Establishment of Collateral Account The Securities Intermediary hereby confirms that:
(a) the Securities Intermediary has established the Collateral Account;
(b) the Collateral Account is a securities account;
(c) subject to the terms of this Agreement, the Securities Intermediary shall identify in its records the Collateral Agent as the entitlement holder entitled to exercise the rights that comprise any financial asset credited to the Collateral Account;
(d) all property delivered to the Securities Intermediary pursuant to this Agreement, including any Applicable Ownership Interests in the Treasury Portfolio (as specified in clause (i) of the definition thereof) or Treasury Securities and the Permitted Investments, will be credited promptly to the Collateral Account; and
(e) all securities or other property underlying any financial assets credited to the Collateral Account shall be (i) registered in the name of the Purchase Contract Agent and indorsed to the Securities Intermediary or in blank, (ii) registered in the name of the Securities Intermediary or (iii) credited to another securities account maintained in the name of the Securities Intermediary. In no case will any financial asset credited to the Collateral Account be registered in the name of the Purchase Contract Agent (in its capacity as such) or any Holder or specially indorsed to the Purchase Contract Agent (in its capacity as such) or any Holder, unless such financial asset has been further indorsed to the Securities Intermediary or in blank.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Establishment of Collection Account (a) The Servicer, on behalf of the Issuer and the Indenture Trustee, shall establish the Collection Account in the name of the Indenture Trustee for the benefit of the Securityholders. The Collection Account shall be an Eligible Deposit Account initially established with the Indenture Trustee and maintained with the Indenture Trustee. Except as otherwise provided in this Agreement, in the event that the Collection Account maintained with the Indenture Trustee is no longer an Eligible Deposit Account, then the Servicer shall, with the Indenture Trustee’s assistance, as necessary, use reasonable efforts to cause the Collection Account to be moved to an Eligible Institution within thirty days.
(b) For so long as the Collection Account is maintained as an Eligible Deposit Account, all amounts held in these accounts shall, to the extent permitted by applicable laws, rules and regulations, be invested, as directed in writing by the Servicer, in Eligible Investments; otherwise such amounts shall be maintained in cash. Earnings on investment of funds in these accounts (net of losses and investment expenses) shall be paid to the Servicer on each Payment Date as servicing compensation, and any losses and investment expenses shall be charged against the funds on deposit in the related account.
(c) For so long as Deutsche Bank Trust Company Americas is the Indenture Trustee, the Collection Account shall be maintained with Deutsche Bank Trust Company Americas as an Eligible Deposit Account. In the event that the long-term debt rating of the Indenture Trustee does not satisfy clause (a) of the definition of Eligible Deposit Account, the Servicer shall, with the assistance of the Indenture Trustee, as necessary, use reasonable efforts to cause the Collection Account to be moved to an Eligible Institution or an account otherwise satisfying the requirements of clause (b) of the definition of Eligible Deposit Account (which may be an account with the Indenture Trustee) within thirty days.
(d) The Indenture Trustee shall transfer all amounts remaining on deposit in the Collection Account on the Payment Date on which the Notes of all Classes have been paid in full (or substantially all of the Trust Estate is otherwise released from the lien of the Indenture) to the Issuer for the benefit of the Certificateholder, and to take all necessary or appropriate actions to transfer all of its right, title and interest in the Collection Account, all funds or investments held or to be held therein and all proceeds thereof, to the Issuer for the benefit of the Certificateholder, subject to the limitations set forth in the Indenture with respect to amounts held for payment to the Noteholders that do not promptly deliver a Note for payment on such Payment Date.
(e) With respect to the Collection Account and all property held therein, the Issuer agrees, by its acceptance hereof that, on the terms and conditions set forth in the Indenture, for so long as Notes of any Class remain outstanding, the Indenture Trustee shall possess all right, title and interest therein (excluding interest or investment income thereon payable to the Servicer), and that such account shall be under the sole dominion and control of the Indenture Trustee for the benefit of the Noteholders and the Certificateholder, as set forth in the Indenture. The parties hereto agree that the Servicer shall have the power, revocable by the Indenture Trustee upon an Event of Default resulting in an acceleration of the Notes or liquidation of the Trust Estate or by the Owner Trustee with the consent of the Indenture Trustee, to instruct the Indenture Trustee to make withdrawals and payments from the Collection Account for the purpose of permitting the Servicer, Indenture Trustee or the Owner Trustee to carry out its respective duties hereunder or under the Indenture or the Trust Agreement, as the case may be.
Establishment of Account (a) The Fund hereby appoints the Custodian as the custodian of all Securities and cash at any time delivered to the Custodian to be held under this Agreement. The Custodian hereby accepts such appointment and agrees to establish and maintain one or more accounts for each Series in which the Custodian will hold Securities and cash as provided herein. Such accounts (each, an “Account,” and collectively, the “Accounts”) shall be in the name of the Fund and Series, if any.
