Events of Default and Termination 9.1 Supplier Event of Default or Solar Pumpset Supplier Event of Default:
9.1.1 The occurrence and continuation of any of the following events, unless any such event occurs as a result of a Force Majeure event or a breach by DISCOM of its obligations under this Agreement, shall constitute a Supplier Event of Default (“Supplier Event of Default/Solar Pumpset Supplier Event of Default”):
(i) the Solar Pumpset Supplier transfers or novates any of its rights and/ or obligations under this Agreement, in a manner contrary to the provisions of this Agreement; except where such transfer: is in pursuance of a law; and does not affect the ability of the transferee to perform, and such transferee has the financial capability to perform, its obligations under this Agreement or is to a transferee who assumes such obligations under this Agreement and the Agreement remains effective with respect to the transferee;
(ii) the Solar Pumpset Supplier becomes voluntarily or involuntarily the subject of any bankruptcy or insolvency or winding up proceedings and such proceedings remain uncontested for a period of thirty (30) days, or Any winding up or bankruptcy or insolvency order is passed against the Solar Pumpset Supplier, or the Solar Pumpset Supplier goes into liquidation or dissolution or has a receiver or any similar officer appointed over all or substantially all of its assets or official liquidator is appointed to manage its affairs, pursuant to law, Provided that a dissolution or liquidation of the Solar Pumpset Supplier will not be a Solar Pumpset Supplier Event of Default if such dissolution or liquidation is for the purpose of a merger, consolidation or reorganization and where the resulting company retains creditworthiness similar to the Solar Pumpset Supplier and expressly assumes all obligations of the Solar Pumpset Supplier under this Agreement and is in a position to perform them; or
(iii) the Solar Pumpset Supplier repudiates this Agreement and does not rectify such breach within a period of thirty (30) days from a notice from DISCOM/NREDCAP in this regard; or
(iv) except where due to any DISCOM’s failure to comply with its material obligations, the Solar Pumpset Supplier is in breach of any of its material obligations pursuant to this Agreement, and such material breach is not rectified by the Solar Pumpset Supplier within thirty (30) days of receipt of first notice in this regard given by DISCOM/NREDCAP; or
(v) the Solar Pumpset Supplier repeatedly delays the commissioning of the Solar Pumpset Systems beyond the timelines or such extended timelines as specified in this Agreement
(vi) Occurrence of any other event which is specified in this Agreement to be a material breach/default of the Solar Pumpset Supplier.
Events of Default and Termination Events The following Events of Default and Termination Events shall apply to Party A and Party B as set forth below:
EVENTS OF DEFAULTS AND CONSEQUENCES 9.1 Subject to the Force Majeure clause, the Promoter shall be considered under a condition of Default, in the following events:
(i) Promoter fails to provide ready to move in possession of the [Apartment/Plot] to the Allottee within the time period specified in para 7.1 or fails to complete the project within the stipulated time disclosed at the time of registration of the project with the Authority. For the purpose of this para, 'ready to move in possession' shall mean that the apartment shall be in a habitable condition which is complete in all respects including the provision of all specifications, amenities and facilities, as agreed to between the parties, and for which occupation certificate and completion certificate, as the case may be, has been issued by the competent authority;
(ii) Discontinuance of the Promoter’s business as a developer on account of suspension or revocation of his registration under the provisions of the Act or the rules or regulations made the re under.
9.2 In case of Default by Promoter under the conditions listed above, Allottee is entitled to the following:
(i) Stop making further payments to Promoter as demanded by the Promoter. If the Allottee stops making payments, the Promoter shall correct the situation by completing the construction milestones and only thereafter the Allottee be required to make the next payment without any interest; or
(ii) The Allottee shall have the option of terminating the Agreement in which case the Promoter shall be liable to refund the entire money paid by the Allottee under any head whatsoever towards the purchase of the apartment, along with interest at the rate prescribed in the Rules within forty-five days of receiving the termination notice: Provided that where an Allottee does not intend to withdraw from the project or terminate the Agreement, he shall be paid, by the promoter, interest at the rate prescribed in the Rules, for every month of delay till the handing over of the possession of the [Apartment/Plot], which shall be paid by the promoter to the allottee within forty-five days of it becoming due.
