3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time: (a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways; (b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available; (c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas; (d) To add additional buildings and improvements to the Common Areas; (e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and (f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
DESCRIPTION OF THE PREMISES Prior to, or during the first month of the effective use (transfer of keys) of the rented property and whenever important alterations have been made to the rented property during the rental period, both parties are obliged to draw up a detailed and contradictory description of the property at their joint expense. If one of the parties so requests, the parties will draw up a detailed and contradictory description of the premises at their joint expense at the end of the rental period. In the absence of an initial description of the premises, the tenant is deemed to have received the property in the condition in which it is in at the time they leave, except if the necessary proof to the contrary is provided. The same applies if no final description of the premises has been drawn up by the end date of the contract. After signature by the contracting parties, the description of the premises will be appended to the present agreement. The lessor has the right to make the reimbursement or release of the deposit dependent on the drawing up of the final description of the premises in the presence of the tenant or their representative, at a mutually agreed time. The lessor will make every effort to be present at this description of the premises at a reasonable time.
Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
Access to Leased Premises Landlord may enter the Leased Premises after business hours, upon twenty-four (24) hour notice to Tenant (and at any time and without notice in case of emergency), for the purposes of (a) inspect the Leased Premises, (b) exhibiting the Leased Premises to prospective purchasers, lenders or, within one hundred eighty (180) days of the end of the Term, prospective, (c) determining whether Tenant is complying with all of its obligations hereunder, (d) supplying janitorial service and any other services to be provided by Landlord to Tenant hereunder, (e) post notices of non-responsibility, and (f) make repairs required of Landlord under the terms hereof or repairs to any adjoining space or utility services or make repairs, alterations or improvements to any other portion of the Building. For such purposes, Landlord shall at all times have and retain a key with which to unlock all of the doors in, on or about the Leased Premises (excluding Tenant’s vaults, safes, storage facilities for sensitive materials, confidential patient files and similar areas designated in writing by Tenant in advance); and Landlord shall have the right to use any and all means which Landlord may deem proper to open said doors in any emergency in order to obtain entry to the Leased Premises. If, as a result of any such inspection or for any reason, Landlord reasonably determines that Tenant has failed to meet its obligations under Section 5.2 hereof, Landlord shall so notify Tenant and Tenant shall immediately commence to cure any such failure. In the event Tenant refuses or neglects to commence and complete such cure within a reasonable time, Landlord may make or cause to be made such repairs. In such event, Landlord’s cost to make such repairs shall constitute an Advance.
Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.
Construction of Tenant Improvements Tenant shall install the Tenant Improvements (as described in Paragraph 2(a) below) in accordance with the terms and conditions of this Work Letter. The quantities, character and manner of installation of all of the work related to the Tenant Improvements shall be subject to the limitations imposed by any applicable governmental regulations, laws, ordinances, codes and rules. Notwithstanding the foregoing, Landlord may at Landlord’s sole election itself (with Landlord’s contractor) construct the portion of the Tenant Improvements that consist of the restrooms and related improvements that will service Building 2 (the “Restroom Improvements”), at Tenant’s cost up to a maximum amount of $322,764 (subject to Section 9(b) below), provided that (a) Landlord notifies Tenant in writing of such election prior to Tenant’s commencement of construction of the Tenant Improvements, and (b) Landlord shall use commercially reasonable efforts to not unreasonably interfere with or delay Tenant’s installation of the Tenant Improvements. If a certificate of occupancy or equivalent permit sign-off for the Premises is delayed beyond the Building 2 Scheduled Commencement Date solely as a result of Landlord’s failure to substantially complete the Restroom Improvements prior to such date, which failure does not result from Tenant Delays (as defined below) or Force Majeure, then the Building 2 Commencement Date shall be extended day for day by the number of days after the Building 2 Scheduled Commencement Date until the issuance of a certificate of occupancy or equivalent permit sign-off (but in no event shall the Building 2 Commencement Date be delayed beyond the date Tenant commences business in the Premises), provided, however, that Tenant delivers written notice to Landlord at such time as Tenant becomes aware that Landlord is in danger of causing such delay. “Tenant Delays” shall mean (i) Tenant’s delay in submittal of Tenant’s Plans and/or responses to Landlord’s comments to Tenant’s Plans beyond the time periods provided in this Work Letter, (ii) Tenant’s delay in any submittals for permits or other governmental approvals with respect to the Tenant Improvements (including without limitation the Restroom Improvements), (iii) changes in Tenant’s Plans as they relate to the Restroom Improvements after they have been submitted to governmental authorities for permits, (iv) delay in obtaining materials for reasons outside Landlord’s reasonable control, and (v) Tenant’s failure to provide reasonable access to the Premises to Landlord’s contractors to install the Restroom Improvements, or unreasonable interference with such installation by Tenant or its contractors or agents.