Mitigation of Loss Each Indemnified Party shall take and shall procure that its Affiliates take all such reasonable steps and action as are reasonably necessary in order to mitigate any Losses (or potential losses or damages) under this Article 13. Nothing in this Agreement shall or shall be deemed to relieve any Party of any common law or other duty to mitigate any losses incurred by it.
Mitigation of Losses The Indemnified Party shall procure that all reasonable steps are taken and all reasonable assistance is given (including the taking of any actions reasonably requested by an Indemnifying Party) to avoid or mitigate any Losses, which in the absence of mitigation might give rise to or increase a Loss in respect of any claim under this Article 8. Without limiting the foregoing, the Purchasers and the Sellers shall seek and collect any indemnification, reimbursement or other recovery of Losses that may be available under any applicable Corporate Trust Contract in accordance with Section 4.2 and the applicable provisions of the Purchase Agreement.
Allocation of Losses (a) On or prior to each Determination Date, the Master Servicer shall determine the amount of any Realized Loss in respect of each Mortgage Loan that occurred during the immediately preceding calendar month.
(b) With respect to any Distribution Date, the principal portion of each Realized Loss (other than any Excess Loss) with respect to a Mortgage Pool shall be allocated in the following order of priority:
(i) to the Class B-6 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(ii) to the Class B-5 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(iii) to the Class B-4 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(iv) to the Class B-3 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(v) to the Class B-2 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(vi) to the Class B-1 Certificates until the Class Certificate Balance thereof has been reduced to zero;
(vii) to the Classes of Senior Certificates of the related Certificate Group, pro rata, in accordance with their Class Certificate Balances.
(c) With respect to any Distribution Date, the principal portion of any Excess Loss with respect to a Mortgage Pool (other than Excess Bankruptcy Losses attributable to Debt Service Reductions) shall be allocated pro rata to each Class of Certificates of the related Certificate Group based on their respective Class Certificate Balances (in the case of the Senior Certificates) or Apportioned Principal Balances (in the case of the Subordinated Certificates).
(d) Any Realized Losses allocated to a Class of Certificates pursuant to Section 4.4(b) or (c) shall be allocated among the Certificates of such Class in proportion to their respective Certificate Principal Balances. Any allocation of Realized Losses pursuant to this paragraph (d) shall be accomplished by reducing the Certificate Principal Balances of the related Certificates on the related Distribution Date in accordance with Section 4.4(e).
(e) Realized Losses allocated in accordance with this Section 4.4 shall be allocated on the Distribution Date in the month following the month in which such loss was incurred and, in the case of the principal portion thereof, after giving effect to the distributions made on such Distribution Date.
(f) On each Distribution Date, the Master Servicer shall determine the Subordinated Certificate Writedown Amount, if any. Any such Subordinated Certificate Writedown Amount shall effect, without duplication of any other provision in this Section 4.4 that provides for a reduction in the Class Certificate Balance of the Subordinated Certificates, a corresponding reduction in the Class Certificate Balance of the Subordinated Certificates, which reduction shall occur on such Distribution Date after giving effect to distributions made on such Distribution Date.
(g) Notwithstanding the foregoing, no such allocation of any Realized Loss shall be made on a Distribution Date to a Class of Certificates to the extent that such allocation would result in the reduction of the aggregate Class Certificate Balances of all the Senior Certificates of a related Certificate Group as of such Distribution Date plus the Apportioned Principal Balances of the Subordinated Certificates of such Certificate Group as of such Distribution Date, after giving effect to all distributions and prior allocations of Realized Losses on such date, to an amount less than the aggregate Stated Principal Balance of the Mortgage Loans in the related Mortgage Pool as of the first day of the month of such Distribution Date, less any Deficient Valuations occurring on or prior to the Bankruptcy Coverage Termination Date (such limitation, the "Loss Allocation Limitation").
