Indemnity Limitation for TIPS Sales Sample Clauses

Indemnity Limitation for TIPS Sales. Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Sample 1Sample 2Sample 3See All (4k)
AutoNDA by SimpleDocs
Indemnity Limitation for TIPS Sales. Texas and other jurisdictions (“Non-Indemnity Jurisdictions”) restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member for a project located in a Non-Indemnify Jurisdiction, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [Name of Non-Indemnity Jurisdiction]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Sample 1Sample 2
Indemnity Limitation for TIPS Sales. Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any “Indemnity” provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, “to the extent permitted by the laws and constitution of [TIPS Member’s State]” unless the Docusign Envelope ID: 1F30112E-5E1B-45A4-9768-D14BA83B6956 TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an “Indemnity” clause that conflicts with these terms is rendered void and unenforceable.
Sample 1
Indemnity Limitation for TIPS Sales. Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable. State Authorized contracts- Attainment Company only authorizes contracts for the following States (All other States are exclusive to Attainment): Texas, New Mexico, New Hampshire, Vermont, Maine, Connecticut, Montana, Idaho, Wyoming, North Dakota, South Dakota, Missouri, Mississippi, Arkansas, Alabama and Arizona
Sample 1
Indemnity Limitation for TIPS Sales. Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable. TIPS Vendor Agreement (Part 1) P 51. Arbitration Limitation for TIPS Sales. Vendor agrees that if any "Arbitration" provision is included in any TIPS Sale agreement/contract between Vendor and a TIPS Member, that clause may not require that the arbitration is mandatory or binding. Vendor agrees that if any "Arbitration" provision is included in any TIPS Sale agreement/contract between Vendor and a TIPS Member, that clause provides for only voluntary and non-binding arbitration unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Arbitration” clause that conflicts with these terms is rendered void and unenforceable. In Witness Whereof, the parties hereto, each acting under due and proper authority, have signed this Agreement. 8/6/2024 240503 Xxx Business Xxx Georgia Telcom, LLC Supplier Response Event Information Number: 240503 Title: Networking Equipment, Software, and Services (2 Part with JOC) Type: Request for Proposal Issue Date: 5/2/2024 Deadline: 6/21/2024 03:00 PM (CT) Notes: This is a solicitation issued by The Interlocal Purchasing System (TIPS), a department of Texas Region 8 Education Service Center. It is an Indefinite Delivery, Indefinite Quantity ("IDIQ") solicitation. It will result in contracts that provide, through adoption/"piggyback" an indefinite quantity of supplies/services, during a fixed period of time, to TIPS public entity and qualifying non-profit "TIPS Members" throughout the nation. Thus, there is no specific project or scope of work to review. Rather this solicitation is issued as a prospective award for utilization when any TIPS Member needs the goods or services offered during the life of the agreement. This is a two part solicitation. Part 1 is solicited for TIPS sales that are not considered a "public work" construction project. Part 1 pe...
Sample 1

Related to Indemnity Limitation for TIPS Sales

  • Venue Limitation for TIPS Sales Vendor agrees that if any "Venue" provision is included in any TIPS Sale Agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Venue” clause that conflicts with these terms is rendered void and unenforceable.

  • Automatic Renewal Limitation for TIPS Sales No TIPS Sale may incorporate an automatic renewal clause that exceeds month to month terms with which the TIPS Member must comply. All renewal terms incorporated into a TIPS Sale Supplemental Agreement shall only be valid and enforceable when Vendor received written confirmation of acceptance of the renewal term from the TIPS Member for the specific renewal term. The purpose of this clause is to avoid a TIPS Member inadvertently renewing an Agreement during a period in which the governing body of the TIPS Member has not properly appropriated and budgeted the funds to satisfy the Agreement renewal. Any TIPS Sale Supplemental Agreement containing an “Automatic Renewal” clause that conflicts with these terms is rendered void and unenforceable.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions (a) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency.

  • Indemnity & Limitation of Liability As an officer of the Company, the Executive shall be entitled to indemnity and limitation of liability as provided pursuant to the Company’s Articles of Incorporation, bylaws and any other governing document, as the same shall be amended from time to time.

  • GMP Cost Limitation The Guaranteed Maximum Price shall not be in excess of the GMP Cost Limitation.

