Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Venue Limitation for TIPS Sales Vendor agrees that if any "Venue" provision is included in any TIPS Sale Agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Venue” clause that conflicts with these terms is rendered void and unenforceable.
CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement.
12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.
Notice of Adjustment Upon the occurrence of any event which requires any adjustment of the Exercise Price, then, and in each such case, the Company shall give notice thereof to the holder of this Warrant, which notice shall state the Exercise Price resulting from such adjustment and the increase or decrease in the number of Warrant Shares purchasable at such price upon exercise, setting forth in reasonable detail the method of calculation and the facts upon which such calculation is based. Such calculation shall be certified by the Chief Financial Officer of the Company.
Notice of Change in Exercise Price The Company shall, promptly after an event requiring a change in the Exercise Price pursuant to Section 6 hereof, send notice to the Holders of such event and change (“Price Notice”). The Price Notice shall describe the event causing the change and the method of calculating same and shall be certified as being true and accurate by the Company’s Chief Financial Officer.
Notice of Adjustments Upon the occurrence of each adjustment pursuant to this Section 9, the Company at its expense will promptly compute such adjustment in accordance with the terms of this Warrant and prepare a certificate setting forth such adjustment, including a statement of the adjusted Exercise Price and adjusted number or type of Warrant Shares or other securities issuable upon exercise of this Warrant (as applicable), describing the transactions giving rise to such adjustments and showing in detail the facts upon which such adjustment is based. Upon written request, the Company will promptly deliver a copy of each such certificate to the Holder and to the Company’s Transfer Agent.
Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.
Matters Applicable to All Requests for Compensation (a) Any Agent or any Lender claiming compensation under this Article III shall deliver a certificate to the Borrower setting forth the additional amount or amounts to be paid to it hereunder which shall be conclusive in the absence of manifest error. In determining such amount, such Agent or such Lender may use any reasonable averaging and attribution methods.
(b) With respect to any Lender’s claim for compensation under Sections 3.01, 3.02, 3.03 or 3.04, the Borrower shall not be required to compensate such Lender for any amount incurred more than one hundred and eighty (180) days prior to the date that such Lender notifies the Borrower of the event that gives rise to such claim; provided that if the circumstance giving rise to such claim is retroactive, then such 180-day period referred to above shall be extended to include the period of retroactive effect thereof. If any Lender requests compensation by the Borrower under Section 3.04, the Borrower may, by notice to such Lender (with a copy to the Administrative Agent), suspend the obligation of such Lender to make or continue from one Interest Period to another applicable Eurocurrency Rate Loan, or, if applicable, to convert Base Rate Loans into Eurocurrency Rate Loans, until the event or condition giving rise to such request ceases to be in effect (in which case the provisions of Section 3.06(c) shall be applicable); provided that such suspension shall not affect the right of such Lender to receive the compensation so requested.
(c) If the obligation of any Lender to make or continue any Eurocurrency Rate Loan, or to convert Base Rate Loans into Eurocurrency Rate Loans shall be suspended pursuant to Section 3.06(b) hereof, such Lender’s applicable Eurocurrency Rate Loans shall be automatically converted into Base Rate Loans (or, if such conversion is not possible, repaid) on the last day(s) of the then current Interest Period(s) for such Eurocurrency Rate Loans (or, in the case of an immediate conversion required by Section 3.02, on such earlier date as required by Law) and, unless and until such Lender gives notice as provided below that the circumstances specified in Sections 3.02, 3.03 or 3.04 hereof that gave rise to such conversion no longer exist:
(i) to the extent that such Lender’s Eurocurrency Rate Loans have been so converted, all payments and prepayments of principal that would otherwise be applied to such Lender’s applicable Eurocurrency Rate Loans shall be applied instead to its Base Rate Loans; and
(ii) all Loans that would otherwise be made or continued from one Interest Period to another by such Lender as Eurocurrency Rate Loans shall be made or continued instead as Base Rate Loans (if possible), and all Base Rate Loans of such Lender that would otherwise be converted into Eurocurrency Rate Loans shall remain as Base Rate Loans.
(d) If any Lender gives notice to the Borrower (with a copy to the Administrative Agent) that the circumstances specified in Sections 3.02, 3.03 or 3.04 hereof that gave rise to the conversion of any of such Lender’s Eurocurrency Rate Loans pursuant to this Section 3.06 no longer exist (which such Lender agrees to do promptly upon such circumstances ceasing to exist) at a time when Eurocurrency Rate Loans made by other Lenders under the applicable Facility are outstanding, if applicable, such Lender’s Base Rate Loans shall be automatically converted, on the first day(s) of the next succeeding Interest Period(s) for such outstanding Eurocurrency Rate Loans, to the extent necessary so that, after giving effect thereto, all Loans held by the Lenders holding Eurocurrency Rate Loans under such Facility and by such Lender are held pro rata (as to principal amounts, interest rate basis, and Interest Periods) in accordance with their respective Commitments for the applicable Facility.