Calculation of Losses (a) The amount of any Loss for which indemnification is provided in clause (i), (ii), (iii), (iv) or (v)(A) of Section 13.01(a) of this Agreement or clause (i), (ii), (iii), (iv) or (v)(A) of Section 13.02(a) of this Agreement shall be net of any amounts actually recovered by the indemnified party under the True Insurance Policies (as such term is defined in the ATCA) with respect to such Loss; provided, however, that the indemnified party shall not have any obligation to seek any such recovery under any True Insurance Policy. The amount of any Loss for which indemnification is provided pursuant to Section 13.01(a) or Section 13.02(a) of this Agreement shall be (i) increased to take account of any net Tax cost incurred by the indemnified party arising from the receipt or accrual of indemnity payments hereunder (grossed up for such increase) and (ii) reduced to take account of any net Tax Benefit (as defined in the ATCA) realized by the indemnified party arising from the deductibility of any such Loss. In computing the amount of any such Tax cost or Tax Benefit, the indemnified party shall be deemed to recognize all other items of income, gain, loss, deduction or credit before recognizing any item arising from the receipt or accrual of any indemnity payment hereunder or the deductibility of any indemnified Loss. Any indemnification payment hereunder shall initially be made without regard to clauses (i) and (ii) in the second sentence of this Section 13.03, and shall be increased or reduced to reflect any such net Tax cost (including gross-up) or net Tax Benefit only after the indemnified party has actually realized such cost or benefit. For purposes of this Agreement, an indemnified party shall be deemed to have “actually realized” a net Tax cost or a net Tax Benefit to the extent that, and at such time as, the amount of Taxes payable by such indemnified party is increased above or reduced below, as the case may be, the amount of Taxes, that such indemnified party would be required to pay but for the receipt or accrual of the indemnity payment or the deductibility of such Loss, as the case may be. The amount of any increase or reduction hereunder shall be adjusted to reflect any final determination (which shall include the execution of Form 870 AD or successor form) with respect to the indemnified party’s liability for Taxes, and payments between the indemnified party and the indemnifying party to reflect such adjustment shall be made if necessary.
(b) No indemnified party shall be entitled to indemnification pursuant to Section 13.01(a) with respect to any Loss that has been taken account of in any adjustment pursuant to Section 1.05 of the Maleic Agreement. If the amount of any Loss, at any time subsequent to the making of any payment for indemnification pursuant to Section 13.01(a) or 13.02(a), is reduced by recovery, settlement or otherwise under or pursuant to any claim, recovery, settlement or payment by or against any other person that is not an affiliate of the indemnified party, the amount of such reduction, less any costs, expenses, premiums or other offsets incurred in connection therewith, shall promptly be repaid by the indemnified party to the indemnifying party. Upon making any payment for indemnification pursuant to Section 13.01(a) or 13.02(a), the indemnifying party shall, to the extent of such payment, be subrogated to all rights of the indemnified party (other than any rights of such indemnified party under any insurance policies) against any third party that is not an affiliate of the indemnified party in respect of the indemnifiable Loss to which such payment relates. Each such indemnified party shall duly execute upon request all instruments reasonably necessary to evidence and perfect the above described subrogation rights.
Determination of Losses The amount of any Losses subject to indemnification shall be reduced by the amounts of any Tax Benefits inuring to the Indemnified Party on account of such Loss and any insurance proceeds received by the Indemnified Party in connection therewith. If the Indemnified Party receives a Tax Benefit after an indemnification payment is made to it, the Indemnified Party shall promptly pay to the Indemnifying Party that made or directed such indemnification payment the amount of such Tax Benefit at such time or times as and to the extent that such Tax Benefit is realized by the Indemnified Party. For purposes hereof, “Tax Benefit” shall mean any refund of Taxes paid or reduction in the amount of Taxes which otherwise would have been paid. The Indemnified Party shall use commercially reasonable efforts to seek full recovery under all insurance policies covering any Losses to the same extent as they would if such Losses were not subject to indemnification hereunder. In the event that an insurance is received by any Indemnified Party with respect to any Losses for which any such Person has been indemnified hereunder, then a refund equal to the amount of the recovery shall be made promptly to the Indemnifying Party that made or directed and provided such indemnification payments to such Indemnified Party. In the case of any Third Party Claim, unless the Indemnifying Party consents otherwise (which consent shall not be unreasonably withheld), the final amount of Losses subject to indemnification shall not be determined until, and the Indemnifying Party shall not be obligated to make a payment to the Indemnified Party until, the matter underlying the Third Party Claim becomes non-appealable or is not appealed.
Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter that an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within thirty (30) days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises.
(b) If an Indemnified Party shall receive notice of any Action, audit, demand or assessment (each, a “Third Party Claim”) against it or which may give rise to a claim for a Loss under this Article VIII, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VIII except to the extent that the Indemnifying Party is materially prejudiced by such failure and shall not relieve the Indemnifying Party from any other obligation or liability that it may have to any Indemnified Party otherwise than under this Article VIII. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within five (5) days of the receipt of notice from the Indemnified Party of such Third Party Claim; provided, however, that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the expense of the Indemnifying Party. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.
LIMITATION AND EXCLUSION OF LIABILITY 1. 6. 1. Traction Software Limited does not exclude its liability (if any) to you:
1. 6. 1. 1. for personal injury or death resulting from Traction Software Limited’s negligence;
2. 6. 1. 2. for any matter for which it would be illegal for Traction Software Limited to exclude or to attempt to exclude its liability; or
3. 6. 1. 3. for fraud.
2. 6. 2. Traction Software Limited makes no express warranties with respect to the Software and Traction Software Limited hereby excludes (to the fullest extent permissible in law), all conditions, warranties (including without limitation any warranty that the Software will meet your requirements or that its operation will be uninterrupted or error free) and stipulations, express (other than those set out in this License) or implied, statutory, customary or otherwise which, but for such exclusion, would or might subsist in favour of you. Except as set out in this License you assume the entire risk as to the quality and performance of the Software.
3. 6. 3. Subject to clause 6. 1 Traction Software Limited will be under no liability to you whatsoever (whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct, indirect or consequential loss (all three of which terms include, without limitation, pure economic loss, loss of profits, loss of business, loss of data, loss of savings, depletion of goodwill and like loss) howsoever caused arising out of or in connection with:
1. 6. 3. 1. the Software, or the manufacture or sale or supply, or failure or delay in supply, of the Software by Traction Software Limited or on the part of Traction Software Limited’s employees, agents or sub-contractors;
2. 6. 3. 2. any breach by Traction Software Limited of any of the express or implied terms of this License;
3. 6. 3. 3. any use made of the Software; or
4. 6. 3. 4. any statement made or not made, or advice given or not given, by or on behalf of Traction Software Limited.
4. 6. 4. Subject to clause 6. 1 and without prejudice to clauses 6. 2 and 6. 3 , Traction Software Limited’s aggregate liability under this License(whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct or consequential loss (all three of which terms include without limitation of profits, loss of business, depletion of goodwill and like loss) howsoever caused (other than for death or personal injury caused by Traction Software Limited’s negligence) will be limited to the higher of the price paid by you to use the Software or USD $1 00.
5. 6. 5. You acknowledge that the above provisions of this clause 6 are reasonable given the charges made (if any) for the Software and you will accept such risk and/or insure accordingly.
6. 6. 6. Any rights that you have as a consumer are not affected by this clause 6.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Risk of Loss or Damage The Lessee assumes all risk of loss or damage to the Equipment from any cause and agrees to return it to the Lessor in the condition received, with the exception of wear and tear, unless otherwise provided in this Agreement.