  • How Do I Correct an Excess Contribution? If you make a contribution in excess of your allowable maximum, you may correct the excess contribution and avoid the 6% penalty tax for that year by withdrawing the excess contribution and its earnings on or before the date, including extensions, for filing your tax return for the tax year for which the contribution was made (generally October 15th). Any earnings on the withdrawn excess contribution may also be subject to the 10% early distribution penalty tax if you are under age 59½. In addition, although you will still owe penalty taxes for one or more years, excess contributions may be withdrawn after the time for filing your tax return. Excess contributions for one year may be carried forward and applied against the contribution limitation in succeeding years. An individual who is partially or entirely ineligible to make contributions to a Xxxx XXX may transfer amounts of up to the yearly contribution limits to a non-deductible Traditional IRA (subject to reduction for amounts remaining in the Xxxx XXX plus other Traditional IRA contributions).

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Warranty; Limitation of Liability Monotype warrants to you that the Licensed Web Fonts will perform substantially in accordance with W3C specifications for the use of fonts in conjunction with the ‘@font-face rule’ specified in the cascading style sheets (“CSS”) specification set forth on the xxxx://xxx.X0.xxx website as of the date of this Agreement for the twenty-one (21) day period following delivery of the Licensed Web Font(s). The Licensed Web Fonts are “productized” for web performance as of the date of this agreement and no representation is made to further productize the fonts. To make a warranty claim, you must, within the twenty-one (21) day warranty period, contact Monotype with sufficient information regarding your licensing of the Licensed Web Font(s) so as to enable Monotype to verify the existence and date of the license. If the Licensed Web Font(s) do not perform substantially in accordance with W3C specifications for the use of fonts in conjunction with the ‘@font-face rule’ specified in the cascading style sheets (“CSS”) specification set forth on the xxxx://xxx.X0.xxx website as of the date you agree to be bound by this Agreement, the entire, exclusive, and cumulative liability and remedy shall be that Monotype will use commercially reasonable effects to cause the Licensed Web Font(s) provided herein to conform with the specifications within twenty-one (21) days or as soon thereafter as commercially reasonable. MONOTYPE DOES NOT WARRANT THE RESULTS YOU MAY OBTAIN BY USING THE LICENSED WEB FONT(S). THE FOREGOING STATES THE SOLE AND EXCLUSIVE REMEDIES FOR MONOTYPE’S BREACH OF WARRANTY. EXCEPT FOR THE FOREGOING LIMITED WARRANTY, MONOTYPE MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, AS TO NONINFRINGEMENT OF THIRD PARTY RIGHTS, MERCHANTABILITY, OR FITNESS FOR ANY PARTICULAR PURPOSE. IN NO EVENT WILL MONOTYPE BE LIABLE TO YOU OR ANYONE ELSE (I) FOR ANY CONSEQUENTIAL, INCIDENTAL OR SPECIAL DAMAGES, INCLUDING WITHOUT LIMITATION ANY LOST PROFITS, LOST DATA, LOST BUSINESS OPPORTUNITIES, OR LOST SAVINGS, EVEN IF MONOTYPE HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, OR (II) FOR ANY CLAIM AGAINST YOU BY ANY THIRD PARTY SEEKING SUCH DAMAGES EVEN IF MONOTYPE IMAGING HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.. Some states or jurisdictions do not allow the exclusions of limitations of incidental, consequential or special damages, so the above exclusion may not apply to you. Also, some states or jurisdictions do not allow the exclusions of implied warranties or limitations on how long an implied warranty may last, so the above limitations may not apply to you. To the greatest extent permitted by law, any implied warranties not effectively excluded by this Agreement are limited to twenty-one (21) days. Some jurisdictions do not permit a limitation of implied warranties where the product results in physical injury or death so such limitations may not apply to you. In those jurisdictions, you agree that Monotype’s liability for such physical injury or death shall not exceed One Hundred Thousand Dollars ($100,000) United States dollars, provided that such jurisdictions permit a limitation of such liability. This warranty gives you specific legal rights. You may have other rights that vary from state to state or jurisdiction to jurisdiction. The Licensed Web Font(s) are non-returnable and nonrefundable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!