9.3 The Allottee shall be considered under a condition of Default, on the occurrence of the following events:
(i) In case the Allottee fails to make payments for consecutive demands made by the Promoter as per the Payment Plan annexed hereto, despite having been issued notice in that regard the allottee shall be liable to pay interest to the promoter on the unpaid amount at the rate prescribed in the Rules;
(ii) In case of Default by Allottee under the condition listed above continues for a period beyond consecutive months after notice from the Promoter in this regard, the Promoter may cancel the allotment of the [Apartment/Plot] in favour of the Allottee and refund the money paid to him by the allottee by deducting the booking amount and the interest liabilities and this Agreement shall thereupon stand terminated. Provided that the promoter shall intimate the allottee about such termination at least thirty days prior to such termination.
Events of Default, Etc During any period during which an Event of Default shall have occurred and be continuing:
(a) each Loan Party shall, at the request of the Collateral Agent, assemble the Collateral owned by it at such place or places, as the Collateral Agent shall reasonably request;
(b) the Collateral Agent may make any compromise or settlement deemed desirable with respect to any of the Collateral and may extend the time of payment, arrange for payment in installments, or otherwise modify in any manner the terms of, any of the Collateral;
(c) the Collateral Agent shall have all of the rights and remedies with respect to the Collateral of a secured party under the Uniform Commercial Code (whether or not the Uniform Commercial Code is in effect in the jurisdiction where the rights and remedies are asserted) and such additional rights and remedies to which a secured party is entitled under all Requirements of Law in effect in any jurisdiction where any rights and remedies hereunder may be asserted, including the right, to the fullest extent permitted by applicable law, to exercise all voting, consensual and other powers of ownership pertaining to the Collateral as if the Collateral Agent were the sole and absolute owner thereof (and each Loan Party agrees to take all such action as may be appropriate to give effect to such right);
(d) the Collateral Agent in its discretion may, in its name or in the name of any Loan Party or otherwise, demand, xxx for, collect or receive any money or property at any time payable or receivable on account of or in exchange for any of the Collateral, but shall be under no obligation to do so; and
(e) the Collateral Agent may, upon five (5) Business Days’ prior written notice to the Loan Parties of the time and place (or, if such sale is to take place on an established exchange or other recognized market, prior to the time of such sale or other Disposition), with respect to the Collateral or any part thereof which shall then be or shall thereafter come into the possession, custody or control of the Collateral Agent, the other Secured Parties or any of their respective agents, sell, assign or otherwise Dispose of all or any part of such Collateral, at such place or places as the Collateral Agent deems best, and for Cash or for credit or for future delivery (without thereby assuming any credit risk), at public or private sale, without demand of performance or notice of intention to effect any such Disposition or of the time or place thereof (except such notice as is required above or by applicable statute and cannot be waived), and the Collateral Agent or any other Secured Party or anyone else may be the purchaser, assignee or recipient of any or all of the Collateral so Disposed of at any public sale (or, to the extent permitted by law, at any private sale) and thereafter, to the fullest extent permitted by Requirements of Law, hold the same absolutely, free from any claim or right of whatsoever kind, including any right or equity of redemption (statutory or otherwise), of the Loan Parties, any such demand, notice and right or equity being hereby expressly waived and released, to the fullest extent permitted by law. The Collateral Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for the sale, and such sale may be made at any time or place to which the sale may be so adjourned. The proceeds of each collection, sale or other Disposition under this Section 8.01 shall be deposited into the Custodial Account and applied in accordance with the Default Priority of Payments and any amounts obtained by the Collateral Agent on account of, or as a result of the exercise by, the Collateral Agent of any right of offset or banker’s lien or right of attachment or garnishment with respect to any funds at any time and from time to time on deposit in, or otherwise to the credit of, the Custodial Account shall be held by the Collateral Agent as additional collateral security for the repayment of the Secured Obligations and shall be applied as provided in accordance with the Default Priority of Payments. The Loan Parties recognize that, by reason of certain prohibitions contained in the Securities Act of 1933, as amended, and applicable state securities laws, the Collateral Agent may be compelled, with respect to any sale of all or any part of the Collateral, to limit purchasers to those who will agree, among other things, to acquire the Collateral for their own account, for investment and not with a view to the distribution or resale thereof. Each Loan Party acknowledges and agrees that any such private sale may result in prices and other terms less favorable than if such sale were a public sale and, notwithstanding such circumstances, agrees that any such private sale shall be deemed to have been made in a commercially reasonable manner. The Collateral Agent shall be under no obligation to delay a sale of any item of Collateral for the period of time necessary to permit the issuer thereof to register such securities for public sale under the Securities Act of 1933, as amended, or under applicable state securities laws, even if such issuer would agree to do so.
