Escalation of Liquidated Damages Amounts. Pursuant to Article 11.4, Contractor shall provide Authority with its escalation calculations for each of the liquidated damage amounts set forth in Article 12.1 and Article
Escalation of Liquidated Damages Amounts Sample Clauses
Related to Escalation of Liquidated Damages Amounts
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.
CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Certain Rules Relating to the Payment of Additional Amounts (a) If any Affected Person requests compensation under Section 5.01, or if the Borrower is required to pay any additional amount to any Affected Person or to any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, then such Affected Person shall (at the request of the Borrower) use commercially reasonable efforts to designate a different lending office for funding or booking the related Loans hereunder or to assign and delegate (or cause to be assigned and delegated) such Affected Person’s rights and obligations hereunder to another office, branch or Affiliate of such Affected Person if, in the judgment of such Affected Person, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 5.01 or 5.03, as the case may be, in the future and (ii) would not subject such Affected Person to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Affected Person. The Borrower hereby agrees to pay all reasonable out of pocket costs and expenses incurred by any Affected Person in connection with any such designation or assignment and delegation. (b) If (i) any Affected Person requests compensation under Section 5.01, (ii) the Borrower is required to pay any additional amount to any Affected Person or any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, (iii) any Affected Person has become a Defaulting Lender or (iv) any Affected Person has failed to consent to a proposed amendment, waiver, discharge or termination that requires the consent of all Lenders and with respect to which the other Lenders shall have or would have granted their consent, then the Borrower may, at its sole expense and effort, upon notice to the Administrative Agent, require the Administrative Agent to cause the related Affected Person to assign and delegate, without recourse (in accordance with and subject to all applicable transfer restrictions), all its interests, rights and obligations under this Agreement and the other Transaction Documents to another appropriate Person (which, in the case of a Lender, shall be an Eligible Assignee) that shall acquire such interest or assume such commitment; provided that (a) the Borrower shall have received the prior written consent of the Administrative Agent and the other Lenders, which consent shall not unreasonably be withheld, (b) such Affected Person, if a Lender, shall have received payment of an amount equal to its outstanding Capital and, if applicable, accrued Interest and Fees thereon and all other amounts then owing to it hereunder from the assignee or the Borrower, (c) in the case of any such assignment and delegation resulting from a claim for compensation under Section 5.01 or payments required to be made pursuant to Section 5.03, such assignment is expected to result in a reduction in such compensation or payments for future periods and (d) in the case of any such assignment and delegation resulting from the failure of an Affected Person to provide a consent, the assignee shall have given such consent and, as a result of such assignment and delegation and any contemporaneous assignments and delegations and consents, the applicable amendment, waiver, discharge or termination can be effected. An Affected Person shall not be required to make any such assignment and delegation if, prior thereto, as a result of a waiver or consent by such Affected Person or otherwise, the circumstances entitling the Borrower to require such assignment and delegation have ceased to apply.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Xxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