Standard of Care; Limitation of Liability; Indemnification (a) ALPS shall be obligated to act in good faith and to exercise commercially reasonable care and diligence in the performance of its duties under this Agreement, including with regard to the processing of investments checks using mutually agreed upon procedures. The parties agree that any encoding or payment processing errors shall be governed by this standard of care and Section 4-209 of the Uniform Commercial Code is superseded by this Section 4 of this Agreement.
(b) In the absence of willful misfeasance, bad faith, negligence or reckless disregard by ALPS in the performance of its duties, obligations or responsibilities set forth in this Agreement, ALPS and its affiliates, including their respective officers, directors, agents and employees, shall not be liable for, and the Fund agrees to indemnify, defend and hold harmless such persons from, all taxes, charges, expenses, disbursements, assessments, claims, losses, damages, penalties, actions, suits, judgments and liabilities (including, without limitation, attorneys’ fees and disbursements and liabilities arising under applicable federal and state laws) arising directly or indirectly from the following:
(i) the inaccuracy of factual information furnished to ALPS by the Fund or the Fund’s investment adviser or custodian or any authorized third party on behalf of the Fund;
(ii) any reasonable error of judgment or mistake of law or for any loss suffered by the Fund in connection with the matters to which this Agreement relates;
(iii) ALPS’ reliance on any instruction, direction, notice, instrument or other information provided by the Fund or the Fund’s investment adviser or custodian or any authorized third party on behalf of the Fund that ALPS reasonably believes to be genuine;
(iv) failure to satisfy requests to cancel or amend payment orders, if ALPS receives such requests without reasonable time to comply with such requests;
(v) failure to detect any erroneous payment order, provided that ALPS complies with the payment order instructions as received and with the Security Procedure (as defined below);
(vi) lost interest with respect to the refundable amount of an unauthorized payment order, unless ALPS is notified of the unauthorized payment order within 30 days of notification by ALPS of the acceptance of such payment order; or
(vii) any other action or omission to act which ALPS properly takes in connection with the provision of services to the Fund pursuant to this Agreement.
(c) ALPS shall indemnify and hold harmless the Fund, the Fund’s investment adviser and their respective officers, directors, agents and employees from and against any and all taxes, charges, expenses, disbursements, assessments, claims, losses, damages, penalties, actions, suits, judgments and liabilities (including, without limitation, attorneys’ fees and disbursements and liabilities arising under applicable federal and state laws) arising directly or indirectly from ALPS’ willful misfeasance, bad faith, negligence or reckless disregard in the performance of its duties, obligations or responsibilities set forth in this Agreement.
(d) Notwithstanding anything in this Agreement to the contrary, neither party shall be liable under this Agreement to the other party hereto for any punitive, consequential, special or indirect losses or damages. Any indemnification payable by a party to this Agreement shall be net of insurance maintained by the indemnified party as of the time the claim giving rise to indemnity hereunder is alleged to have arisen to the extent it covers such claim.
(e) In any case in which either party (the “Indemnifying Party”) may be asked to indemnify or hold the other party (the “Indemnified Party”) harmless, the Indemnified Party will notify the Indemnifying Party promptly after identifying any situation which it believes presents or appears likely to present a claim for indemnification against the Indemnifying Party although the failure to do so shall not prevent recovery by the Indemnified Party and shall keep the Indemnifying Party advised with respect to all developments concerning such situation. The Indemnifying Party shall have the option to defend the Indemnified Party against any claim which may be the subject of this indemnification, and, in the event that the Indemnifying Party so elects, such defense shall be conducted by counsel chosen by the Indemnifying Party and reasonably satisfactory to the Indemnified Party, and thereupon the Indemnifying Party shall take over complete defense of the claim and the Indemnified Party shall sustain no further legal or other expenses in respect of such claim. The Indemnified Party will not confess any claim or make any compromise in any case in which the Indemnifying Party will be asked to provide indemnification, except with the Indemnifying Party’s prior written consent.