Notification of Defaults and Events of Default Each Lender hereby agrees that, upon learning of the existence of a Default or an Event of Default, it shall promptly notify the Administrative Agent thereof. The Administrative Agent hereby agrees that upon receipt of any notice under this §14.10 it shall promptly notify the other Lenders of the existence of such Default or Event of Default.
Events of Defaults If one or more of the following events ("Events of Default") shall have occurred and be continuing:
Events of Default and Remedies (a) Any one or more of the following events which shall have occurred and be continuing shall constitute an event of default (“Event of Default”):
(i) The Company or any subsidiary (A) shall institute any proceeding or voluntary case seeking to adjudicate it bankrupt or insolvent, or seeking dissolution, liquidation, winding up, reorganization, arrangement, adjustment, protection, relief or composition of it or its debts under any law relating to bankruptcy, insolvency or reorganization or relief of debtors, or seeking the entry of any order for relief or the appointment of a receiver, trustee, custodian or other similar official for such the Company or any subsidiary or for any substantial part of its property, or shall consent to the commencement against it of such a proceeding or case, or shall file an answer in any such case or proceeding commenced against it consenting to or acquiescing in the commencement of such case or proceeding, or shall consent to or acquiesce in the appointment of such a receiver, trustee, custodian or similar official; (B) shall be unable to pay its debts as such debts become due, or shall admit in writing its inability to apply its debts generally; (C) shall make a general assignment for the benefit of creditors; or (D) shall take any action to authorize or effect any of the actions set forth above in this subsection 4(a)(i);
(ii) Any proceeding shall be instituted against the Company seeking to adjudicate it a bankrupt or insolvent, or seeking dissolution, liquidation, winding up, reorganization, arrangement, adjustment, protection, relief of debtors, or seeking the entry of an order for relief or the appointment of a receiver, trustee, custodian or other similar official for the Company or for any substantial part of its property, and either such proceeding shall not have been dismissed or shall not have been stayed for a period of sixty (60) days or any of the actions sought in such proceeding (including, without limitation, the entry of any order for relief against it or the appointment of a receiver, trustee, custodian or other similar official for it or for any substantial part of its property) shall occur; or
(iii) The Company shall fail to pay the any part of the Principal when due hereunder;
(b) If an Event of Default described above has occurred, then the Holder may, without further notice to the Company, declare the principal amount of this Note at the time outstanding, and all other amounts payable under this Note to be forthwith due and payable, whereupon such principal and all such amounts shall become and be forthwith due and payable.
(c) The Company covenants that in case the Principal of the Note becomes due and payable by declaration or otherwise, then the Company will pay in cash to the Holder of this Note, the whole amount that then shall have become due and payable on this Note for Principal. In case the Company shall fail forthwith to pay such amount, the Holder may commence an action or proceeding at law or in equity for the collection of the sums so due and unpaid, and may prosecute any such action or proceeding to judgment or final decree against Company or other obligor upon this Note, wherever situated, the monies adjudicated or decreed to be payable.