(b) The Custodian may from time to time establish on its books and records such sub-accounts within each Account as the Fund and the Custodian may agree upon (each a “Special Account”), and the Custodian shall reflect therein such assets as the Fund may specify in Instructions.
(c) The Custodian may from time to time establish pursuant to a written agreement with and for the benefit of a broker, dealer, future commission merchant or other third party identified in Instructions such accounts on such terms and conditions as the Fund and the Custodian shall agree, and the Custodian shall transfer to such account such Securities and money as the Fund may specify in Instructions.
Establishment of Collateral Accounts Securities Intermediary acknowledges and agrees that: (i) it has established and is maintaining on its books and records the accounts identified on the attached Schedule 1 (each such account, together with any replacements thereof or substitutions therefor, the “Collateral Account” and such accounts, collectively, the “Collateral Accounts”) in the name of the Borrower; (ii) each Collateral Account is a “securities account” (within the meaning of Section 8-501(a) of the UCC) in respect of which Securities Intermediary is a “securities intermediary” (within the meaning of Section 8-102(a)(14) of the UCC and, with respect to any Book-Entry Security, within the meaning of Federal Book-Entry Regulations) and the Security Agent is the “entitlement holder” (within the meaning of Section 8-102(a)(7) of the UCC); provided, however, that if, notwithstanding the intention of the parties hereto, all or any portion of the Collateral Account is determined to be a “deposit account” (within the meaning of Section 9-102 of the UCC) rather than a “securities account,” then the Securities Intermediary represents, warrants, covenants and agrees that it is a “bank” (as defined in Section 9-102(a)(8) of the UCC) and will treat the Borrower as its customer (within the meaning of Section 9-104(a)(3) of the UCC) with respect to the Collateral Accounts (or portion thereof); (iii) all property delivered, or to be delivered, to Securities Intermediary pursuant to this Agreement is, and will be, promptly credited to the Collateral Accounts; (iv) it does not know of any claim to or interest in any Collateral Account or any assets or funds therein, except for claims and interests of the parties to this Agreement as set forth herein; and (v) it shall not change the name or account number of any Collateral Account without the prior written consent of the Security Agent. Except as provided in Section 2(b), Securities Intermediary agrees that it shall not take “entitlement orders” (as defined in Section 8-102(a)(8) of the UCC) or “instructions” (within the meaning of Section 9-104(a)(2) of the UCC) with respect to the Collateral Accounts or any assets or funds therein from any Person other than the Security Agent.
Establishment of Accounts (a) The Servicer shall establish and maintain an Eligible Account with the Securities Intermediary in the name of the Indenture Trustee for the benefit of (i) the Securityholders (the “Collection Account”), (ii) the Noteholders (the “Note Distribution Account”), (iii) the Securityholders (the “Reserve Fund”) and (iv) the Securityholders (the “Yield Supplement Account”), in each case, bearing a designation clearly indicating that the funds deposited therein are held for the benefit of the related Securityholders. Except as otherwise provided in this Agreement, in the event that the Indenture Trustee is no longer an Eligible Institution, the Servicer shall, with the assistance of the Indenture Trustee as necessary, cause the Accounts to be moved to an Eligible Institution.
(b) To the extent permitted by applicable laws, rules and regulations, all amounts held in the Collection Account, the Reserve Fund and the Yield Supplement Account shall be either invested by the Securities Intermediary in Eligible Investments selected in writing by the Servicer or maintained in cash. No amounts held in the Note Distribution Account will be invested. Earnings on investment of funds in the Collection Account (net of losses and investment expenses) shall be paid to the Servicer as part of the Supplemental Servicing Fee and any losses and investment expenses shall be charged against the funds on deposit in the related Account.
(i) Except as otherwise provided in Section 4.01(b), the Indenture Trustee shall possess all right, title and interest in all funds on deposit from time to time in the Accounts and in all proceeds thereof (including all income thereon) and all such funds, investments, proceeds and income shall be part of the Owner Trust Estate. The Accounts shall be under the sole dominion and control of the Indenture Trustee for the benefit of the Noteholders or the Securityholders, as the case may be.
(ii) Notwithstanding anything else contained herein, the Servicer agrees that the Reserve Fund, the Yield Supplement Account and the Collection Account will be established only with an Eligible Institution which agrees substantially as follows: (A) it will comply with Entitlement Orders related to such account issued by the Indenture Trustee without further consent by the Servicer or Issuer; (B) until termination of this Agreement, it will not enter into any other agreement related to such account pursuant to which it agrees to comply with Entitlement Orders of any Person other than the Indenture Trustee; (C) all Account Property delivered or credited to it in connection with such account and all proceeds thereof will be promptly credited to such account; (D) it will treat all Account Property as Financial Assets; and (E) all Account Property will be physically delivered (accompanied by any required endorsements) to, or credited to an account in the name of, the Eligible Institution maintaining the related Account in accordance with such Eligible Institution’s customary procedures such that such Eligible Institution establishes a Security Entitlement in favor of the Indenture Trustee with respect thereto over which the Indenture Trustee (or such other Eligible Institution) has Control.
