Exclusions and Infringement Remedies Sample Clauses

Exclusions and Infringement Remedies. Upon ChannelAdvisor’s sole determination that the use of the ChannelAdvisor Platform infringes upon the rights of any third party, ChannelAdvisor may, at its sole discretion and own cost and expense, either: (a) procure the right for Customer to continue to license the ChannelAdvisor Platform, (b) modify the ChannelAdvisor Platform in such a way that the use thereof does not infringe on the rights of third parties, or (c) terminate this Agreement by notice to Customer and refund any Fees paid in advance for the license to use the ChannelAdvisor Platform remaining (on a prorata basis) after the termination date. ChannelAdvisor shall have no liability or obligation with respect to any infringement claim if the infringement is caused by: (i) a modification made by Customer to an item, software, or Service supplied by ChannelAdvisor or a modification made by ChannelAdvisor at Customer’s request, (ii) use of the ChannelAdvisor Platform in an application or environment other than as intended under this Agreement,
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Exclusions and Infringement Remedies. Upon ChannelAdvisor’s sole determination that the use of the ChannelAdvisor Platform infringes upon the rights of any third party, ChannelAdvisor may, at its sole discretion and own cost and expense, either: (a) procure the right for Customer to continue to license the ChannelAdvisor Platform, (b) modify the ChannelAdvisor Platform in such a way that the use thereof does not infringe on the rights of third parties, or (c) terminate this Agreement by notice to Customer and refund any Fees paid in advance for the license to use the ChannelAdvisor Platform remaining (on a pro rata basis) after the termination date. ChannelAdvisor shall have no liability or obligation with respect to any infringement claim if the infringement is caused by: (i) a modification made by Customer to an item, software, or Service supplied by ChannelAdvisor or a modification made by ChannelAdvisor at Customer’s request, (ii) use of the ChannelAdvisor Platform in an application or environment other than as intended under this Agreement, (iii) Customer’s unauthorized use of the ChannelAdvisor Platform, (iv) ChannelAdvisor acting in accordance with Customer’s specifications or guidelines, or (v) the combination, operation or use of the ChannelAdvisor Platform with other third party product(s) not supplied by ChannelAdvisor. Customer indemnifies, defends and holds harmless ChannelAdvisor and its Representatives from and against all Claims arising out of or related to any of the circumstances stated in this Section 8.4(i)-(v). The remedies stated in this Section 8.1-8.4 are the SOLE AND EXCLUSIVE remedies of Customer for the infringement of third party Intellectual Property rights by ChannelAdvisor.
Sample 1Sample 2
Exclusions and Infringement Remedies. Upon Shopping Feed’s sole determination that the use of the Shopping Feed Platform infringes upon the rights of any third party, Shopping Feed may, at its sole discretion and own cost and expense, either: (a) procure the right, at Shopping Feed’s sole cost and expense, for Customer to continue to license the Shopping Feed Platform, (b) modify the Shopping Feed Platform in such a way that the use thereof does not infringe on the rights of third parties, or (c) terminate this Agreement by notice to Customer and refund any Fees paid in advance for the license to use the Shopping Feed Platform remaining (on a prorata basis) after the termination date. Shopping Feed shall have no liability or obligation with respect to any infringement claim if the infringement is caused by: (i) a modification made by Customer to an item, software, or Service supplied by Shopping Feed or a modification made by Shopping Feed at Customer’s request, (ii) use of the Shopping Feed Platform in an application or environment other than as intended under this Agreement, (iii) Customer’s unauthorized use of the Shopping Feed Platform, (iv) Shopping Feed acting in accordance with Customer’s specifications or guidelines or (v) the combination, operation or use of the Shopping Feed Platform with other third party product(s) not supplied by Shopping Feed. Customer indemnifies, defends and holds harmless Shopping Feed from and against all obligations, actions, suits, claims, demands, settlements, judgments, damages, losses, liabilities, costs and expenses (including without limitation reasonable attorney’s fees) arising out of or related to any of the circumstances stated in this Section. The remedies stated in this Section 9.0 are the SOLE AND EXCLUSIVE remedies of Customer for the infringement of third party intellectual property rights by Shopping Feed.
Sample 1
Exclusions and Infringement Remedies. Upon ChannelAdvisor’s sole determination that the use of the ChannelAdvisor Platform infringes upon the rights of any third party, ChannelAdvisor may, at its sole discretion and own cost and expense, either: (a) procure the right for Customer to continue to license the ChannelAdvisor Platform, (b) modify the ChannelAdvisor Platform in such a way that the use thereof does not infringe on the rights of third parties. If neither (a), nor (b) can be achieved after the exercise of commercially reasonable efforts, Customer may in accordance with sec. 323 of the German Civil Code, terminate the license for ChannelAdvisor Platform, whereas in case of such termination the Customer is entitled to a refund of any fees paid in advance for the license to use CA Platform remaining (on a prorate basis) after the termination date. ChannelAdvisor shall have no liability or obligation with respect to any infringement claim if the infringement is caused by: (i) a modification made by Customer to an item, software, or Service supplied by ChannelAdvisor or a modification made by ChannelAdvisor at Customer’s request, (ii) use of the ChannelAdvisor Platform in an application or environment other than as intended under this Agreement, (iii) Customer’s unauthorized use of the ChannelAdvisor Platform, (iv) ChannelAdvisor acting in accordance with Customer’s specifications or guidelines, or (v) the combination, operation or use of the ChannelAdvisor Platform with other third party product(s) not supplied by ChannelAdvisor. Customer indemnifies, defends and holds harmless ChannelAdvisor and its Representatives from and against all obligations, actions, suits, claims, demands, settlements, judgments, damages, losses, liabilities, costs and expenses (including without limitation reasonable attorney’s fees) arising out of or related to any of the circumstances stated in this Section. The remedies stated in this Section 8.0 are the SOLE AND EXCLUSIVE remedies of Customer for the infringement of third party Intellectual Property rights by ChannelAdvisor.
Sample 1