Events of Default; Acceleration If any of the following events (each an "EVENT OF DEFAULT") shall occur with respect to any Borrower:
(a) Such Borrower (i) shall default in the payment of principal of any Loan, interest accrued thereon or fee due hereunder after the same becomes due and payable, whether at maturity or by acceleration or otherwise, or (ii) shall default in the payment of any other amount due hereunder after the same becomes due and payable; or
(b) Such Borrower shall default in the performance of or compliance with any term contained in Sections 9.01(a) or 9.01(b) and such default shall have continued for more than three (3) Banking Days, or such Borrower shall default in the performance of or compliance with any term contained in Sections 8.02(d), 8.02(e), 8.02(g), 8.05, 9.02, 9.03 or 9.04; or
(c) Such Borrower shall default in the performance of or compliance with any term contained herein other than those expressly referred to in this Section 10.01, and such default shall not have been remedied within five (5) Banking Days after written notice thereof shall have been given to such Borrower by the Operations Agent; or
(d) Such Borrower shall default in the performance of, or compliance with, any material term contained in any other written agreement with the Operations Agent or any Bank pertaining to this Agreement or such Borrower's Loans, and such default shall continue for more than the period of grace, if any, specified therein and shall not have been waived pursuant thereto; or
(e) Any representation, warranty certification or statement made or deemed made by such Borrower in this Agreement or in any certificate, financial statement or other document delivered pursuant hereto shall prove to have been false or incorrect in any material respect when made; or
(f) Except as otherwise provided in this Section 10.01, such Borrower shall default in any payment due on Indebtedness for borrowed money or the deferred purchase price of property, the aggregate outstanding principal amount of which is in excess of five percent (5%) of such Borrower's Total Assets, and such default shall continue for more than the period of grace, if any, applicable thereto and shall not have been waived pursuant thereto and shall permit the holder of such Indebtedness to declare such Indebtedness due and payable before its stated maturity, or in the performance of or compliance with any term of any evidence of such Indebtedness or of any mortgage, indenture or other agreement relating thereto, and any such default shall continue for more than the period of grace, if any, specified therein and shall not have been waived pursuant thereto and shall permit the holder of such Indebtedness to declare such Indebtedness due and payable before its stated maturity, unless such Borrower shall be contesting such payment or obligation in good faith by appropriate proceedings promptly initiated and diligently conducted and such Borrower shall have set aside on its books such reserves, if any, with respect thereto as are required by GAAP and deemed appropriate by such Borrower and its independent public accountants, PROVIDED, that no Event of Default pursuant to paragraphs (b) or (i) of this Section 10.01 shall have occurred and be continuing as a result of such claim having been asserted in respect of such Indebtedness; or
(g) Such Borrower shall discontinue its business (other than in connection with a permitted merger or consolidation of such Borrower) or shall make an assignment for the benefit of creditors, or shall fail generally to pay its debts as such debts become due, or shall apply for or consent to the appointment of or taking possession by a trustee, receiver or liquidator (or other similar official) of such Borrower or any substantial part of the property or assets of such Borrower or shall commence a case or have an order for relief entered against it under the federal bankruptcy laws, as now or hereafter constituted, or any other applicable federal or state bankruptcy, insolvency or other similar law, or if any action shall be taken to dissolve or liquidate such Borrower (other than in connection with a permitted merger or consolidation of such Borrower); or
(h) If, within sixty (60) days after the commencement against such Borrower of a case under the federal bankruptcy laws, as now or hereafter constituted, or any other applicable federal or state bankruptcy, insolvency or other similar law, such case shall have been consented to or shall not have been dismissed or all orders or proceedings thereunder affecting the operations or the business of such Borrower stayed, or if the stay of any such order or proceeding shall thereafter be set aside, or if within sixty (60) days after the entry of a decree appointing a trustee, receiver or liquidator (or other similar official) of such Borrower or any substantial part of the property of such Borrower such appointment shall not have been vacated; or