(iii) The Servicer shall have the power, revocable by the Indenture Trustee or by the Owner Trustee with the consent of the Indenture Trustee, to instruct the Indenture Trustee to make withdrawals and payments from the Accounts for the purpose of permitting the Servicer or the Owner Trustee to carry out its respective duties hereunder or under the Trust Agreement or permitting the Indenture Trustee to carry out its duties under the Indenture.
Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.
Establishment and Maintenance of Records GRANTEE shall maintain records, including but not limited to, books, financial records, supporting documents, statistical records, personnel, property, and all other pertinent records sufficient to reflect properly:
a. All direct and indirect costs of whatever nature claimed to have been incurred and anticipated to be incurred in the performance of this AGREEMENT; and
b. All other matters covered by this AGREEMENT. Such records shall be maintained in accordance with requirements now or hereafter prescribed by the CITY.
Establishment of and Deposits to Custodial Account The Servicer shall segregate and hold all funds collected and received pursuant to the Mortgage Loans separate and apart from any of its own funds and general assets and shall establish and maintain one or more Custodial Accounts, in the form of time deposit or demand accounts, titled as directed by the Master Servicer. The Custodial Account shall be an Eligible Deposit Account established with an Eligible Institution. Any funds deposited in the Custodial Account may be invested in Eligible Investments subject to the provisions of Section 3.11 hereof. Funds deposited in the Custodial Account may be drawn on by the Servicer in accordance with Section 3.04. The creation of any Custodial Account shall be evidenced by a letter agreement in the form of Exhibit B. A copy of such certification or letter agreement shall be furnished to the Master Servicer not later than 30 calendar days after the Closing Date, and, upon request, to any subsequent owner of the Mortgage Loans. The Servicer shall deposit in the Custodial Account within two Business Days of receipt, and retain therein, the following collections received by the Servicer and payments made by the Servicer after the Cut-off Date (other than scheduled payments of principal and interest due on or before the Cut-off Date or received by the Servicer prior to the Cut-off Date but allocable to the period subsequent thereto or Servicing Transfer Date), as applicable:
(i) all payments on account of principal on the Mortgage Loans, including all Principal Prepayments;
(ii) all payments on account of interest on the Mortgage Loans adjusted to the Mortgage Loan Remittance Rate;
(iii) all Liquidation Proceeds;
(iv) all Insurance Proceeds (other than amounts applied to the restoration or repair of the Mortgaged Property or immediately released to the Mortgagor in accordance with Accepted Servicing Practices);
(v) all Condemnation Proceeds that are not applied to the restoration or repair of the Mortgaged Property or released to the Mortgagor;
(vi) with respect to each Principal Prepayment in full or in part, the Prepayment Interest Shortfall Amount, if any, for the month of distribution. Such deposit shall be made from the Servicer’s own funds, without reimbursement therefor up to a maximum amount per month of the Servicing Fee actually received for such month for the Mortgage Loans;
(vii) all Monthly Advances made by the Servicer pursuant to Section 4.03;
(viii) any amounts required to be deposited by the Servicer in connection with the deductible clause in any blanket hazard insurance policy;
(ix) any amounts received with respect to or related to any REO Property or REO Disposition Proceeds;
(x) any Prepayment Penalty Amount; and
(xi) any other amount required hereunder to be deposited by the Servicer in the Custodial Account. The foregoing requirements for deposit into the Custodial Account shall be exclusive, it being understood and agreed that, without limiting the generality of the foregoing, payments in the nature of the Servicing Fee and Ancillary Income need not be deposited by the Servicer into the Custodial Account. Any interest paid on funds deposited in the Custodial Account by the depository institution shall accrue to the benefit of the Servicer and the Servicer shall be entitled to retain and withdraw such interest from the Custodial Account pursuant to Section 3.04. Additionally, any other benefit derived from the Custodial Account associated with the receipt, disbursement and accumulation of principal, interest, taxes, hazard insurance, mortgage insurance, etc. shall accrue to the Servicer.
Establishment of Segregated Account Upon receipt of Proper Instructions, the Custodian shall establish and maintain on its books a segregated account or accounts for and on behalf of a Portfolio, into which account or accounts may be transferred cash and/or securities or other assets of such Portfolio, including securities maintained by the Custodian in a Securities System pursuant to Section 2.22(a) hereof or an Eligible Securities Depository pursuant to Section 2.22(b) hereof, said account or accounts to be maintained: (a) for the purposes set forth in Sections 2.09, 2.10 and 2.11 hereof; (b) for the purposes of compliance by the Portfolio with the procedures required by Investment Company Act Release No. 10666, or any subsequent release or releases of the SEC or SEC rules or regulations relating to the maintenance of segregated accounts by registered investment companies; or (c) for such other purposes as set forth, from time to time, in Special Instructions.
