Cost Overruns In the event that the costs and expenses incurred by Borrower in completing any work which is the subject of this Agreement exceed the respective amounts allocated by Lender for such items of expense, Borrower shall be responsible for the payment (from sources other than the Property Reserves) of such excess costs and expenses.
Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
LENDER'S EXPENDITURES If any action or proceeding is commenced that would materially affect Lender's interest in the Collateral or if Borrower fails to comply with any provision of this Agreement or any Related Documents, including but not limited to Borrower's failure to discharge or pay when due any amounts Borrower is required to discharge or pay under this Agreement or any Related Documents, Lender on Borrower's behalf may (but shall not be obligated to) take any action that Lender deems appropriate, including but not limited to discharging or paying all taxes, liens, security interests, encumbrances and other claims, at any time levied or placed on any Collateral and paying all costs for insuring, maintaining and preserving any Collateral. All such expenditures incurred or paid by Lender for such purposes will then bear interest at the rate charged under the Note from the date incurred or paid by Lender to the date of repayment by Borrower. All such expenses will become a part of the Indebtedness and, at Lender's option, will (A) be payable on demand; (B) be added to the balance of the Note and be apportioned among and be payable with any installment payments to become due during either (1) the term of any applicable insurance policy; or (2) the remaining term of the Note; or (C) be treated as a balloon payment which will be due and payable at the Note's maturity.
Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Attorneys’ Fees and Costs of Collection Guarantor shall pay on demand all attorneys' fees and all other costs and expenses incurred by Lender in the enforcement of or preservation of Lender's rights under this Guaranty including, without limitation, all reasonable attorneys' fees and expenses, investigation costs, and all court costs, whether or not suit is filed herein, or whether at maturity or by acceleration, or whether before or after maturity, or whether in connection with bankruptcy, insolvency or appeal, or whether in connection with the collection and enforcement of this Guaranty against any other Guarantor, if there be more than one. Guarantor agrees to pay interest on any expenses or other sums due to Lender under this Section 10 that are not paid when due, at a rate per annum equal to the interest rate provided for in the Note. Guarantor's obligations and liabilities under this Section 10 shall survive any payment or discharge in full of the Guaranteed Obligations.
Production Proceeds Notwithstanding that, by the terms of the various Mortgages, certain Guarantors and Borrower are and will be assigning to Administrative Agent and Lenders all of the “Production Proceeds” (as defined therein) accruing to the property covered thereby, so long as no Event of Default has occurred such Loan Parties may continue to receive from the purchasers of production all such Production Proceeds, subject, however, to the Liens created under the Mortgages, which Liens are hereby affirmed and ratified. Upon the occurrence of an Event of Default, Administrative Agent and Lenders may exercise all rights and remedies granted under the Mortgages, including the right to obtain possession of all Production Proceeds then held by Loan Parties or to receive directly from the purchasers of production all other Production Proceeds. In no case shall any failure, whether purposed or inadvertent, by Administrative Agent or Lenders to collect directly any such Production Proceeds constitute in any way a waiver, remission or release of any of their rights under the Mortgages, nor shall any release of any Production Proceeds by Administrative Agent or Lenders to Loan Parties constitute a waiver, remission, or release of any other Production Proceeds or of any rights of Administrative Agent or Lenders to collect other Production Proceeds thereafter.
Initial Contribution of Trust Property; Fees, Costs and Expenses The Property Trustee acknowledges receipt from the Depositor in connection with the Original Trust Agreement of the sum of ten dollars ($10), which constituted the initial Trust Property. The Depositor shall pay all fees, costs and expenses of the Trust (except with respect to the Trust Securities) as they arise or shall, upon request of any Trustee, promptly reimburse such Trustee for any such fees, costs and expenses paid by such Trustee. The Depositor shall make no claim upon the Trust Property for the payment of such fees, costs or expenses.
Development Costs With respect to activities prior to the Amendment Effective Date, each Party was to pay [*] of the total Direct Development Costs of a Product incurred in accordance with the Development Budget (as defined in the Original Agreement). Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, with respect to activities on and after the Amendment Effective Date, subject to Sections 3.1.2, Alimera will be solely responsible for, and shall pay one hundred percent (100%) of, all development costs of a Product, including Direct Development Costs. Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, (i) all payments owing by CDS hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by CDS (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), further including any penalties and interest which might have accrued with respect thereto, and further including all CDS payments deferred pursuant to that February 11, 2008 letter agreement sent by CDS and executed by CDS and Alimera regarding deferral of payments under the Original Agreement as of such date; (ii) all payments owing by Alimera hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by Alimera (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), and further including any penalties and interest which might have accrued with respect thereto; and (iii) subject to Sections 3.1.1 and 3.1.2, from and after the Amendment Effective Date, CDS will have no liability whatsoever hereunder for any past, present or future development costs, including Direct Development Costs (which includes those incurred before, on and after the Amendment Effective Date), and instead Alimera shall have sole liability therefor.