(i) A final judgment which, together with other outstanding final judgments against such Borrower, exceeds an amount in the aggregate equal to five percent (5%) of such Borrower's Total Assets (exclusive of amounts covered by available insurance) shall be rendered against such Borrower and if, within thirty (30) days after entry thereof, such judgment shall not have been discharged or execution thereof stayed pending appeal, or if, within thirty (30) days after the expiration of any such stay, such judgment shall not have been discharged; or
(j) Such Borrower or any member of the Controlled Group shall fail to pay when due an amount or amounts aggregating in excess of $500,000 which it is obligated to pay to the PBGC or to a Plan under Title IV of ERISA; or a notice of intent to terminate a Plan or Plans having aggregate Unfunded Liabilities in excess of $500,000 shall be filed under Title IV of ERISA by such Borrower or any member of the Controlled Group, any plan administrator or any combination of the foregoing; or the PBGC shall institute proceedings under Title IV of ERISA to terminate or to cause a trustee to be appointed to administer any such Plan or Plans or a proceeding shall be instituted by a fiduciary of any such Plan or Plans against such Borrower or any member of the Controlled Group to enforce Sections 515 or 4219(c)(5) of ERISA; or a condition shall exist by reason of which the PBGC would be entitled to obtain a decree adjudicating that any such Plan or Plans must be terminated; or there shall occur a complete or partial withdrawal from, or a default, within the meaning of Section 4219(c)(5) of ERISA, with respect to, one or more Multiemployer Plans which could cause such Borrower or one or more members of the Controlled Group to incur a current payment obligation in excess of $500,000; or
(k) Such Borrower shall cease to be an investment management company (or a Portfolio thereof) registered under the Investment Company Act, or such Borrower's registration under the Investment Company Act, or that of any Borrower Agent of such Borrower, shall lapse or be suspended; then, and in any such event, and at any time thereafter, if any Event of Default shall then be continuing with respect to such defaulting Borrower, (i) in the case of any Event of Default specified in paragraphs (g) and (h) above, the Commitments as to such defaulting Borrower shall thereupon automatically be terminated and the principal of and accrued interest on the Loans shall automatically become due and payable without presentment, demand, protest or other notice or formality of any kind, all of which are hereby expressly waived, and (ii) in the case of any other Event of Default specified above, either or both of the following actions may be taken: the Operations Agent may, and upon the written or telephonic (confirmed in writing) request of the Majority Banks shall, by written notice to such defaulting Borrower (A) declare the principal of and accrued interest in respect of such defaulting Borrower's Loans to be forthwith due and payable, whereupon the principal of and accrued interest in respect of such Loans shall become forthwith due and payable without presentment, demand, protest or other notice of any kind, all of which are hereby expressly waived by such Borrower, and/or (B) terminate the Commitments as to such defaulting Borrower, whereupon the Commitments of the Banks to make Committed Credit Loans hereunder to such defaulting Borrower shall forthwith terminate without any other notice of any kind and the percentages of the Commitment Fee and other fees and expenses otherwise payable by such defaulting Borrower hereunder accruing from and after the date of termination shall be reallocated among the remaining Borrowers PRO RATA on the basis of the percentages set forth opposite such remaining Borrowers' names on SCHEDULE 1, as in effect at the time of such termination.
Events of Default Any of the following shall constitute an Event of Default:
Default and Consequences of Default 12.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Supplier’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
12.2 If the Client owes the Supplier any money the Client shall indemnify the Supplier from and against all costs and disbursements incurred by the Supplier in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Supplier’s collection agency costs, and bank dishonour fees).
12.3 Further to any other rights or remedies the Supplier may have under this Contract, if a Client has made payment to the Supplier, and the transaction is subsequently reversed, the Client shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by the Supplier under this clause 12 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Client’s obligations under this Contract.
12.4 Without prejudice to the Supplier’s other remedies at law the Supplier shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to the Supplier shall, whether or not due for payment, become immediately payable if:
(a) any money payable to the Supplier becomes overdue, or in the Supplier’s opinion the Client will be unable to make a payment when it falls due;
(b) the Client has exceeded any applicable credit limit provided by the Supplier;
(c) the Client becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(d) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.