Related to Exclusions and Infringement Remedies

  • Infringement Remedies If, in either party’s opinion, any piece of equipment, software, commodity, or service supplied by Contractor or its subcontractors, or its operation, use or reproduction, is likely to become the subject of a copyright, patent, trademark, or trade secret infringement claim, Contractor must, at its expense: (a) procure for the State the right to continue using the equipment, software, commodity, or service, or if this option is not reasonably available to Contractor, (b) replace or modify the same so that it becomes non-infringing; or (c) accept its return by the State with appropriate credits to the State against Contractor’s charges and reimburse the State for any losses or costs incurred as a consequence of the State ceasing its use and returning it.

  • INDEMNITY FOR INFRINGEMENT CLAIMS EXCEPT TO THE EXTENT ARISING FROM MATERIALS PROVIDED TO CONTRACTOR BY UNIVERSITY, WHICH MATERIALS ARE UTILIZED BY CONTRACTOR IN THEIR UNALTERED FORM AND WITHOUT LIMITING THE GENERALITY OF THE INDEMNIFICATION CLAUSE REFERENCED IN THE HOLD HARMELSS SECTION BELOW, CONTRACTOR EXPRESSLY AGREES TO INDEMNIFY AND HOLD HARMLESS UNIVERSITY AND ITS DIRECTORS, OFFICERS, EMPLOYEES, AND AGENTS FROM AND AGAINST ANY AND ALL CLAIMS, SUITS, ACTIONS, LOSSES, LIABILITIES, COSTS, EXPENSES, AND DAMAGES ARISING OUT OF OR RELATED TO ANY CLAIMS THAT THE DELIVERABLES INFRINGE ANY PATENT, COPYRIGHT, TRADE SECRET, TRADEMARK, TRADE DRESS, MASK WORK, UTILITY DESIGN, OR OTHER PROPRIETARY RIGHT OF ANY THIRD PARTY. The indemnity under this Section will not apply to the extent such alleged or actual infringement arises as a result of (i) modifications of such work made by University which were not approved by Contractor, or (ii) Contractor’s compliance with any of University’s designs, specifications or instructions. In the event that a court of competent jurisdiction determines in a final, non-appealable order that the work is infringing in a manner for which Contractor is obligated to indemnify University pursuant to this Section, Contractor will, at its option, either (1) procure for University the right to continue using such infringing work; (2) replace the infringing work with a non-infringing item of like form, fit or function; or (3) modify the work so that it no longer infringes.

  • Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.

  • Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.

  • INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.

  • Limitations and exclusions of liability 16.1 Nothing in this Agreement will:

  • Exclusions of liability 11.1 In respect of Limited Liability, we will not be liable for loss of or damage to your goods as a result of fire or explosion howsoever that fire or explosion was caused, unless we have been negligent or in breach of contract.

  • Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.

  • Exclusions and Limitations of Liability TO THE MAXIMUM EXTENT PERMITTED UNDER APPLICABLE LAW, (a) NONE OF THE 8x8 PARTIES SHALL BE LIABLE UNDER THE AGREEMENT FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE, EXEMPLARY, OR COVER DAMAGES; LOSS OF PROFITS, REVENUES, OR GOODWILL; OR LOSS OR INTERRUPTION OF BUSINESS, WHETHER FROM BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STRICT LIABILITY, OR OTHERWISE AND (b) THE MAXIMUM LIABILITY OF THE 8x8 PARTIES UNDER THE AGREEMENT, WHETHER ARISING FROM A THEORY OR CLAIM OF BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STATUTORY DUTY, OR OTHERWISE, SHALL IN NO CASE EXCEED THE TOTAL AMOUNT OF SERVICE FEES PAYABLE UNDER THE AGREEMENT FOR THE TWELVE- (12-) MONTH PERIOD PRECEDING THE FIRST INCIDENT OUT OF WHICH THE LIABILITY AROSE. THE FOREGOING EXCLUSION AND LIMITATION SHALL APPLY REGARDLESS OF WHETHER EITHER PARTY WAS ADVISED OF THE POSSIBILITY OF SUCH DAMAGES OR THE FAILURE OF THE ESSENTIAL PURPOSE OF ANY LIMITED REMEDY, AND ON A CUMULATIVE (RATHER THAN PER-INCIDENT) BASIS. CUSTOMER ACKNOWLEDGES AND AGREES THAT THE PRICING AND OTHER TERMS UNDER THE AGREEMENT ARE BASED ON THE FOREGOING EXCLUSION AND LIMITATION.

  • Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.

Time is Money Join Law Insider Premium to draft better contracts faster.